Fairfield Connecticut Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Repairs to Hurricane-damaged Sanibel Causeway Completed in 105 Days

February 12, 2024 — Marigo Farr - Engineering News-Record
Permanent repairs to the roadway portion of the Sanibel Causeway are substantially complete one year and four months after more than 6,000 Sanibel Island residents lost access to the mainland in the wake of Hurricane Ian. The Superior Construction and The De Moya Group joint-venture team, responsible for the work, say that all travel lanes are now permanently open to the island off Florida's southwest coast near Fort Myers. Reprinted courtesy of Marigo Farr, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

COVID-19 and Mutual Responsibility Clauses

June 01, 2020 — Joseph M. Leone - ConsensusDocs
As everyone knows, there is a tremendous amount of uncertainty in the construction industry due to the COVID-19 pandemic. Schedules, productivity, safety processes, and seemingly everything else are being affected. In these difficult times, most contractors are making every effort to work together to solve the problems caused by COVID-19. But what happens when differences arise between project owners, contractors, and subcontractors as to the effect of COVID-19 on a project? One party may want to continue pushing the schedule, others may want to slow down, or, more likely, not be able to keep up with the original schedule because of some reason related to COVID-19. As between a prime contractor and a subcontractor, a mutual responsibility clause can provide some clarity or, unfortunately, depending on how the subcontract is written, confusion. Almost all subcontracts have a clause which flows down the prime contractor’s obligations on a project to the subcontractor as applicable to the subcontractor’s work. Known as “flow-down” clauses, this clause works in one direction; obligations of the prime contractor “flow-down” to the Subcontractor. A mutual responsibility clause, in essence, works in both directions. The subcontractor is required to perform its obligations consistent with the prime contractor’s obligations to the owner and the subcontractor is granted the same rights against the prime contractor which the prime contractor has against the owner. Obligations flow down and rights flow up. The rights and obligations flowing through the prime contractor include, the obligation to perform the work in accordance with the plans and specifications, the obligation to meet the schedule constraints in the prime agreement, and the right to extensions of time and change orders to the extent the prime contractor obtains the same. Read the court decision
Read the full story...
Reprinted courtesy of Joseph M. Leone, Drewry Simmons Vornehm, LLP
Mr. Leone may be contacted at jleone@dsvlaw.com

Duty to Defend Bodily Injury Evolving Over Many Policy Periods Prorated in Louisiana

November 17, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Louisiana Supreme Court held that the duty to defend in long latency disease cases should be prorated between the insurer and insured when the policies cover for only a portion of the time in which the exposure occurred. Arceneaux v. Amstar Corp., 2016 La. LEXIS 1675 (La. Sept. 7, 2016). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Canada Housing Surprises Again With July Starts Increase

August 13, 2014 — Greg Quinn – Bloomberg
Canada’s housing starts beat economist predictions for a fourth straight month in July, led by the most single-family home projects in almost two years. The pace of work on new homes rose 0.7 percent to a seasonally adjusted annual pace of 200,098 units, the fastest since October, from a revised 198,665 in June, Ottawa-based Canada Mortgage & Housing Corp. reported today. Economists forecast a decline to 193,000, according to the median of 18 responses in a Bloomberg News survey. Most economists and the central bank have predicted that rising prices and near-record debt loads would curb demand for housing. Instead, home resales, prices and starts have climbed after a tough winter, as mortgage rates remain near record lows. Read the court decision
Read the full story...
Reprinted courtesy of Greg Quinn, Bloomberg
Mr. Quinn may be contacted at gquinn1@bloomberg.net

Even with LEED, Clear Specifications and Proper Documentation are Necessary

December 31, 2014 — Christopher G. Hill – Construction Law Musings
A recent lawsuit filed in California over the proper documentation necessary for LEED certification (discussed in detail at the Green Building Law Update) emphasizes the fact that, no matter how detailed the LEED certification process seems to be, a mere reference to that process or a certain level of LEED certification is far from sufficient to assure a smooth project. While I don’t practice in California and don’t have any idea how the lawsuit will turn out, the fact that there is litigation over even the basics of LEED like documentation shows the clear necessity to make sure that your specifications and contract documents are specific and clear from the beginning. Owners, General Contractors and Subcontractors need to remember this fact at all times and particularly in situations where, like in the instance of LEED, the “specification” seems to be set out by others. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Mold Due to Construction Defects May Temporarily Close Fire Station

October 25, 2013 — CDJ STAFF
Fire Station 5 in Chino, California is about to undergo mold remediation. Ruben Martinez, the city’s Public Works Director, expects the station to be closed during remediation. “We’d like to get the firemen out of there so there isn’t any potential infection or worker’s compensation issues,” he said. However, Fire Department Captain Steve Harrison did not think the station needed to be closed. “We are adamant the station stays staffed while the remediation work is completed.” The mold came about due to problems the station has had with roof leaks since its opening in 1999. The current set of repairs will cost between $12,000 and $25,000, and the city is discussing matters with its insurer to determine who will pay for the repairs. It’ won’t be the original contractor, as the building is past the 10-year limit for construction defect claims. Even if a claim were possible, the contractor who built the building is bankrupt. Read the court decision
Read the full story...
Reprinted courtesy of

Wisconsin Supreme Court Holds that Subrogation Waiver Does Not Violate Statute Prohibiting Limitation on Tort Liability in Construction Contracts

October 21, 2019 — Gus Sara - The Subrogation Strategist
In Rural Mut. Ins. Co. v. Lester Bldgs., LLC 2019 WI 70, 2019 Wisc. LEXIS 272, the Supreme Court of Wisconsin considered whether a subrogation waiver clause in a construction contract between the defendant and the plaintiff’s insured violated Wisconsin statute § 895.447, which prohibits limitations of tort liability in construction contracts. The Supreme Court affirmed the lower court’s decision that the waiver clause did not violate the statute because it merely shifted the responsibility for the payment of damages to the defendant’s insurance company. The waiver clause did not limit or eliminate the defendant’s tort liability. This case establishes that while § 895.447 prohibits construction contracts from limiting tort liability, a subrogation waiver clause that merely shifts responsibility for the payment of damages from a tortfeasor to an insurer does not violate the statute and, thus, is enforceable. In Rural Mutual, the plaintiff’s insured, Jim Herman, Inc. (Herman), entered into a contract with Lester Buildings, LLC (Lester) to design and construct a barn on Herman’s property. The contract included a provision that stated the following: Both parties waive all rights against each other and any of their respective contractors, subcontractors and suppliers of any tier and any design professional engaged with respect to the Project, for recovery of any damages caused by casualty of other perils to the extent covered by property insurance applicable to the Work or the Project, except such rights as they have to the proceeds of such property insurance and to the extent necessary to recover amounts relating to deductibles of self-insured retentions applicable to insured losses. . . . This waiver of subrogation shall be effective notwithstanding allegations of fault, negligence, or indemnity obligation of any party seeking the benefit or production [sic] of such waiver. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES