Fairfield Connecticut Building Expert Directory

Five Issues to Consider in Government Contracting (Or Any Contracting!)

September 02, 2024 — David Adelstein - Florida Construction Legal Updates
The appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting. Issue #1- Patently Ambiguous Specifications The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

2017 California Employment Law Update

January 13, 2017 — Evelin Y. Bailey - California Construction Law Blog
Below are some of the new laws going into effect this year that affect the construction industry. Unless otherwise noted, the laws go into effect on January 1, 2017. Public Works and Prevailing Wages You can read more about the new laws—AB 326, AB 1926 and SB 954—relating to public works and prevailing wages in an earlier blog post. Employment Contracts Choice of Forum and Choice of Law. Under SB 1241, an employer cannot require an employee who primarily works and resides in California to agree to file a lawsuit or bring a claim in another state when the claim arises in California. This is usually referred to as the choice of forum clause. Read the court decision
Read the full story...
Reprinted courtesy of Evelin Y. Bailey, Wendel Rosen Black & Dean LLP
Ms. Bailey may be contacted at ebailey@wendel.com

Construction May Begin with Documents, but It Shouldn’t End That Way

March 02, 2020 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome back Rob Mathewson. In his role as CEO, Rob handles strategy and partnerships for Geedra in addition to overseeing technology architecture and implementation. He has spent twenty years in sales and marketing management roles with experience in industrial, consumer and construction markets. Rob believes the construction industry is ripe for innovation, based on its massive size, yet low productivity. Even with such inefficiencies, a building still rises from the ground. Rob’s goal with Geedra is to leverage technology to increase transparency and communication so that projects can be completed with less risk, effort and cost. Prior to founding Geedra, Rob was the Chief Marketing Officer for Construction Documentation Services, where he was responsible for sales, marketing and business development. He spent 15 years in the chemical distribution business, including eleven years as the Northwest Branch Manager of a $50 million distributor. Rob was the founder and CEO for On The Spot Games, a board game startup. He is currently in the midst of a streak of over 2,900 consecutive days without a bad hair day. An avid mentor himself, his own business inspirations come from problem solvers like Dean Kamon, innovative communicators like Seth Godin, fierce competitors like Lance Armstrong and global gurus like Thomas Friedman. When he’s not creating innovations in the construction industry, his passions include bike riding, throwing the ball around with his kids, and cooking. He is an accomplished public speaker and is a past president of Emerald City Toastmasters. Rob holds a B.S. in Manufacturing Engineering from Boston University and a MBA from Seattle University. Construction folks are a focused bunch. Once a contractor signs a deal for a project, its team will immediately get to work generating and then executing a construction document set. For the entire duration of the schedule to follow, the construction team eats, sleeps and dreams about those documents. Their monomaniacal efforts continue until a building rises up from a patch of dirt in a matter of months. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Economic Damages and the Right to Repair Act: You Can’t Have it Both Ways

March 16, 2017 — Garret Murai – California Construction Law Blog
In 2002, the California State Legislature passed Senate Bill 800 also known as the Right to Repair Act (Civil Code Sections 895 et seq.) in an effort to stem a then rising tide in residential construction defect litigation. SB 800, which applies to newly constructed residential units including single-family homes and condominiums (but not condominium conversions) sold after January 1, 2003, was intended to curb residential construction defect lawsuits by giving developers and others in the construction chain an opportunity to repair construction defects before being sued in court. SB 800 also provides minimum construction standards and limits the time in which a homeowner can bring a claim for construction defects. In Acqua Vista Homeowners Association v. MWI, Case No. D068406 (January 26, 2017), the California Court of Appeals for the Fourth District examined the circumstances in which homeowners can sue a material supplier under the Right to Repair Act. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Congratulations to BWB&O’s Las Vegas Team on Obtaining Summary Judgment for the Firm’s Landowner Client!

August 03, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Partner Anthony Garasi, Senior Associate Madeline Arcellana, and Associate Laura Rios successfully won a Motion for Summary Judgment (“MSJ”), while also defeating two competing MSJs filed by Plaintiff, and ultimately obtaining a full dismissal of their landowner client against claims of premises liability. Plaintiff, who sued both BWB&O’s client (the landowner) and its tenant, alleged injury when he slipped and fell, while utilizing a temporary wooden board as a ramp that was placed on the subject property by the tenant, who was occupying the property subject to a lease-to-own arrangement with BWB&O’s client. In this Motion practice, the BWB&O team successfully obtained a ruling from the Court to find that BWB&O’s client had effectively contracted to delegate its maintenance responsibilities to its tenant, and also that the tenant owed BWB&O’s client full indemnity for Plaintiff’s alleged losses. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Rihanna Gained an Edge in Construction Defect Case

January 29, 2014 — Beverley BevenFlorez-CDJ STAFF
In depositions taken last week, the former owner of Rihanna’s “dream home” in Los Angeles, California, alleged “that he’d told brokers Prudential California Realty of the house’s issues,” according to Inquisitr. However, Rihanna, the singer and recent Grammy Award winner, claims that Prudential “didn’t inform” her “of these problems before she moved in, in 2009.” Rihanna has claimed that roof leaks “ruined a sound system that she’d had custom-fitted into her new abode, which cost her $6.9 million, and it also lead to mold growing on some of her designer garments too.” The singer claims to have been “tricked” into purchasing the property: “’the actual value of the property at the time of purchase, taking into consideration the extensive construction defects… was millions of dollars less’” than what she ultimately paid for it.” Read the court decision
Read the full story...
Reprinted courtesy of

BWB&O Expands to North San Diego

December 09, 2019 — Bremer Whyte Brown & O’Meara
Bremer Whyte Brown & O’Meara is excited to announce our expansion to North San Diego County. Our new office location in Encinitas is strategically located between our Newport Beach and Downtown San Diego offices. The new North San Diego office will provide further resources to better serve our clients. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O’Meara

COVID-izing Your Construction Contract

December 21, 2020 — Frederick E. Hedberg - Construction Executive
The global COVID-19 pandemic has changed the world forever, disrupting many industries, as well as creating unprecedented challenges that threaten many businesses. The construction industry is no different. Projects throughout the country have been adversely affected by unplanned work stoppages, delays, disruptions to the supply chain, price escalations and other unanticipated events. It is critical that owners, developers, contractors and suppliers learn from their experiences over the past year and account for the COVID-19 pandemic when drafting and negotiating contracts for their projects. First and foremost, parties should clearly define their rights and responsibilities to properly manage risks due to COVID-19 and its impacts. COVID-19 and other key related terms should be defined, relying on the CDC and state governments for guidance, to eliminate any uncertainties. The contract should also identify executive orders, guidelines and regulations that have been issued concerning COVID-19 by states, municipalities and other authorities that have jurisdiction where the project is located. Reprinted courtesy of Frederick E. Hedberg, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Hedberg may be contacted at fhedberg@rc.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES