COLUMBUS OHIO BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

---

Building Recovery Comes to Las Vegas, Provides Relief

October 01, 2013 — CDJ STAFF
The recession hit the Las Vegas area hard, and so residents are now relieved as the economy recovers. During the recession, the area lost more than 70,000 construction jobs. Those who remained still found it hard t find work. But KVVU, Las Vegas, spoke with Fredy Salguero, a construction worker who still finds getting a steady paycheck a challenge. “You work like one, two, three days a week, and before you were able to work six or seven.” The signs are good that better times will be coming for Mr. Salguero. Housing prices are up 30 percent and there are $7 million of commercial projects on the Las Vegas Strip. With the nation’s highest unemployment rate, Nevada needs the help. Read the court decision
Read the full story...
Reprinted courtesy of

---

Google, Environmentalists and University Push Methane-Leak Detection

December 21, 2016 — Mary B. Powers – Engineering News-Record
National Grid, which serves New York, Massachusetts and Rhode Island, is set to be the second U.S. natural-gas utility to use technology advanced by Google Earth, the Environmental Defense Fund (EDF) and Colorado State University to boost large-scale methane-leak detection. It is launching a $3-billion effort to replace gas pipelines in New York. The technology uses cutting-edge spatial analytics methods and methane sensors, specially fitted to Google Street View cars, to identify leaks and accurately measure the amount of methane escaping. Read the court decision
Read the full story...
Reprinted courtesy of Mary B. Powers, Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

---

Veterans Day – Thank You for Your Service

December 05, 2022 — Travis Colburn - Ahlers Cressman & Sleight
Happy Veterans Day[1] to our country’s servicemembers past and present! ACS would like to express its deepest gratitude and respect in saying thank you to those that have served, or are serving, in our armed forces. It undoubtedly takes incredible bravery, fortitude, integrity, respect, and a commitment to our country’s evolving ideals. Some of those same attributes that are necessary for service are also well-geared toward a post-military career in construction. As some already know, Veterans have unique construction contracting opportunities at both the state and federal level. The following is a high-level overview of the process and opportunities for veterans who are not aware or who are considering a career in construction. There are federal and state level opportunities for Veteran-owned businesses. The initial step in accessing federal and state level contracting opportunities is different for each but begins with certification/verification. At the federal level, effective January 1, 2023, all responsibilities for the verification of Veteran-owned small businesses (“ VSOB”) will transfer from the Department of Veterans Affairs to the Small Business Administration.[2] Verification is the process that establishes eligibility for access to Veteran-specific benefits, including certain government contracts and the purchase of surplus government property, by confirming that VSOBs and service-disabled Veteran-owned small businesses (“SDVOSB”) are operated by Veterans.[3] Read the court decision
Read the full story...
Reprinted courtesy of Travis Colburn, Ahlers Cressman & Sleight
Mr. Colburn may be contacted at travis.colburn@acslawyers.com

---

New Jersey’s Governor Puts Construction Firms on Formal Notice of His Focus on Misclassification of Workers as Independent Contractors

May 24, 2018 — Kevin J. O'Connor & Joseph M. Vento - Peckar & Abramson, P.C.
We have written quite a bit about the mounting threat to employers, both nationally and locally, of claims of misclassification of workers as independent contractors rather than employees. New Jersey’s new Gov. Phil Murphy signed an executive order last week that establishes a task force on employee misclassification to punish contractors who commit fraud by classifying their employees as independent contractors. In the words of Governor Murphy: “I am signing this order to crack down on unscrupulous contractors who commit 1099 fraud to exploit workers and rob them of family and medical leave and safe workplace protections that the law provides,” Murphy said. “The employer gives themselves an unfair business advantage and this practice is illegal. This is a question of enforcing what is already on the books.” He has vowed that any employer caught misclassifying workers will either be brought into compliance or put out of business. The task force will foster compliance with the law and conduct a comprehensive review of existing practices. Reprinted courtesy of Kevin J. O'Connor, Peckar & Abramson, P.C. and Joseph M. Vento, Peckar & Abramson, P.C. Mr. O'Connor may be contacted at koconnor@pecklaw.com Mr. Vento may be contacted at jvento@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

