Cambridge Massachusetts Building Expert Directory

Taylor Morrison v. Terracon and the Homeowner Protection Act of 2007

June 11, 2014 — Buck Mann – Colorado Construction Litigation
On January 30, 2014, the Colorado Court of Appeals decided the case of Taylor Morrison of Colorado, Inc. v. Bemas Construction, Inc. and Terracon Consultants, Inc. 2014WL323490. The case addressed a substantial issue of Colorado constitutional law, as well as a variety of procedural issues of potential importance to construction litigation attorneys. Of particular interest is the question of whether the provisions of the 2007 Homeowner Protection Act (“HPA”) are limited in application to contracts between residential homeowners and construction professionals, or whether they have broader application between commercial construction professional parties as well. As discussed below, the Court of Appeals stated that it would not answer the question, and then, separately, implied that the statute might only apply to homeowner transactions – with the resulting exclusion of commercial transactions. However, after its analysis, it left the actual decision of that issue to a future court in a later case. The factual background for the case involved claims of breach of a contract for soils engineering by Terracon Consultants, Inc. (“Terracon”) and negligent excavation work by Bemas Construction, Inc. (“Bemas”). Plaintiff was Taylor Morrison of Colorado (“Taylor Morrison”), the developer and general contractor for a residential subdivision called Homestead Hills. After it constructed many homes, Taylor Morrison began to receive complaints of cracking drywall resulting from foundation movement and it made repairs at significant expense. Taylor Morrison then filed suit against Terracon and Bemas in connection with their respective roles in the original construction. Read the court decision
Read the full story...
Reprinted courtesy of Buck Mann, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Mann may be contacted at mann@hhmrlaw.com

Changes to Pennsylvania Mechanic’s Lien Code

July 13, 2017 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome Jim Fullerton. Jim is the President of the law firm of Fullerton & Knowles, P.C., which has attorneys licensed in Virginia, Maryland, Pennsylvania, and the District of Columbia, is a Martindale Hubbell Peer Rated Lawyer AV® Preeminent.™ The firm represents owners, lenders, design professionals, suppliers, subcontractors, general contractors and other members of the real estate and construction industries, filing mechanic’s liens, surety bond and other construction claims across all of the states in the Mid Atlantic region. He also represents creditors in bankruptcy issues nationwide, particularly defense of bankruptcy preference claims; advises owners and lenders in real estate lending and acquisition transactions; on all real estate and construction law issues; contract formation and disputes. The firm’s Construction Law Survival Manual is well known and widely used by participants in the construction process. The 550 page manual provides valuable information about construction contract litigation, mechanic’s liens, payment bond claims, bankruptcy and credit management and contains over 30 commonly used contract forms. All of this information and recent construction law issues are constantly updated on the firm’s website. There are two changes to the Pennsylvania Mechanic’s Lien Code that became effective September 2014. First, residential properties built by an owner for their own residence will now have a defense of payment to subcontractor mechanic’s liens. This protects homeowners from mechanic’s liens if they have paid their general contractors in full. Second, construction loan open end mortgages will have priority over mechanic’s liens, as long as at least sixty per cent (60%) of the loan proceeds are used for construction costs. This change was pushed by Pennsylvania lenders in response to a recent court case. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

AB5, Dynamex, the ABC Standard, and their Effects on the Construction Industry

December 09, 2019 — Donald A. Velez - Smith Currie
Last year, we reported that the California Supreme Court in Dynamex Operations West, Inc. v. Superior Court (2018) 4 Cal.5th 903 (“Dynamex”) adopted a new, pro-employment standard (the “ABC Standard”), which presumes a worker is an employee versus an independent contractor under California wage orders and regulations. Assembly Bill 5 (“AB5”) has now been passed by the California Legislature and signed by Governor Newsom. Bill AB5 codifies the ABC Standard and brings increased costs, administrative duties, and legal risks for hiring parties on multiple fronts, including, but not limited to:

Payroll taxes;
Meals, breaks and overtime policies and enforcement and premium pay;
Benefits;
Leave and PTO policies, requirements and enforcement;
Wage order violations;
Labor Code violations and Private Attorney General Actions (“PAGA”) claims;
Unemployment insurance; and
Workers’ compensation coverage, claims, and premiums.

Read the court decision
Read the full story...
Reprinted courtesy of Donald A. Velez, Smith Currie
Mr. Velez may be contacted at davelez@smithcurrie.com

California Court of Appeal Finds Alleged Inadequate Defense by Insurer-Appointed Defense Counsel Does Not Trigger a Right to Independent Counsel

January 11, 2022 — Robert Dennison - Traub Lieberman
The California Second District Court of Appeal had occasion to examine an insurer’s duty to provide independent counsel (“Cumis counsel”) to its insured in a declaratory relief action entitled Nede Management, Inc. v. Aspen American Insurance Company. The action arose from a fire on a property covered by an insurance policy issued by Aspen American Ins. Co (“Aspen”). Aspen’s insureds were sued for wrongful death and negligence by tenants and squatters allegedly injured by the fire. Aspen defended three individual members of the family who owned the property and the family business, Nede Management, Inc. (“Nede”), which managed the property. The defense was subject to reservations of rights on the lack of an obligation to pay any judgment in excess of the $1 million policy limits and no coverage for punitive damages. Aspen appointed defense counsel to defend its insureds. The insureds sought independent counsel based on the assertion that defense counsel appointed by the insurer defended the action inadequately, failed to communicate an initial settlement demand within policy limits and failed to fully investigate the case. Aspen did provide Cumis counsel to Nede for a period but terminated the arrangement after revoking its reservation of rights to that entity. The underlying case eventually settled at no cost to the insureds. Read the court decision
Read the full story...
Reprinted courtesy of Robert Dennison, Traub Lieberman
Mr. Dennison may be contacted at rdennison@tlsslaw.com

Ten Years After Colorado’s Adverse Possession Amendment: a brief look backwards and forwards

September 25, 2018 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
In response to national outrage over an infamous adverse possession case in Boulder, Colorado, in which a lawyer and a judge intentionally took their neighbors’ undeveloped land through adverse possession, the Colorado legislature amended the state’s adverse possession statute (C.R.S. § 38-41-101) to make the claim significantly harder to prove. It did this because it believed “there were insufficient ‘obstacles’ to establishing a claim for adverse possession under the existing law.”[1] Effective July 1, 2008, the amendment created a heightened burden of proof, additional element requirements, and the possibility of a losing defendant recovering money from successful plaintiffs for the value of the land they took and the taxes the defendant had paid on that land. The Boulder case eventually settled, but the resulting statutory amendments have drastically changed the landscape of Colorado’s adverse possession law. Ten years later, this blog post takes a brief look at the amended statute, the impact it has had, and questions that have yet to be resolved. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Quick Note: Can a Party Disclaim Liability in their Contract to Fraud?

April 11, 2022 — David Adelstein - Florida Construction Legal Updates
It is possible for a party to contractually disclaim or otherwise foreclose liability to a fraud claim. However, let’s be honest. It can be done, but rarely is and would require very specific language to EXPLICITLY disclaim or foreclose such liability to a fraud claim. A recent case, discussed here, exemplifies this point where as-is language in a purchase-and-sale agreement was NOT specific to contractually foreclose or disclaim liability to a fraud claim. For a party to contractually waive a fraud claim, there needs to be an express waiver of liability for fraud that might have been made and that any fraudulent misrepresentation, if such fraud was committed, was disclaimed and would not destroy the validity of the parties’ contract. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Report to Congress Calls for Framework to Cut Post-Quake Recovery Time

February 01, 2021 — Bruce Buckley - Engineering News-Record
Engineers and government agencies along with model building code and standard developers should work together to create a national framework more focused on earthquake resilience and post-quake recovery time, according to a report delivered to Congress last week. While current seismic codes address life safety, the report says stakeholders should also consider re-occupancy and functional recovery time, taking into account the potential impacts to a community as a whole. Reprinted courtesy of Bruce Buckley, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES