Cambridge Massachusetts Building Expert Directory

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Short-Term Rental Legislation & Litigation On the Way!

November 18, 2019 — Patrick J. Paul - Snell & Wilmer Real Estate Litigation Blog
The advent of the shared economy in the real estate context has provided homeowners and investors alike with expanded opportunities to generate revenue from the use of their real estate. Airbnb and VRBO are two of the most popular companies facilitating short-term rental availability. The rapid growth in this shared real estate economy has served as a disruptor of sorts to the traditional hotel and hospitality industry, causing that industry to revisit its own models in order to better compete. The popularity of short-term rental use, however, has created a whole new set of problems about which property owners, state and local governments, renters, and those impacted by the explosion of short-term rentals should be aware. Among other things, without more, most traditional homeowners’ policies will not cover the insured property’s use for commercial purposes – a problem similar to the early rideshare providers. Full and part-time resident owners who previously enjoyed a greater certainty with respect to their neighbors are today frustrated by the revolving door of vacationers, revelers, wedding attendees and similar nontraditional uses of neighborhood residential property. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Paul, Snell & Wilmer
Mr. Paul may be contacted at ppaul@swlaw.com

Jason Poore Receives 2018 Joseph H. Foster Young Lawyer Award

July 21, 2018 — Jason Poore - White and Williams LLP
Jason Poore, an associate in the General Litigation Group, recently received the 2018 Joseph H. Foster Young Lawyer Award during the Philadelphia Association of Defense Counsel’s annual meeting. The Joseph H. Foster Young Lawyer Award honors “a young lawyer who best exemplifies the qualities of professionalism and dedication as defense counsel in the practice of law and in the promotion of the highest ideals of justice in the community." Jason continues to make significant contributions to the local bar and community. In addition to serving on the Executive Committee of the Philadelphia Bar Association Young Lawyers Division, he is the creator and Chair of the PBA's Youth Courts Committee. Read the court decision
Read the full story...
Reprinted courtesy of Jason Poore, White and Williams LLP
Mr. Poore may be contacted at poorej@whiteandwilliams.com

Public Contract Code 9204 – A New Mandatory Claims Process for Contractors and Subcontractors – and a Possible Trap for the Unwary

March 22, 2017 — Alex R. Baghdassarian & Joseph S. Sestay – Peckar & Abramson, P.C.
New California legislation affecting public works contractors was adopted pursuant to Assembly Bill 626, sponsored by the Union Trade Contractors Association of California and endorsed by various trade and contractor associations including the AGC. AB 626, which was intended to assist contractors in presenting claims against public agencies, affords new opportunities, and some potential pitfalls, to contractors and subcontractors submitting claims to public owners. The legislation, codified at California Public Contract Code (PCC) section 9204, is effective for public works contracts entered into after January 1, 2017. All public entities (including the CSUS and the UC system), other than certain Departments of the State (CalTrans, High-Speed Rail Authority, Water Resources, Parks and Recreation, Corrections and Rehabilitation, General Services and the Military) are bound by the provisions of PCC Section 9204. PCC 9204 establishes a mandatory pre-litigation process for all claims by contractors on a public works project. It is an attempt to address the reluctance of public owners to promptly and fairly negotiate change orders on projects, putting some teeth to the mandate of existing law under PCC Section 7104, which precludes public owners from shifting to the contractor the risk of addressing differing subsurface and/or concealed hazardous site conditions. Reprinted courtesy of Alex R. Baghdassarian, Peckar & Abramson, P.C. and Joseph S. Sestay, Peckar & Abramson, P.C. Mr. Baghdassarian may be contacted at abaghdassarian@pecklaw.com Mr. Sestay may be contacted at jsestay@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Jersey Shore gets Beach Prisms Designed to Reduce Erosion

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
Thirty-five beach prisms manufactured by Smith-Midland Corporation have been installed along the Jersey shore in Ocean Gate, New Jersey. According to the Wall Street Journal, “The prisms protect homes, prevent erosion, and reduce impacts from natural disasters like Hurricane Sandy.” They “are made with a built-in parabolic curve that scatters waves away as spray instead of allowing them to crash up onto the vulnerable shoreline.” Ocean Gate’s Mayor Paul J. Kennedy stated, "We've been losing beach year after year with the Nor'easters we get. So we came up with an idea that hopefully will work,” The Wall Street Journal reported. Read the court decision
Read the full story...
Reprinted courtesy of

Structural Failure of Precast-Concrete Span Sets Back Sydney Metro Job

January 04, 2018 — Chris Webb - Engineering News-Record
Originally Published by CDJ on February 23, 2017 A key component of Australia’s biggest public transport infrastructure project—Sydney’s $6.3-billion Metro North West—is the subject of a critical and detailed technical report describing how an elevated viaduct span failed at a stitch joint between two precast segments during construction last September. Project officials say the affected span, which did not suffer a progressive collapse, has since been removed and its replacement fast-tracked to avoid further delays. Little additional detail was provided. Read the court decision
Read the full story...
Reprinted courtesy of Chris Webb, ENR

Window Installer's Alleged Faulty Workmanship On Many Projects Constitutes Multiple Occurrences

May 10, 2017 — Tred R. Eyerly - Insurance Law Hawaii
Lawsuits filed for recovery due to the faulty design and installation of doors and windows by homeowners across the country were found to allege multiple occurrences. Pella Corp. v. Liberty Mut. Ins. Co., 2017 U.S. Dist. 53631 (C.D. Iowa March 31, 2017). The underlying lawsuits alleged that Pella Corporation's windows were defectively designed, manufactured, or installed, and allowed water intrusion to buildings that resulted in third-party property damage or personal injury. Pella sued Liberty Mutual for declaratory judgment and filed a motion for partial summary judgment to determine how many occurrences the underlying cases presented. Pella sought a determination that each of the 15 underlying cases presented one "occurrence" as the term was defined in the CGL policies issued by Liberty Mutual. Liberty Mutual argued that only three or four occurrences were presented, relying on common fact patterns. Pella argued that there were separate and distinct causes of different injuries and damage and thus, each underlying case constituted a separate occurrence. Liberty Mutual, on the other hand, highlighted language within the definition of "occurrence," which stated that an "occurrence" included "continuous or repeated exposure to the same general harmful conditions." The "substantially the same general harmful conditions" language dictated that the scope of "occurrence" be understood to be broad, such that various instances of damage-causing water intrusion in different times and places constituted "substantially the same general harmful conditions." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Toolbox Talk Series Recap – Best Practices for Productive Rule 26(f) Conferences on Discovery Plans

May 13, 2024 — Douglas J. Mackin - The Dispute Resolver
In the April 4, 2024 edition of Division 1’s Toolbox Talk Series, Julian Ackert and Steve Swart presented on how to prepare for and structure Rule 26(f) conferences to be more effective. While Swart and Ackert focused on the requirements of Federal Rule of Civil Procedure 26(f) regarding the requisite conference of the parties prior to a scheduling conference or scheduling order, it is worth noting that many states have substantially similar requirements. Rule 26(f) requires the parties to (i) discuss the nature and basis of their claims or defense; (ii) make or arrange for mandatory disclosures pursuant to Rule 26(a)(1); (iii) discuss issues about preserving discoverable information (including Electronically Stored Information – “ESI”); and (iv) develop a proposed discovery plan. Swart and Ackert’s presentation focused on the preservation of ESI and the proposed discovery plan. Read the court decision
Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES