New Jersey’s Governor Puts Construction Firms on Formal Notice of His Focus on Misclassification of Workers as Independent Contractors
May 24, 2018 —
Kevin J. O'Connor & Joseph M. Vento - Peckar & Abramson, P.C.We have written quite a bit about the mounting threat to employers, both nationally and locally, of claims of misclassification of workers as independent contractors rather than employees. New Jersey’s new Gov. Phil Murphy signed an executive order last week that establishes a task force on employee misclassification to punish contractors who commit fraud by classifying their employees as independent contractors.
In the words of Governor Murphy: “I am signing this order to crack down on unscrupulous contractors who commit 1099 fraud to exploit workers and rob them of family and medical leave and safe workplace protections that the law provides,” Murphy said. “The employer gives themselves an unfair business advantage and this practice is illegal. This is a question of enforcing what is already on the books.” He has vowed that any employer caught misclassifying workers will either be brought into compliance or put out of business. The task force will foster compliance with the law and conduct a comprehensive review of existing practices.
Reprinted courtesy of
Kevin J. O'Connor, Peckar & Abramson, P.C. and
Joseph M. Vento, Peckar & Abramson, P.C.
Mr. O'Connor may be contacted at koconnor@pecklaw.com
Mr. Vento may be contacted at jvento@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
WSHB Ranks No.10 in Law360’s Best of Law Firms for Women
April 28, 2016 —
Beverley BevenFlorez-CDJ STAFFLaw360 recently published the survey findings and listed the “100 Best Law Firms for Female Attorneys,” and
Wood Smith Henning & Berman LLP (WSHB) ranked tenth.
“I was thrilled to help spearhead a recruitment committee to attract and retain female lawyer talent,” Victoria Ersoff, the first named partner at WSHB, stated. “Long before it was fashionable, the leaders at WSHB recognized that in order to retain first-class lawyers, they need to provide them with opportunities to balance their work and personal life.”
Janice Michaels, managing partner of WSHB’s Las Vegas office, praised the firm for treating all attorneys equally: “Female lawyers at WSHB are on equal footing with their male counterparts, whether it’s trial experience, mentoring or expanding professional opportunities. It is a great environment to learn and grow without the impediment of a glass-ceiling.”
Read the court decisionRead the full story...Reprinted courtesy of
Resolve to Say “No” This Year
January 26, 2016 —
Christopher G. Hill – Construction Law MusingsWe hear all of the time how to “get to ‘yes'” and how doing so can lead to more business and of course more business leads to more profits. Purely logical, right? Without construction owners with work for general contractors to perform and general contractors hiring subcontractors to perform that work, construction grinds to a halt and clients and friends of mine in the construction industry don’t make money. For this to happen, “yes” has to happen more often than not. So, why the title of this post?
Chalk it up to spending much if not all of my time as a construction attorney either anticipating or dealing with the Murphy’s Law ruled nature of the construction world or to the “Monday morning quarterback” nature of my profession, but I see numerous instances where not taking the job or signing the bad contract would have led to a better outcome than performing the work. What do I mean by this? I mean that as a construction company (particularly one that is lower down the “payment chain” and therefore less in control of the flow of money), you need to carefully evaluate not only the contract presented, but whether you get a good feeling about the party with whom you are contracting.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
NY Appellate Court Holds Common Interest Privilege Applies to Parties to a Merger
January 07, 2015 —
Jay Shapiro, Lori S. Smith and Brittney Edwards – White and Williams LLPThe common interest privilege is a doctrine that operates to maintain the confidentiality of communications between parties and counsel that have aligned interests. It is designed to encourage the free flow of information between these parties, and has historically been utilized primarily in the context of litigation. However, in Ambac Assurance Corp., et al. v. Countrywide Home Loans, Inc., et al., the New York Supreme Court, Appellate Division, First Department recently expanded the common interest privilege by holding that it is applicable in transactional contexts. 2014 WL 6803006, No. 651612/10 (1st Dep’t 2014). The Ambac court defined the common interest doctrine as “a limited exception to waiver of the attorney-client privilege” when a third party is present during a communication between an attorney and his or her client. The doctrine shields such communications from disclosure when they are (1) protected by the attorney client privilege and (2) “made for the purpose of furthering a legal interest or strategy common to the parties.”
Until Ambac, New York courts touched on, but never squarely addressed, whether a third requirement must be satisfied before the common interest doctrine can be invoked: “that the communication must affect pending or reasonably anticipated litigation.” The Ambac court addressed and rejected this purported third requirement while reversing the decision of the trial court which found that defendant Bank of America failed “to cite any New York case that applied the common-interest doctrine outside of either joint-representation of two parties by one attorney, or where parties reasonably anticipated litigation.”
Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys
Jay Shapiro,
Lori S. Smith and
Brittney Edwards
Mr. Shapiro may be contacted at shapiroj@whiteandwilliams.com
Ms. Smith may be contacted at smithl@whiteandwilliams.com
Ms. Edwards may be contacted at edwardsb@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Ninth Circuit Resolves Federal-State Court Split Regarding Whether 'Latent' Defects Discovered After Duration of Warranty Period are Actionable under California's Lemon Law Statute
December 17, 2015 —
Laura C. Williams & R. Bryan Martin – Haight Brown & Bonesteel LLPIn Daniel v. Ford Motor Company (filed 12/02/15), the Ninth Circuit resolved a federal and state court split on the issue of whether consumers can sustain a breach of implied warranty claim under California’s Song Beverly Consumer Warranty Act (aka the “lemon law” statute) for “latent” defects discovered after the warranty period has expired. Answering this question in the affirmative, the Ninth Circuit followed the holding in the California state appellate decision of Mexia v. Rinker Boat Co. 95 Cal.Rptr.3d 285 (2009), which definitively determined there is nothing in California’s lemon law that requires a consumer to discover a latent defect during the duration of the warranty.
The underlying class action lawsuit was brought in federal district court by purchasers of Ford Focus vehicles. The plaintiffs alleged Ford was aware of, but failed to disclose, a rear suspension defect in the Focus that resulted in premature tire wear which can cause decreased vehicle control, catastrophic tire failure and drifting on wet or snowy roads. The plaintiffs alleged a number of claims including violations of California’s Song Beverly Consumer Warranty Act and Magnuson Moss Warranty Act. Ford successfully moved for summary judgment on all claims prompting an appeal.
Reprinted courtesy of
Laura C. Williams, Haight Brown & Bonesteel LLP and
R. Bryan Martin, Haight Brown & Bonesteel LLP
Ms. Williams may be contacted at lwilliams@hbblaw.com
Mr. Martin may be contacted at bmartin@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
House of the Week: Spanish Dream Home on California's Riviera
July 30, 2014 —
Emily Heffter – BloombergFamous clients of renowned Los Angeles architect Richard Landry are not known for their restraint.
The Brentwood estate he designed for Tom Brady and Gisele Bundchen has a moat and just sold to Dr. Dre for $40 million. Michael Jackson died in a home Landry designed (a rental), and he has designed luxurious mansions for Wayne Gretzky, Michael Bolton, Mark Wahlberg and Kenny G.
Still, homeowner Lorna Auerbach did something unique when Landry started designing her dream home in Pacific Palisades: She flew him to Spain, with her, for 10 days.
Read the court decisionRead the full story...Reprinted courtesy of
Emily Heffter, Bloomberg
Federal Court Opinion Has Huge Impact on the Construction Industry
July 06, 2020 —
Wally Zimolong - Supplemental ConditionsThe United States District Court for the Eastern District of Pennsylvania in Philadelphia recently issued an opinion that should get the attention of any contractor or subcontractor performing work on a federal funded construction project. In U.S. ex rel IBEW Local 98 v. The Fairfield Company, the federal court held that a contractor on a SEPTA project could be held liable under the False Claims Act for failing to pay its workers under the Davis Bacon Act. The court found that liability was appropriate under the FCA even through the contractor did not knowingly violate the Davis Bacon Act. The court awarded the plaintiff over $1,000,000 in damages and an additional over $1,000,000 in attorneys fees.
An Extremely Brief Primer on the FCA
A full discussion of the FCA is beyond the realm of this blog post and you could write a book on FCA cases. But in a nutshell, the FCA prohibits a contractor from knowingly submitting a claim for payment to the federal government (or an entity receiving funding from the federal government, like SEPTA) that is false. Importantly, knowingly does not equal actual knowledge of the falsity of the claim. Rather, “reckless disregard of the truth or falsity” of the submission is sufficient. As explained below, this standard played an important role in the court’s decision and should give contractors performing work on federally funded projects pause.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
