Fairfield Connecticut Building Expert Directory

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Update to Washington State Covid-19 Guidance

November 23, 2020 — Brett M. Hill - Ahlers Cressman & Sleight PLLC
Yesterday, November 15, 2020, Governor Inslee announced modifications to the current COVID-19 restrictions in response to the current rise in cases across Washington State. There are no additional restrictions on construction at this time. However, during the Governor’s press conference yesterday, he did indicate that positive cases were increasing on construction sites, and that they would be tracking the statistics over the next 2 – 3 weeks – to see if additional restrictions would be necessary for construction sites in the future. Additionally, the construction industry group is meeting with the Governor’s office today, November 16, 2020, and we will keep you informed of any changes as a result of that meeting. Unless otherwise specifically noted, the modifications take effect at 12:01 a.m., Tuesday, November 17, 2020. All modifications to existing prohibitions set forth herein shall expire at 11:59 p.m., Monday, December 14, 2020, unless otherwise extended. If an activity is not listed below, currently existing guidance shall continue to apply. If current guidance is more restrictive than the below listed restrictions, the most restrictive guidance shall apply. These below modifications do not apply to education (including but not limited to K-12, higher education, trade and vocational schools), childcare, health care, and courts and judicial branch-related proceedings, all of which are exempt from the modifications and shall continue to follow current guidance. Terms used in this proclamation have the same definitions used in the Safe Start Washington Phased Reopening County-by-County Plan. Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers Cressman Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com

Construction Problem Halts Wind Power Park

November 13, 2013 — CDJ STAFF
Engineers have yet to determine why a blade on a wind turbine broke at a wind power plant in Michigan, but as part of their investigation they are halting work on the final 10 turbines. The already completed 60 turbines have been taken out of operation. As a result, the Echo Wind Park is no longer generating power. Scott Simons, a spokesperson for the project, said “we’re not going to put anyone or anything at risk until we get to the bottom of this.” However, Dennis Buda, the project manager, attributed the broken blade to a manufacturing defect. Construction was planned to end in November. Read the court decision
Read the full story...
Reprinted courtesy of

New Notary Language For Mechanics Lien Releases and Stop Payment Notice Releases

January 21, 2015 — Garret Murai – California Construction Law Blog
Thanks to Scott Wolfe, Jr. over at ZLien for bringing this to my attention: Effective January 1, 2015, the notary language required for Certificates of Acknowledgment – used by notaries for mechanics lien releases and stop payment notice releases in California – now require the following new wording to appear at the top of the notary certificate in a box:

A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Is the Removal and Replacement of Nonconforming Work Economically Wasteful?

September 19, 2022 — David Adelstein - Florida Construction Legal Updates
There are times a contractor installs the wrong material or system contrary to the plans and specifications. A nonconformity. The owner wants the already-installed material or system to be replaced in conformity with the plans and specifications. However, what was installed is functionally equivalent to what the plans and specifications required and would be cost prohibitive, i.e., economically wasteful. If the contractor elects to remove and replace the nonconforming work, it may seek a change order because it is economically wasteful. Or, the contractor may refuse (typically, not the best approach) in furtherance of taking on the fight based on the economic wastefulness associated with the removal and replacement. A recent case, David Boland, Inc. v. U.S., 2022 WL 3440349 (Fed.Cl. 2022), talks about this exaction situation and the economic waste doctrine. This is an important doctrine for contractors to understand when faced with a similar predicament. Here, a contractor was hired by the government to construct a wastewater collection system that was to be owned and operated by a private company. The contractor’s work was going to be incorporated into a larger sewer system that the private company already operated. The contractor was required to install sewer manholes reinforced with steel in accordance with an ASTM standard. The manholes could be rejected if they did not conform to the ASTM standard. Compliance with this ASTM standard was also required by the private company’s construction protocol for the infrastructure, which was incorporated into the contractor’s contract with the government. The contractor was required to strictly comply with the contract. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

What Contractors Can Do to Address Rising Material Costs

August 23, 2021 — Garret Murai - California Construction Law Blog
From lumber to used cars to pastrami sandwiches, prices are rising. This past month, at a town hall meeting in Cincinnati, Ohio, President Biden acknowledged that inflation was increasing, responding to a question from a restaurant owner about labor shortages, “I think your business and the tourist business is really going to be in a bind for a little while.” Although construction companies typically don’t work in the same small margins that restaurants do, labor shortages and material price increases have nevertheless impacted the construction industry. According to a recent report by Cumming, the cost of construction materials from lumber to steel to gypsum have gone up over the last 12 months, in some cases nearly double: For contractors entering into construction contracts and those performing work under existing contracts, the increasing cost of materials and shortage of labor creates challenges, some of which can be addressed through contractual provisions and the framework of those contracts. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Lewis Brisbois Ranks Among Top 25 Firms on NLJ’s 2021 Women in Law Scorecard

July 25, 2021 — Jana Lubert - Lewis Brisbois
Lewis Brisbois has been ranked among the top 25 law firms included in the National Law Journal's (NLJ) 2021 Women in Law Scorecard (Women’s Scorecard), moving up from 27th place to 23rd place this year. In addition, of the top 25 firms in the Women’s Scorecard, Lewis Brisbois had the highest number of female minority partners. The Women’s Scorecard is produced as part of the annual NLJ 500 firm head count report, and only the largest 350 firms are eligible to be included on the scorecard. A firm’s score is determined by adding the percentage of female attorneys and percentage of female partners. Diversity staffing counts were based on a firm’s average full-time attorneys in 2020, excluding contract and temporary attorneys. Read the court decision
Read the full story...
Reprinted courtesy of Jana Lubert, Lewis Brisbois
Ms. Lubert may be contacted at Jana.Lubert@lewisbrisbois.com

California Construction Bill Dies in Committee

July 21, 2011 — CDJ STAFF

AB 20, which its sponsor, Linda Halderman (R-Fresno), stated would discourage class action lawsuits against builders and protect jobs in the construction industry, has died in committee. Although the Business Journal reported in June that Haldeman was promoting the bill during a talk in her district and the bill is still on her web site, the California Assembly reports that the bill failed in committee on March 15, 2011. It is possible that the bill could be reconsidered, but the Assembly Committee on Judiciary sees the bill as responding to issues quieted by SB 800 which gives builders the right to repair alleged defects before any suit can be filed.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES