FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Prompt Payment More Likely on Residential Construction Jobs Than Commercial or Public Jobs

May 02, 2022 — Levelset
NEW ORLEANS, May 02, 2022 (GLOBE NEWSWIRE) -- In construction, no line of work guarantees prompt and in-full payments, but contractors working on residential jobs say their rate of prompt payment is significantly better than commercial or public jobs, according to the 2022 Levelset Cash Flow and Payment Report. However, the report revealed that residential construction jobs require increased communication to improve the chance of prompt payment when compared to commercial or public jobs. Contractors working on residential projects are more than twice as likely as those working on public projects to report getting paid within 30 days, with residential construction contractors saying they are paid in 30 days or less 48% of the time and public construction contractors saying that only happens 21% of the time. Significantly slow payments of 60 days or more are three times more likely on public construction projects than on residential construction projects, according to the survey participants. Residential contractors say it happens rarely, just 6% of the time, while public project contractors say it happens nearly one out of five times (18%). For more information about the report and a detailed summary of findings, please visit: www.levelset.com/survey About Levelset Levelset's mission is to empower contractors to always get what they earn. Levelset's products help millions in the construction industry each year to make payment paperwork and compliance easier, get cash faster, monitor the risk on jobs and contractors, and better understand payment processes and rules. The results are faster payments, access to capital, and fewer surprises. Founded in 2012, Levelset is based in New Orleans, Louisiana, with offices in Austin, Texas, and Cairo, Egypt, and is owned and operated by Procore Technologies, Inc. For more information, visit www.levelset.com. Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Law: Unexpected, Fascinating, Bizarre

April 25, 2012 — CDJ STAFF

Guy Randles offers an amusing set of odd construction law cases in the Daily Journal of Commerce, which he describes as “the unexpected, the fascinating and even the bizarre.” He noted that in one case “a whistleblower claimed he was terminated for reporting to the owner that the contractor’s painters had not applied the required coating thickness.” The whistleblower was the project manager and “was responsible for ensuring the proper coating thickness.”



A less amusing case was that of an architect who was arrested for manslaughter. Gerard Baker “told investigators that the considered the fireplaces to be merely decorative.” Randles notes that “the mansion’s fireplaces were built of wood framing and lined with combustible drywall.” Further, a “gas fireplace even vented into the house’s interior.” Building officials called the house “a death trap.” According to the LA police chief this may be the only case in which building defects lead to a manslaughter charge.



Read the full story…

 Read the court decision
Read the full story...
Reprinted courtesy of

---

AFL-CIO Joins in $10 Billion Infrastructure Plan

June 30, 2011 — CDJ STAFF

The AFL-CIO has announced plans to generate up to $10 billion in funding for infrastructure development, training construction workers, and making buildings more energy efficient, pledging $20 million to retrofit buildings. Bloomberg News reports that union officials made the announcement in Chicago at the Clinton Global Initiative, releasing a statement from Richard Trumka, president of the union, “we, at the AFL-CIO, believe that together, with our partners in business and government, we can profitably invest significant resources to make America more competitive and energy efficient.” A foot injury prevented Mr. Trumka from attending the event.



The statement also quoted Mark Ayers, president of the Building and Construction Trades Department of the AFL-CIO, “the time is now to become intensely focused on the creation of jobs.”



Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Experts: Best Bet in $300M Osage Nation Wind Farm Dispute Is Negotiation

March 11, 2024 — Daniel Tyson - Engineering News-Record
Nearly two months after a federal judge ruled that renewables developer Enel Green Power North America must deconstruct 84 land-based wind turbines because it did not secure mineral rights on Osage Nation land in northern Oklahoma, two energy sector attorneys say the unit of an Italy-based company must negotiate with the tribe. Reprinted courtesy of Daniel Tyson, Engineering News-Record Mr. Tyson may be contacted at tysond@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Loss Ensuing from Alleged Faulty Workmanship is Covered

July 19, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that under Montana law, water damage resulting from alleged faulty workmanship in repairing the insured's roof was covered. Leep v. Trinity Universal Ins Co., 2017 U.S. Dist. LEXIS 86759 (D. Mont. June 6, 2017). The insured's property was damaged in a hail storm. The insured contracted with Sprauge to repair the hail damage. Sprauge tore off and replaced roof lining and shingles. Sprague replaced a vent cap and tubes, but did not replace any vent piping or vents. The contract between the insured and Sprauge provided it was the owners' responsibility to check the exhaust vents for all furnaces and water heaters after the roofing project was completed. Subsequent to the repairs, water was found dripping from a bathroom fan. Moisture was also found on the second story emanating from the ceiling. Finally, in the attic, the furnace vent piping was disconnected and the furnace exhaust was venting into the attic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Falls Requiring Time Off from Work are Increasing

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
The Safety News Alert reported that while “overall occupational injuries that require time off from work” have decreased, other injuries, such as falls, have increased, according to findings from the Bureau of Labor Statistics (BLS) annual report. “The rate of falls on the same level increased to 15.4 in 2013 from 14.8 in 2012, with increases in construction, wholesale trade, and transportation and warehousing,” Safety News Alert wrote. Furthermore, “Incidence rates and counts for private sector heavy and tractor-trailer truck drivers and food preparation workers increased in 2013.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Home Prices in 20 U.S. Cities Increased 4.3% in November

January 28, 2015 — Victoria Stilwell – Bloomberg
(Bloomberg) -- Home prices in 20 U.S. cities rose at a slower pace in the year ended in November, a sign the industry struggled to find momentum even amid low mortgage rates. The S&P/Case-Shiller index of property values increased 4.3 percent from November 2013 after rising 4.5 percent in the year ended in October, the group said Tuesday in New York. The median projection of 28 economists surveyed by Bloomberg called for a 4.3 percent year-over-year advance. Nationally, prices rose 4.7 percent after a 4.6 percent gain in the year ended in October. Read the court decision
Read the full story...
Reprinted courtesy of Victoria Stilwell, Bloomberg
Ms. Stilwell may be contacted at vstilwell1@bloomberg.net

---