FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Watch Your Step – Playing Golf on an Outdoor Course Necessarily Encompasses Risk of Encountering Irregularities in the Ground Surface

May 08, 2023 — Kaitlyn A. Jensen & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
On April 27, 2023, the First District Court of Appeal issued an opinion in Walter Wellsfry, et al. v. Ocean Colony Partners, LLC (A165175, April 27, 2023) affirming summary judgment for a golf course owner on the grounds that the injured golfer’s lawsuit was barred by the primary assumption of risk doctrine. In doing so, the Court of Appeal found that outdoor golfers assume the risks associated with the topographical features of the course, including the risk of stepping on an inconspicuous tree root. Recreational golfer Walter Wellsfry was walking from a tee box back to his golf cart when he allegedly stepped on a small tree root concealed by grass, causing him to fall into his golf cart in immediate pain. The ground consisted of mixed terrain, including a combination of grass, dirt, and sand. The tree root was estimated to be approximately 1.5 inches high by 1.5 inches wide. Believing he may have only sprained an ankle, Wellsfry continued the course and reported the incident to management. He later sued the golf course owner Ocean Colony Partners for negligence, claiming that the tree root was a “hidden obstruction” creating an unreasonable risk of harm to anyone who traversed the area. Reprinted courtesy of Kaitlyn A. Jensen, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Mr. Jensen may be contacted at kjensen@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Costs Absorb Two Big Hits This Quarter

July 14, 2016 — Tim Grogan and Bruce Buckley – Engineering News-Record
Two big events hit construction this quarter: Brexit—that is, the British vote to leave the European Union— and the U.S government’s decision to increase tariff duties on Chinese cold-rolled flat steel by 522%. However, neither will have much of an impact on domestic construction costs, according to ENR’s sources. Reprinted courtesy of Tim Grogan, ENR and Bruce Buckley, ENR Mr. Grogan may be contacted at grogant@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

No Coverage for Property Damage That is Limited to Work Completed by Subcontractor

April 25, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The issue before the 11th Circuit was whether, under Florida law, a general contractor had coverage for a property damage claim limited to the defective work performed by a subcontractor, and not affecting any other portion of the project. The court found no coverage in Amerisure Mut. Ins. Co. v. Auchter Co., 2012 U.S. App. LEXIS 5412 (11th Cir. March 15, 2012).



Amelia Island Company contracted with Auchter Company, a general contractor, for construction of an inn and conference room. Auchter subcontracted with Register Contracting Company to install the Inn’s roof. Pursuant to the Florida Building Code, installation of the roof required that it be able to withstand 110 m.p.h. winds.



Register completed installing the roof tiles in January 1998. Beginning in 2002, the tiles began dislodging from the roof. During the 2004 hurricane season, three hurricanes caused more tiles to come off the roof. Some of these tiles hit other tiles, cracking them.



In 2006, the parties went to arbitration over the costs of repairs for the roof.



Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

EPA Threatens Cut in California's Federal Highway Funds

October 14, 2019 — Tom Ichniowski - Engineering News-Record
In a new salvo against the state of California, the U.S. Environmental Protection Agency has threatened to restrict uses for some federal highway aid to the state unless it moves to withdraw what EPA terms “backlogged and unapprovable" plans that outline steps the state would take to reduce pollution and meet Clean Air Act standards. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

---

Congratulations Devin Brunson on His Promotion to Partner!

April 26, 2021 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is very proud to announce Devin Brunson has been promoted to the position of partner with the firm! Mr. Brunson came to BWB&O from another civil litigation firm and helped start the Denver, Colorado office along with partners Lucian Greco, John Toohey and Peter Brown. He has taken on a significant leadership role within the firm over the past several years and has been integral in growing the office to its current footprint. He is licensed to practice law in Colorado, District of Colorado, and in the U.S. District Court. His practice is focused in the areas of civil and business litigation, construction litigation, and employment law. Mr. Brunson has a diverse practice background that includes complex civil litigation and intellectual property disputes and has had the privilege of representing business owners, contractors, corporate executives, and professional athletes during the course of his career. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Drones Used Despite Uncertain Legal Consequences

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
Francis Manchisi of Wilson Elser discussed how several industries—including construction—are using unmanned aircraft systems or unmanned aerial vehicles, commonly referred to as drones, and are either exploiting legal loopholes or ignoring laws altogether. The Federal Aviation Administration (FAA) has recently released a Notice of Proposed Rulemaking, which is now in a 60-day “notice and comment” period that is open to the public. Once that period ends, the FAA will consider the comments before putting the rules into law. According to Manchisi, the proposed rules include:

• Unmanned aircraft must weigh less than 55 lbs. (25 kg).
• Unmanned aircraft must remain within visual line of sight (VLOS) of the operator or visual observer.
• Maximum altitude is 500 feet above ground level.
• Preflight inspection by the operator is required.
• Operators are required to obtain an unmanned aircraft operator certificate with a sUAS rating from the FAA.

Read the court decision
Read the full story...
Reprinted courtesy of

---

Angela Cooner Receives Prestigious ASA State Advocate Award

April 12, 2021 — Angela Cooner - Lewis Brisbois
Phoenix Partner Angela L. Cooner recently received the American Subcontractors Association, Inc. (ASA) 2020 State Advocate award during ASA’s Virtual Awards Presentation, which took place on February 25. ASA selected Ms. Cooner as the recipient of this honor based upon the significant time that she spent and value she added to subcontractor advocacy in Arizona over the last year. In nominating Ms. Cooner for this award, ASA of Arizona stated, “Angie’s dedication and track record are second to none. However, it is her leadership in managing the recent merger between the Arizona State Contractors’ Coalition (AZSCC) and Arizonans for Fair Contracting (AFC) where she has distinguished herself most notably.” Moreover, ASA explained that Ms. Cooner’s dedication “has allowed ASA of Arizona to renegotiate a new contract with a government affairs firm that helped secure victory on a critical proportional liability bill and begin the upcoming legislative session on the right foot.” According to ASA, Ms. Cooner has donated the equivalent of $120,000 in billable hours to the organization through her work for AFC and as legal counsel for ASA of Arizona’s Board of Directors. Read the court decision
Read the full story...
Reprinted courtesy of Angela Cooner, Lewis Brisbois
Ms. Cooner may be contacted at Angela.Cooner@lewisbrisbois.com

---