Fairfield Connecticut Building Expert Directory

Contractors and Force Majeure: Contractual Protection from Hurricanes and Severe Weather

October 11, 2017 — Christopher G. Hill - Construction Law Musings
This week’s Guest Post Friday here at Musings welcomes back Clay Olsen. Clay is is an attorney at Harper Whitwell PLLC. The firm is located in Mississippi and South Carolina where they routinely represent the interests of construction. This season is not special as hurricanes are a part of life on the east coast and gulf shores. From New York to Louisiana, just about every state has seen massive property loss from hurricanes during the past ten years. We often see harsh outcomes for those on the coast living in finished homes. What happens to the unfinished and current projects awaiting completion? If you’re building on the coast, take a look at all of the following risk aversion mechanisms:

Builders Risk Insurance is necessary as is Coverage for named storms. Be sure to review the “excluded perils” or speak to your agent as hurricane coverage best not be omitted.

Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Offices of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Real Estate & Construction News Roundup (12/4/24) – Highest Rate of Office Conversions, Lending Caps for Fannie Mae and Freddie Mac and Affordability Challenges for Homebuyers

December 23, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, infrastructure-related ballot initiatives, U.S. Green Building Council’s success stories, support for sustainable building, and more!

2024 is expected to see the highest rate of office conversions since CBRE began tracking them in 2016. (Nish Amarnath, SmartCities Dive)
The Federal Housing Finance Agency has established lending caps of $73 billion each for Fannie Mae and Freddie Mac, allowing them to purchase a total of up to $146 billion in multifamily loans in 2025. (Leslie Shaver, Multifamily Dive)
A number of infrastructure-related initiatives with the potential to impact facilities managers were on the ballot during the 2024 U.S. presidential election. (Joe Burns, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Coverage Doomed for Failing Obtain Insurer's Consent for Settlement

January 22, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Fourth Circuit affirmed the district court's determination that there was no duty to indemnify after the insured settled without consent of the insurer. Perini/Tompkins Joint Venture v. ACE American Ins. Co., 2013 U.S. App. LEXIS 24865 (4th Cir. Dec. 16, 2013). The insured, a joint venture, was hired as manager for the construction of a $900 million hotel and convention center. OCIP and excess policies were obtained through ACE. The project was also insured by a Builders Risk Policy through Factory Mutual Insurance Company. During construction, a rod eroded, causing the atrium to collapse. Substantial property damage occurred and the completion of the project was delayed for several months. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Los Angeles Warehousing Mecca Halts Expansion Just as Needs Soar

September 05, 2022 — Ngai Yeung & Augusta Saraiva - Bloomberg
Communities in the Inland Empire, the US’s logistics mecca east of Los Angeles, are suspending new warehousing projects to examine the impact from decades of pollution -- putting the industry under pressure when it’s needed most. This week, the city council for Pomona is set to vote on extending a temporary halt on industrial developments to study the environmental impact, while the nearby city of Norco will decide whether to establish a 45-day moratorium. The actions follow similar freezes by a handful of Southern California cities like Riverside, Colton, Chino and Redlands over the past several years. Meanwhile, a state-level bill -- which is a long-shot to pass in the legislature but gives a reading of the mood -- proposes banning large industrial construction within 1,000 feet of non-industrial areas such as schools, homes and playgrounds in Riverside and San Bernardino counties, an area that spans 27,000 square miles. Reprinted courtesy of Ngai Yeung, Bloomberg and Augusta Saraiva, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

California Supreme Court Allows Claim Under Unfair Competition Statute To Proceed

October 16, 2013 — Tred Eyerly — Insurance Law Hawaii
The California Supreme Court determined that insurance practices violating the state's Unfair Insurance Practices Act (UIPA) could support a claim under the state's unfair competition law (UCL). Zhang v. Superior Court, 57 Cal. 4th 353 (2013). Zhang purchased a CGL policy from California Capital Insurance Company. She sued California Capital in a dispute over coverage for fire damage to her commercial property. The complaint included causes of action for breach of contract, breach of the implied covenant of good faith and fair dealing, and violation of the UCL. In her UCL claim, Zhang alleged that California Capital had "engaged in unfair, deceptive, untrue, and/or misleading advertising" by promising to provide timely coverage in the event of a compensable loss, when it had no intention of paying the true value of the insureds' covered claims. Zhang specifically alleged unreasonable delays causing deterioration of her property; withholding of policy benefits; refusal to consider cost estimates; misinforming her as to the right to an appraisal; and falsely telling her mortgage holder that she did not intend to repair the property, resulting in foreclosure proceedings. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Drug Company Provides Cure for Development Woes

November 18, 2011 — CDJ STAFF

Vertex Pharmaceuticals is poised to become the holder of Boston’s biggest commercial lease, paying $72.5 million for 1.1 million square feet on Boston’s waterfront. Vertex’s new buildings are still under construction, but the plans have spurred other development in the Fan Pier area, according to the New York Times. The Times quotes Mary A. Burke, a senior economist at the Federal Reserve Bank of Boston that the Vertex project gives “a big push” to the “momentum for economic growth.”

The Fallon Company is building Vertex’s new laboratory and office space. They are separately planning to build a high-rise with 150 luxury condominium units. According to Joseph Fallon, the chief executive and president of the Fallon Company, there is already a waiting list of 50 buyers for the condominiums.

Across the street from the Vertex site, a group including Morgan Stanley and Boston Global Investors is planning a 23-block mixed use project that would include 1.2 million square feet of retail space. Additionally, the New England Development and the Hanover Group is building a 356-unit apartment building at the adjacent Pier 4.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Oregon agreement to procure insurance, anti-indemnity statute, and self-insured retention

March 05, 2011 — CDCoverage.com

In Continental Casualty Ins. Co. v. Zurich American Ins. Co., No. 09-35484 (9th Cir. Oct. 28, 2010), general contractor TCR was sued by an employee of subcontractor Safeway for bodily injuries suffered while working on the project. In the subcontract, Safeway agreed to procure primary insurance providing coverage for TCR for liability arising out of Safeway’s negligence. Safeway’s CGL policy included a self-insured retention that had to be satisfied before the insurer had a duty to defend. TCR filed suit against Safeway alleging that

Read the full story...

Reprinted courtesy of CDCoverage.com