Construction Delays: Which Method Should Be Used to Calculate Delay?
July 25, 2021 —
David Adelstein - Florida Construction Legal UpdatesIf you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay.
There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:
- As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
How Will Artificial Intelligence Impact Construction Litigation?
September 12, 2023 —
Patrick McKnight - The Dispute ResolverIn the first half of 2023, artificial intelligence (“AI”) caught the public’s imagination. Attorneys have not been immune from the fever-pitch of commentary regarding the possible applications. While early adopters have had varying degrees of success, commentators have proposed various potential impacts on construction projects and disputes. This article discusses potential areas where AI can assist in preventing and resolving disputes from the pre-bid stage through project completion and close-out.
What is AI?
Artificial intelligence entered the popular zeitgeist accompanied by both optimistic and pessimistic predictions about the future. Internet searches on AI exploded in December 2022, reflecting a rapid and widespread public interest in the topic. The term “AI” itself is often loosely used to refer to a machine or computer software with the ability to conduct machine learning.[1] Whereas “automation” is the simple process of computing inputs, artificial intelligence refers to the ability to learn without additional programming from a human being. Now, increased computing power is finally helping some of the potential applications of this technology come into focus. Nonetheless, artificial intelligence is still maturing and is subject to “hallucinations” where the technology essentially generates erroneous nonsense.
Read the court decisionRead the full story...Reprinted courtesy of
Patrick McKnight, Fox Rothschild LLPMr. McKnight may be contacted at
pmcknight@foxrothschild.com
Submitting Claims on Government Projects Can Be Tricky
March 19, 2015 —
Craig Martin – Construction Contractor AdvisorThe Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start.
K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
$24 Million Verdict Against Material Supplier Overturned Where Plaintiff Failed to Prove Supplier’s Negligence or Breach of Contract Caused an SB800 Violation
March 16, 2017 —
Jon A. Turigliatto, Esq. & Chelsea L. Zwart, Esq. – Chapman Glucksman Dean Roeb & Barger BulletinAcqua Vista Homeowners Assoc. v. MWL Inc. (2017) 2017 WL 371379
COURT OF APPEAL EXTENDS GREYSTONE HOMES, INC. v. MIDTEC, INC., HOLDING THAT CIVIL CODE §936 CREATES A NEGLIGENCE STANDARD FOR CLAIMS AGAINST MATERIAL SUPPLIERS BROUGHT UNDER SB800.
The Fourth District California Court of Appeal recently published its decision Acqua Vista Homeowners Assoc. v. MWI, Inc. (2017) 2017 WL 371379, holding that claims against a material supplier under SB800 (Civil Code §895 and §936) require proof that the SB800 violation was caused by the supplier's negligence or breach of contract.
Civil Code §936 states in relevant part, that it applies "to general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals to the extent that the general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals caused, in whole or in part, a violation of a particular standard as the result of a negligent act or omission or a breach of contract .... [T]he negligence standard in this section does not apply to any general contractor, subcontractor, material supplier, individual product manufacturer, or design professional with respect to claims for which strict liability would apply."
Acqua Vista Homeowners Association (the "HOA") sued MWI, a supplier of Chinese pipe used in the construction of the Acqua Vista condominium development. The HOA's complaint asserted a single cause of action for violation of SB800 standards, and alleged that defective cast iron pipe was used throughout the building. After trial, the trial court entered a judgment against MWI in the amount of $23,955,796.28, reflecting the jury's finding that MWI was 92% responsible for the HOA's damages.
MWI filed a motion for a directed verdict and motion for judgment notwithstanding the verdict on the grounds that the HOA had failed to present any evidence that MWI had caused an SB800 violation as a result of its negligence or breach of contract, and had therefore failed to prove negligence and causation as required by SB800, citing to Greystone Homes, Inc. v. Midtec, Inc.(2008) 168 Cal.App.4th 1194. The trial court denied both motions, relying on the last sentence of Civil Code §936, which states in part, "[T]he negligence standard in this section does not apply to any ... material supplier ... with respect to claims for which strict liability would apply."
The Court of Appeal reversed and ordered the trial court to enter judgment in favor of MWI. The Court of Appeal relied on the legislative history of S8800 and Greystone, which held that the first sentence of Civil Code §936 contains an "explicit adoption of a negligence standard" for S8800 claims against product manufacturers. The Court of Appeal reasoned that since §936 treats product manufacturers and material suppliers identically, the holding of Greystone must equally apply to material suppliers.
Because the complaint did not state a common law cause of action for strict liability, the HOA was required to prove that the damages were caused by MWI' s negligence or breach of contract. Although, the Court of Appeal found that while the HOA's evidence may have supported a finding that the manufacturer of the leaking pipes was negligent, the HOA had not provided any evidence that MWI, the supplier, had failed to supply the type of pipe ordered, acted unreasonably in failing to detect any manufacturing defects present in the pipe, or damaged it during transportation. Accordingly, the HOA could not prove that the alleged S8800 violation was caused, in whole or in part, by MWI' s negligence, omission, or breach of contract.
In light of the decision, homeowner and associations that allege only violations of SB800 standards without asserting a common law cause of action for strict liability cannot prevail by simply producing evidence of a violation, and are required to prove that violation was caused by the negligent act or omission, or breach of contract, of the defendant contractor, material supplier, and/or product manufacturer.
Reprinted courtesy of
Jon A. Turigliatto, Esq, Chapman Glucksman Dean Roeb & Barger and
Chelsea L. Zwart, Esq., Chapman Glucksman Dean Roeb & Barger
Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com
Ms. Zwart may be contacted at czwart@cgdrblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Application of Set-Off When Determining Prevailing Party for Purposes of Attorney’s Fees
February 22, 2021 —
David Adelstein - Florida Construction Legal UpdatesThe recent opinion from the Second District Court of Appeal in Hayward Baker, Inc. v. Westfield Ins. Co., 2020 WL 7767859 (2nd DCA 2020) demonstrates that the significant issues test for determining the prevailing party for purposes of attorney’s fees applies to disputes involving payment bonds under Florida’s Lien Law (Florida Statutes Chapter 713). The
significant issues test is more or less a subjective test where the party that is deemed to have prevailed on the significant issues in the case is the prevailing party for purposes of attorney’s fees in the case. A trial court has discretion to determine the prevailing party which will not be disturbed absent an appellate court finding the trial court abused that discretion. This significant issues test is an important consideration so that parties understand just because money ends up going their way does not necessarily mean they prevailed on the significant issues in the case. It could mean that. But it may not based on the claims and moneys involved in the dispute.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
In One of the First Civil Jury Trials to Proceed Live in Los Angeles Superior Court During Covid, Aneta Freeman Successfully Prevailed on Behalf of our Client and Obtained a Directed Verdict and Non-Suit
July 05, 2021 —
Aneta B. Freeman – Chapman Glucksman Dean & Roeb News AlertIn one of the first civil jury trials to proceed live in Los Angeles Superior Court during Covid, Aneta Freeman obtained a rare directed verdict and nonsuit in a complex, high exposure action, after seven days of trial. The dismissal was obtained after the parties rested after the liability phase of the bifurcated trial.
Ms. Freeman represented a general contractor in an action in which Plaintiff alleged that the general contractor and the County of Los Angeles (which was dismissed earlier on statutory immunity grounds) created a dangerous condition when they allegedly allowed mosquitos to breed in 2015 during construction at a flood retention basin in Marina Del Rey.
Plaintiff contracted West Nile Virus, and subsequently developed myasthenia gravis and a myriad of other conditions and ailments. Plaintiff relied heavily on a 2015 report from the Los Angeles West Vector Control District which suggested that the construction was the source of mosquitos which resulted in a “cluster” of West Nile Virus cases in the Marina Del Rey and surrounding areas.
In pretrial motions, Ms. Freeman successfully excluded that report, opinion testimony from the vector control former executive director, narrowed the scope of plaintiff’s entomologist testimony, and excluded Brad Avrit from testifying for the Plaintiff on construction standard of care.
The matter proceeded with a stipulated a 10 person jury, and all participants socially distanced and masked throughout the trial. Witnesses appeared live, with the exception of Plaintiff’s entomologist, portions of whose video deposition were played.
Following seven days of trial after both parties rested, Judge Mark Young granted the general contractor’s nonsuit and also, in the alternative, a directed a verdict for our client.
Plaintiff had demanded $10,000,000 of the County and the general contractor globally prior to trial, and $5,000,000 from the general contractor. The general contractor issued two CCP 998s, which were ignored by Plaintiff.
Read the court decisionRead the full story...Reprinted courtesy of
Aneta B. Freeman, Chapman Glucksman Dean & RoebMs. Freeman may be contacted at
afreeman@cgdrlaw.com
Bond Principal Necessary on a Mechanic’s Lien Claim
October 23, 2018 —
Christopher G. Hill - Construction Law MusingsAs anyone that reads this construction law blog knows, mechanic’s liens are a big part of the Virginia landscape for a construction attorney like me.
One option for dealing with a mechanic’s lien here in Virginia that we have not discussed but so often is the ability to “bond off” a lien. In short, the Virginia statute allows a party to essentially substitute a bond valued at a court set multiple of the principal amount of the mechanic’s lien for the memorandum. In exchange, the lien is released of record. Any enforcement action can still proceed with security for the claimant and the property owner feeling better about things because there will be no lien on the title to the land.
In many ways this process provides an easier path to resolution for both owner and claimant. First of all, the claimant does not have to deal with a bank or other interest holders in the property (though a recent case discussed below reminds us that certain other parties are necessary). Second of all, the owner does not have the cloud on the title of a mechanic’s lien that may have been filed by a subcontractor over which he has no control.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Amazon Hits Pause on $2.5B HQ2 Project in Arlington, Va.
March 27, 2023 —
Jim Parsons - Engineering News-RecordAmazon is tapping the brakes on its $2.5-billion HQ2 second headquarters project in Arlington County, Va., announcing an indefinite delay to the start of the program’s 2.8-million-sq-ft second phase, known as PenPlace.
Reprinted courtesy of
Jim Parsons, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