EEOC Issues Anti-Harassment Guidance To Construction-Industry Employers

July 22, 2024 — Christopher Kelleher & Andrew Scroggins - The Construction Seyt
Seyfarth Synopsis: The Equal Employment Opportunity Commission (“EEOC”) has issued guidance tailored to the construction industry regarding compliance with anti-harassment laws. This lines up with our prediction in early 2024 that the EEOC had put the construction industry squarely in its sights. The guidance is important for construction-industry leaders and employers to understand to prevent and remedy workplace harassment, and to avoid potential harassment liability. On June 18, 2024, the EEOC issued its Promising Practices for Preventing Harassment in the Construction Industry. This guidance provides key recommendations that construction-industry leaders and employers should consider implementing to prevent and address harassment in the workplace, and avoid being the target of the EEOC’s enforcement efforts. The guidance is intended to supplement the EEOC’s Strategic Enforcement Plan (“SEP”) for fiscal years 2024-2028, which provides direction on the EEOC’s current objectives, principles, and enforcement efforts – among them, increasing diversity in the construction industry and remedying harassment. (We’ve written previously about the proposed and final SEP.) Reprinted courtesy of Christopher Kelleher, Seyfarth and Andrew Scroggins, Seyfarth Mr. Kelleher may be contacted at ckelleher@seyfarth.com Mr. Scroggins may be contacted at ascroggins@seyfarth.com Read the court decision
Read the full story...
Reprinted courtesy of

---

One Insurer's Settlement with Insured Does Not Bar Contribution Claim by Other Insurers

October 30, 2013 — Tred Eyerly — Insurance Law Hawaii
The New Jersey Supreme Court held that one insurer could seek contribution from another insurer who settled with and secured a release from the insured. Potomac Ins. Co. v. Pennsylvania Manufacturers' Ass'n Ins. Co., 2013 N.J. LEXIS 847 (N.J. Sept. 16, 2013) The township of Evesham retained Roland Aristone, Inc. to be its general contractor for construction of a new middle school. After completion of the school, the roof leaked. Evesham sued Aristone for the construction defects. Aristone tendered to its various CGL carriers. Two insurers, Selective Way Insurance Company and OneBeacon Insurance Company, defended. Two others, Pennsylvania Manufacturers' Insurance Company (PMA) and Royal Insurance Company, denied coverage. Aristone sued PMA and Royal, and ultimately settled with PMA for $150,000 in exchange for Aristone's release from all claims, including claims for defense fees and costs. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---

Iowa Court Holds Defective Work Performed by Insured's Subcontractor Constitutes an "Occurrence"

July 28, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Iowa Supreme Court held that property damage caused by a subcontractor's defective work was an "occurrence." Nat'l Sur. Corp. v. Westlake Invs., LLC, 2016 Iowa LEXIS 71 (Iowa June 10, 2016). In 2002, the insureds, the developers and general contractor, began construction on an apartment complex. While the complex was still under construction, it was purchased by Westlake Investments, LLC. During construction, numerous problems surfaced, including visible water penetration issues in several buildings. In February 2008, Westlake sued the insureds, seeking to recover lost profits, repair costs, and other damages under tort and contract theories. Arch Insurance Group defended under the primary policy. A settlement was eventually reached whereby a consent judgment for $15,600,000 was entered against the insureds and in favor of Westlake. Arch contributed its policy limits of $1,000,000 to the settlement. Other third party defendants contributed $1,737,500, leaving $12,762,500 of the judgment unsatisfied. The insureds assigned rights under their excess policy with National Surety Corporation (NSC) to Westlake. NSC's policy was a following-form policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---