Seattle Washington Building Expert Directory

Liquidated Damages Clause Not Enforced

October 02, 2023 — David R. Cook Jr. - Autry, Hall & Cook, LLP
A liquidated-damages clause was not enforced in a recent case before the Georgia Court of Appeals. The clause did not contain standard provisions that would normally allow a trial court to enforce the clause as written. As a result, the trial court looked beyond the contract to determine whether the City satisfied the requirements for enforcement of the liquidated-damages clause. Below are the relevant excerpts. City of Brookhaven v. Multiplex, LLC, A23A0843, 2023 WL 4779591 (Ga. Ct. App. July 27, 2023) Here, the Contract provides for “Liquidated Damages at the rate of $1,000.00 per calendar day” in the last paragraph of the Scope of Work addendum. The Contract lacks, however, any language indicating that the liquidated damages were not intended to be a penalty. See Fuqua Const. Co. v. Pillar Dev., Inc., 293 Ga. App. 462, 466, 667 S.E.2d 633 (2008) (rejecting use of parol evidence where the parties “explicitly agreed” in “unambiguous contract language” that the liquidated damages were not a penalty). Absent such language, the court can look to parol evidence in the record to determine the effect the provision was intended to have. See J.P. Carey Enterprises, 361 Ga. App. at 391-392 (1) (b), 864 S.E.2d 588 (looking to “extrinsic evidence” such as emails, documents, and deposition testimony to determine whether the damages provision at issue was a penalty); see also Gwinnett Clinic, Ltd. v. Boaten, 340 Ga. App. 598, 602-603, 798 S.E.2d 110 (2017) (“Shah’s testimony also suggested that one purpose of the liquidated damages provision was to deter employees from breaching the agreement”). Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Wilke Fleury Attorneys Recognized in “The Best Lawyers in America” & “Best Lawyers: One’s to Watch” 2024 Editions

September 06, 2023 — Wilke Fleury LLP
Congratulations 2024 Best Lawyers & Ones to Watch wf | Wilke Fleury David A. Frenznick, Kathryne E. Baldwin Daniel L. Egan, Adriana C. Cervantes, Jason G. Eldred Wilke Fleury is extremely proud to have two attorneys recognized in The Best Lawyers in America and three attorneys recognized in the Best Lawyers: Ones to Watch in America! Best Lawyers has been regarded by lawyers and the public for more than 40 years as the most credible measure of legal integrity and distinction in the United States. Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Parking Garage Collapse May Be Due to Construction Defect

November 07, 2012 — CDJ STAFF
A parking garage under construction at the Doral campus of Miami Dade College collapsed on October 9. Experts state that the collapse may have been due to errors in the construction process, either in the fabrication of the pre-cast components or in their assembly. The Bradenton Herald quotes Mark Santos, a structural engineer, who “would look at erection procedures – that’s probably the one question to ask first.” During the failure, floors separated from the south wall of the structure. The contractor responsible for the garage, Ajax Building Corp, said there was “no indication of any potential cause.” Read the court decision
Read the full story...
Reprinted courtesy of

Taylor Morrison Home Corp’ New San Jose Development

October 15, 2014 — Beverley BevenFlorez-CDJ STAFF
The Silicon Valley Business Journal reported that Taylor Morrison Home Corp has made the “biggest land acquisition so far in San Jose” after acquiring “an 8-acre chunk of dirt in the developing Montecito Vista area where it has plans to build out 184 townhomes.” The developer “paid about $32.5 million, or roughly $176,600 per buildable unit, for the land, according to public tax records,” according to the Silicon Valley Business Journal. Construction is scheduled to begin November of 2015 and models should be ready by April of 2016. Read the court decision
Read the full story...
Reprinted courtesy of

Back Posting with Thoughts on Lien Waivers

May 20, 2015 — Christopher G. Hill – Construction Law Musings
After a week of being unable to post due to the rigors of my solo construction practice, I’m back on the blogging train. For those of you that missed my new musings this past week, I hope that you had a chance to look through some of the past Guest Post Friday posts for some good stuff to read. During the course of my busy week last week, a question came up regarding the mechanic’s lien waivers that commercial construction companies routinely execute as part of the payment process. The waiver forms vary, but each essentially states that in exchange for payment the payee, whether a subcontractor or supplier (or even general contractor) waives its future rights to record a mechanic’s lien for the work that is covered by the payment received. Most if not all of these forms further require a certification that the funds paid will either be used to pay suppliers or that suppliers have already been paid. This general description is not the reason for this post. As is always the case in the Commonwealth of Virginia where the contract is king and a court is unlikely to reinterpret any written contractual document, the devil is in how that waiver is worded. Some waivers are worded in such a way that they essentially require a payee to certify receipt of the funds prior to payment being received. These same forms require the same pre-payment certification that all suppliers and subcontractors of the payee have already been paid. In short they require a payee to both place complete trust in the payor that the check will be paid and that the check will not bounce while in many cases (often with an unstated “wink and nod”) claiming payment was already made when all know the likelihood is that it has not. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Drones, Googleplexes and Hyperloops

March 05, 2015 — Garret Murai – California Construction Law Blog
I don’t know if it’s just me, or if there has been a lot of news lately about technology and construction:

Although flying in the face of some bad press recently, the use of drones in construction. And we’re talking about more than just cameras with propellers.

Battle of the (tech) Titans, as Google battles it out with the likes of LinkedIn and Microsoft for development rights in Mountain View, California for its futuristic new Googleplex. And we’re talking about more than just cameras with propellers.. And Google is only the most recent tech titan with development plans. Facebook’s Frank Gehry-designed campus expansion is in the works and Apple’s “spaceship” campus has already broken ground. We’ve come a long way since the HP garage in Palo Alto, baby!

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

New Rule Prohibits Use of Funds For Certain DoD Construction and Infrastructure Programs and Projects

May 30, 2018 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
Recently, our colleagues Glenn Sweatt and Alex Ginsberg published their Client Alert titled DFARS Clause Blocks Funding for Unsafe Projects in Afghanistan, Recently published regulation implements the FY17 NDAA to prohibit use of funds for DoD construction and infrastructure programs and projects in Afghanistan that cannot be safely accessed by U.S. Government personnel. Takeaways include:

New rule prevents Government contracting officers from funding projects that are not able to be safely accessed by Government civilian or military personnel, as these may pose an increased risk of fraud, corruption or waste, or lack efficient oversight.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Not So Universal Design Fails (guest post)

April 28, 2016 — Melissa Dewey Brumback – Construction Law in North Carolina
Today we have a guest post from Carla Williams, who works in customer service for the Williams Brothers Corporation of America. Carla humorously brings light to a serious problem– the intent behind ADA and Universal Design is very often not met with poorly-thought out applications in the real world. Enjoy, and feel free to leave a comment for Carla below. Universal design is the idea that architecture should be inherently accessible to everyone. The growing number of architects adopting universal design is great news for people with accessibility needs. Instead of having separate entrances and walkways to make a building accessible, universal design allows people of all abilities to move together. Unfortunately, many buildings are stuck back in 1990 right after the Americans with Disabilities Act was made law. These buildings may be technically “accessible,” but they aren’t spaces people with accessibility needs can maneuver very easily. Until all building designers come to understand and implement the beauty and functionality of universal design, the world is left with less than ideal accessibility. “Less than ideal” is a bit of an understatement. Many times full-on “accessibility fails” take place. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett PLLC
Ms. Brumback may be contacted at mbrumback@rl-law.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES