Fairfield Connecticut Building Expert Directory

Constructive Changes – A Primer

October 02, 2018 — Jonathan R. Mayo - Smith Currie
A “constructive change” occurs when an owner action or omission not formally acknowledged by the owner to be a change in the contact’s scope of work forces the contractor to perform additional work. Constructive changes are not formal change orders, but informal changes that could have been ordered under a contract’s changes clause if the change had been recognized by the owner. The constructive change doctrine recognizes that being informally required to do extra work is similar to a formal change order and should be governed by similar principles. Thus, if it is found that a constructive change order did occur, the contractor may be entitled to payment for additional costs incurred, and an extension to the contract performance period. Constructive changes most often arise where there is a dispute regarding contract interpretation, defective plans and specifications, acceleration or suspension of work, interference or failure to cooperate with the contractor, misrepresentation or nondisclosure of superior knowledge or technical information, over inspection, or a delay in providing requested information crucial to the contractor’s ability to continue work. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan R. Mayo, Smith Currie
Mr. Mayo may be contacted at jrmayo@smithcurrie.com

Even Toilets Aren’t Safe as Hackers Target Home Devices

June 11, 2014 — Amy Thomson – Bloomberg
Come home to a hot iron and smoldering clothes this afternoon? Soon, it may not be a sign of forgetfulness, but rather evidence that you’ve been hacked. In coming years, your smartphone will be able to lock your house, turn on the air conditioning, check whether the milk is out of date, or even heat up your iron. Great news, except that all that convenience could also let criminals open your doors, spy on your family or drive your connected car to their lair. “As these technologies become more sophisticated, it opens up a broader spectrum of threats,” said Gunter Ollmann, chief technology officer of IOActive, a tech security firm in Seattle. A world of connected devices makes it possible “for the bad guys to have permanent entry into your household.” Read the court decision
Read the full story...
Reprinted courtesy of Amy Thomson, Bloomberg
Ms. Thomson may be contacted at athomson6@bloomberg.net

The Economic Loss Rule: From Where Does the Duty Arise?

January 24, 2022 — Taylor Hite - Colorado Construction Litigation
When entering a contract under Colorado law or attempting to enforce your rights when the other party breaches a contract, it is important to know and understand what rights you have and what claims you can bring or defenses you may have. One important consideration is Colorado’s version of the economic loss rule. The Colorado Supreme Court has issued several opinions clarifying the scope of the economic loss rule since it adopted the rule in 2000. The purpose of the economic loss rule is to maintain the boundary between contract law and tort law. In Colorado, the economic loss rule provides that a party suffering only economic loss from the breach of an express or implied contractual duty may not assert a tort claim for the breach without an independent duty of care under tort law. In most instances the economic loss rule will not bar intentional tort claims. The question becomes: from where does the duty arise? Is there an independent duty in tort law? Did the duty arise solely from the contract? Read the court decision
Read the full story...
Reprinted courtesy of Taylor Hite, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Hite may be contacted at Hite@hhmrlaw.com

Court Adopts Magistrate's Recommendation to Deny Insurer's Summary Judgment Motion in Collapse Case

June 06, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The district court accepted the magistrate's recommended ruling denying the insurer's motion for summary judgment on breach of contract and bad faith claims in a case involving collapse. Jang v. Liberty Mut. Fire Ins. Co., 2018 U.S. Dist. LEXIS 51880 (D. Conn. March 27, 2018). After purchase of their home, the insureds' inspector found large cracks in the foundation. Liberty denied coverage, contending that the basement wall was collapsing due to settling earth or movement. The insureds' expert later found the foundation had cracks from the oxidation of iron sulfide minerals in the foundation's concrete. The insureds sued for breach of contract, bad faith, and violations of the Connecticut Unfair Insurance Practice Act and the Unfair Trade Practices Act. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

A Closer Look at an HOA Board Member’s Duty to Homeowners

October 10, 2013 — Derek Lindenschmidt — Higgins, Hopkins, McLain & Roswell, LLC.
Whenever a homeowner association (HOA) starts thinking in terms of a construction defect lawsuit against its developer and/or builder, its board members will inevitably be confronted with the purported risk and liability to their homeowners if they do not pursue the alleged defects and deficiencies brought to their attention. Not surprisingly, the board members are on occasion led to believe that pursuing such claims is synonymous with acting in the homeowners’ “best interests.” Further—and unfortunately—board members often feel as though they will breach their obligation to the homeowners if theydon’t agree to proceed with such claims. Nevertheless, how well do we really know what the board members’ duty actually consists of, when it applies, and what potential liability exists for a board member’s breach of same? The answers might surprise you. Read the court decision
Read the full story...
Reprinted courtesy of Derek Lindenschmidt
Derek Lindenschmidt can be contacted at lindenschmidt@hhmrlaw.com

Happy Thanksgiving from CDJ

November 27, 2013 — CDJ STAFF
As Thanksgiving kicks off this holiday season, all of us at CDJ would like to gratefully acknowledge all of our valued readers and contributors in the construction defect and claims community. This November marks CDJ’s third anniversary. With your continued support we are looking forward to expanded coverage and features in our 4th year. Best wishes to you and yours this holiday season! Read the court decision
Read the full story...
Reprinted courtesy of

Fifth Circuit: Primary Insurer Relieved of Duty to Defend Without Release of Liability of Insured

March 02, 2020 — Bethany L. Barrese & Ashley McWilliams - Saxe Doernberger & Vita, P.C.
In Aggreko, LLC v. Chartis Specialty Ins. Co.,1 the Fifth Circuit affirmed a decision by the Texas District Court and held that a Covenant Not to Execute constituted a “settlement” sufficient to exhaust policy limits and terminate a primary insurer’s duty to defend. This case arose out of a wrongful death suit filed by the parents of James Brenek II (“Brenek”). In 2014, Brenek was fatally electrocuted by an electrically energized generator housing cabinet while performing work on a rig in Texas for Guichard Operating Company, LLC (“Guichard”), a Louisiana-based drilling subcontractor. Guichard had leased the generator from Aggreko, LLC (“Aggreko”). A rental agreement between Guichard and Aggreko required Guichard to maintain commercial general liability insurance during the lease period and list Aggreko and the rig owner, Rutherford Oil Corporation (“Rutherford”), as additional insureds under the policy. Guichard’s primary insurance carrier, The Gray Insurance Company (“Gray”), agreed to defend and indemnify Aggreko and Rutherford in the wrongful death suit. The Gray policy had a limit of $1,000,000, subject to a $50,000 self-insured retention. Reprinted courtesy of Bethany L. Barrese, Saxe Doernberger & Vita, P.C. and Ashley McWilliams, Saxe Doernberger & Vita, P.C. Ms. Barrese may be contacted at blb@sdvlaw.com Ms. McWilliams may be contacted at amw@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Eastern District of Pennsylvania Denies Bad Faith Claim in HO Policy Dispute

September 24, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Patrick Nugent of Saul Ewing LLP’s article in JD Supra Business Advisor, the Eastern District of Pennsylvania entered a summary judgment for the insurer on a statutory bad faith claim in a coverage dispute under a homeowner’s policy. The coverage dispute was over “the collapse of a wall in the plaintiffs’ home.” The Plaintiffs alleged that “the collapse resulted from excessive rainfall during a storm in March 2011.” However, Metropolitan Direct Property and Casualty Insurance Company’s engineer concluded that the collapse “resulted from long-term and on-going water infiltration attributable to poor maintenance.” Water damage had occurred a year prior to the collapse, but had not been repaired. In response, “Plaintiffs filed a complaint in Pennsylvania state court alleging breach of contract and statutory bad faith.” The court “determined that Metropolitan’s denial of benefits ‘was not only reasonable, but correct under the Policy language,’” and “ruled that the plaintiffs could not demonstrate that Metropolitan lacked a reasonable basis for denying their claim and entered summary judgment for Metropolitan on the plaintiffs’ bad faith claim.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES