Contract, Breach of Contract, and Material Breach of Contract
July 05, 2023 —
Wendy Rosenstein - Ahlers Cressman & Sleight PLLCAt its most basic level, a contract is an agreement to make a trade. Parties to a contract agree to perform a specific action on the condition that the other side also performs a specific action. For instance, you and a Girl Scout could create a contract in which the Girl Scout agrees to deliver one box of cookies and you agree to pay her $6.00. In this case, both you and the Girl Scout have obligations under the contract.
If the Girl Scout failed to send you the cookies, what do you do? You send her a note, in writing, telling her that you expect the cookies (or assurance that you will get the cookies) within a certain amount of time—this is notice and the opportunity to cure. Most contracts have a “notice and opportunity to cure” provision, which essentially says that one side must give the other side an opportunity to fix breaches before canceling the contract. Once a party receives a notice to cure, they must either rectify the problem or offer adequate assurances that they will fix the problem. Generally, the party has only a short period of time to address the breach.
Read the court decisionRead the full story...Reprinted courtesy of
Wendy Rosenstein, Ahlers Cressman & Sleight PLLC
Property Damage to Insured's Own Work is Not Covered
May 27, 2019 —
Tred R. Eyerly - Insurance Law HawaiiThe Michigan Court of Appeals found there was no coverage for a lawsuit filed against the insureds for faulty workmanship. Skanska United States Bldg. v M.A.P. Mech. Contrs., 2019 Mich App. LEXIS 529 (Mich. Ct. App. March 19, 2019).
Contractor Skanska United States Building was the construction manager on a renovation project for the medical center. The heating and cooling portion of the project was subcontracted to M.A.P. Mechanical Contractors (MAP). MAP had a CGL policy from Amerisure Insurance Company. Skanska and the medical center were named as additional insureds on the policy.
After installation of the steam boiler and related piping, it was discovered that the heating system did not function property. Skanska discovered that MAP had installed some of the expansion joints backward, causing damage to concrete, steel, and heating system. The medical center sent a demand to MAP. Skanska performed the repairs and replaced the damaged property. Skanska then submitted a claim to Amerisure, which was denied.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
California Appeals Court Remands Fine in Late Completion Case
November 18, 2011 —
CDJ STAFFThe California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.
The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”
Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”
Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”
The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”
The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.
The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Only Two Weeks Until BHA’s Texas MCLE Seminar in San Antonio
April 28, 2014 —
Beverley BevenFlorez-CDJ STAFFThere are just two weeks remaining to sign up for Bert L. Howe & Associate’s inaugural Texas MCLE seminar, “THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION.” This activity will be presented on Friday, May 9th at noon in BHA’s San Antonio offices, located at 17806 IH 10, Suite 300, San Antonio, TX 78256. There is no cost for attendance at this seminar and lunch will be provided.
This course has been approved for Minimum Continuing Legal Education credit by the State Bar of Texas Committee on MCLE in the amount of 1.0 credit hours, of which 0.0 credit hours will apply to legal ethics/professional responsibility credit. The seminar will be presented by Don MacGregor, general contractor and project manager.
Water intrusion through doors, windows and roofing systems, as well as soil and foundation-related movement, and the resultant damage associated therewith, are the triggering effects for the vast majority of homeowner complaints today and serve as the basis for most residential construction defect litigation. The graphic and animation-supported workshop/lecture activity will focus on the residential construction process from site preparation through occupancy, an examination of associated damages most often encountered when investigating construction defect claims, and the inter-relationships between the developer, general contractor, sub trades and design professionals. Typical plaintiff homeowner/HOA expert allegations will be examined in connection with those building components most frequently associated with construction defect and claims litigation.
The workshop will examine:
* Typical construction materials, and terminology associated with residential construction
* The installation process and sequencing of major construction elements, including interrelationship with other building assemblies
* The parties (subcontractors) typically associated with major construction assemblies and components
* An analysis of exposure/allocation to responsible parties.
Attendance at THE RESIDENTIAL CONSTRUCTION PROCESS & CONSTRUCTION DEFECT LITIGATION seminar will provide the attendee with:
* A greater understanding of the terms and conditions encountered when dealing with common construction defect issues
* A greater understanding of contractual scopes of work encountered when reviewing construction contract documents
* The ability to identify, both quickly and accurately, potentially responsible parties
* An understanding of damages most often associated with construction defects, as well as a greater ability to identify conditions triggering coverage
Course #: 901290467 / Sponsor #: 14152.
To register for the event, please email Don MacGregor at dmac@berthowe.com. If you have any questions, please feel free to contact Don at (210) 540-9017 (office) or (714) 713-4956 (cell).
Read the court decisionRead the full story...Reprinted courtesy of
Bridge Disaster - Italy’s Moment of Truth
September 10, 2018 —
Flavia Krause-Jackson & Kathleen Hunter - BloombergThe tragedy of modern Italy, so beautiful yet so decrepit, can be told through its bridges.
Italians love to point to the Romans as the first engineers – the country boasts some of the world’s oldest viaducts. It’s a source of national pride that blinded the nation to the reality of today, where decades of neglect led to a moment of reckoning.
The collapse of the Morandi bridge in Genoa, leaving 43 dead, was followed by the usual mud-slinging, including within a tenuous ruling coalition and more importantly, to soul-searching. Meant to last 100 years, the bridge was hated more than loved – everyone who crossed it felt unsafe.
Reprinted courtesy of
Flavia Krause-Jackson, Bloomberg and
Kathleen Hunter, Bloomberg
Read the court decisionRead the full story...Reprinted courtesy of
OSHA’s COVID-19 Emergency Temporary Standard Is in Flux
December 06, 2021 —
Megan E. Baroni & Jonathan H. Schaefer - Construction ExecutiveOn Friday, Nov. 5, 2021, Occupational Safety and Health Administration’s COVID-19 Vaccination and Testing Emergency Temporary Standard was issued, with most requirements set to go into effect on Dec. 5. The ETS applies to employers with a total of 100 or more employees company-wide. Employers covered by the ETS would be required to develop, implement and enforce a mandatory vaccination policy, subject to limited exemptions, or allow unvaccinated employees to test regularly and be subject to a mask policy, among other associated recordkeeping, reporting and training requirements.
Almost immediately, the ETS was hit with a number of legal challenges in various courts across the country. On November 6, just a day after the ETS was issued, the U.S. Circuit Court of Appeals for the Fifth Circuit issued an order staying the implementation of the ETS until further notice. The Court’s order was not a final ruling on the validity of the ETS but has halted implementation of the ETS, at least for the time being. Other legal challenges are already in process, further complicating the issue of if and when the ETS will become effective.
As of November 2021, the ETS is on hold, at least temporarily. That could change any day and the ETS could be back in effect, in whole or in part, or permanently halted. The legal challenges to the ETS are unlikely to end, or diminish, until the Supreme Court has weighed in, making for a few uncertain months ahead.
Reprinted courtesy of
Megan E. Baroni and Jonathan H. Schaefer, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Ms. Baroni may be contacted at mbaroni@rc.com
Mr. Schaefer may be contacted at jschaefer@rc.com
Read the court decisionRead the full story...Reprinted courtesy of
Flying Solo: How it Helps My Construction Clients
February 18, 2015 —
Christopher G. Hill – Construction Law MusingsTwo and a half years ago, on July 1, 2010, I opened my solo practice. At the time, I really had no insight into how big this change would be from a positive, customer service, perspective.
When I made the decision to go solo with my construction law practice, I knew I wanted to have flexibility to serve my client base of contractors and subcontractors in Virginia. I started some flat rate billing and had the ability to take cases that were below the dollar value of those that my old firm was willing to take. I also knew that I would be a master of my own destiny for better or worse (and it has been much more of the former than the latter).
What I did not realize is the impact that owning my own business would have on my perspective. I have always believed that, in most cases where construction disputes occur, mediation is a great option. However mediation only occurs with conflict. For any business, whether construction or otherwise, conflict creates expenses that were not likely to have been anticipated or built in to the budget. Litigation is not something that most businesses can, or should, build into their operating budgets.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Law Office of Christopher G. Hill, PCMr. Hill may be contacted at
chrisghill@constructionlawva.com
Florida's New Pre-Suit Notification Requirement: Retroactive or Prospective Application?
February 05, 2024 —
Holly A. Rice - Saxe Doernberger & Vita, P.C.Florida’s newly formed Sixth District Court of Appeal (“Sixth DCA”) recently certified conflict with Florida’s Fourth District Court of Appeal on the issue of retroactive application of the pre-suit notice requirement contained in Florida Statute §627.70152.1 Earlier this year, the Fourth District Court of Appeal (“Fourth DCA”) held that the pre-suit notice provision applies retroactively, meaning, it applies to all suits filed after July 1, 2021, regardless when the insurance policy was issued.2 The Sixth DCA, in
Hughes v. Universal Property & Casualty Insurance Company,3 directly rejected the Fourth DCA’s interpretation and instead found a retroactive application of the pre-suit notice to be unconstitutional under Florida law. Prior to the Fourth DCA’s ruling, most trial courts had found no retroactive application for the pre-suit notice provision.4
In August 2021, shortly after Florida Statutes Section 627.70152 went into effect on July 1, 2021, Rebecca Hughes (“Hughes”) sued Universal Property & Casualty Insurance Company (“Universal Property”) for breach of contract after Universal Property denied her insurance claim. Hughes did not file a pre-suit notice under Section 627.70152. Universal Property moved to dismiss based on Hughes’ failure to file the pre-suit notice, arguing that the pre-suit notice requirement applies to all lawsuits filed after July 1, 2021, even if the claimant’s insurance policy was issued before the statute’s effective date. The trial court agreed with Universal Property and dismissed the lawsuit.
Read the court decisionRead the full story...Reprinted courtesy of
Holly A. Rice, Saxe Doernberger & Vita, P.C.Ms. Rice may be contacted at
HRice@sdvlaw.com
