Fairfield Connecticut Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Be Mindful Accepting Payment When Amounts Owed Are In Dispute

August 29, 2022 — Nicholas Korst - Ahlers Cressman & Sleight PLLC
After completing work on a project, or even during a project, it is not uncommon for some portion of the contract balance and/or a claim to be in dispute. As a contractor or subcontractor, it is important to be careful what is signed (or not signed) upon receipt of any payment both during and after completion of work on a project. One of the most common documents signed related to a receipt of payment is a lien/claim release document. This can be in the form of a conditional, unconditional, progress and/or final release. The language included in the release document is critically important, especially as it pertains to disputed amounts. As a contractor or subcontractor, if there are known disputes related to amounts owing, whether it be contract balance, disputed change order(s), a delay or inefficiency claim, or any other amounts believed to be owed, it is important to include language in the lien release that expressly carves out the disputed amounts. The same should be done for disputes related to extensions of time. This allows the contractor to accept the payment and release rights for the undisputed work, but continue to reserve its right to pursue the amounts in dispute later. If disputed amounts are not carved out, those amounts may effectively be waived and the subcontractor or contractor may lose all rights to recovery. As a subcontractor in Alaska recently learned, there are potentially other ways a contractor may waive or lose its rights to recover amounts in dispute – without even signing a waiver or release document. In Smallwood Creek, Inc. v. Build Alaska General Contracting, LLC et al., the general contractor sent the subcontractor a check described as “final payment.” The subcontractor believed it was owed more than what the general contractor had sent and refused to accept the check. Months later, the subcontractor deposited the check. The subcontractor reversed course again and attempted to repay the general contractor the amount deposited. The general contractor refused, claiming the subcontractor’s acceptance of payment constituted satisfaction of all amounts owing to the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of Nicholas Korst, Ahlers Cressman & Sleight PLLC
Mr. Korst may be contacted at nicholas.korst@acslawyers.com

Claims against Broker for Insufficient Coverage Fail

May 10, 2021 — Tred R. Eyerly - Insurance Law Hawaii
After a coverage dispute for damage caused by Hurricane Harvey was settled, the insured's claims against its insurance broker for providing insufficient coverage were dismissed. Hitchcock Indep. Sch. Dist. v. Arthur J. Gallagher & Co., 2021 U.S. Dist. LEXIS 57452 (S.D. Texas Feb. 26, 2021). The School District suffered $3.5 million in property damage after Hurricane Harvey struck. Its insurers denied coverage and the School District sued. During the litigation, the School District learned that the policies contained an arbitration clause and a New York choice of law provision. Rather than pursue its claims in arbitration, the School District settled with its insurers and sued its broker for failing to obtain insurance without arbitration or choice of law provisions. The broker moved to dismiss The School District claimed that it had to settle with the insurers for less than what it would have settled had the arbitration and choice of law provisions not been in its policies. The court found this novel theory to be based upon pure speculation Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Bridge Disaster - Italy’s Moment of Truth

September 10, 2018 — Flavia Krause-Jackson & Kathleen Hunter - Bloomberg
The tragedy of modern Italy, so beautiful yet so decrepit, can be told through its bridges. Italians love to point to the Romans as the first engineers – the country boasts some of the world’s oldest viaducts. It’s a source of national pride that blinded the nation to the reality of today, where decades of neglect led to a moment of reckoning. The collapse of the Morandi bridge in Genoa, leaving 43 dead, was followed by the usual mud-slinging, including within a tenuous ruling coalition and more importantly, to soul-searching. Meant to last 100 years, the bridge was hated more than loved – everyone who crossed it felt unsafe. Reprinted courtesy of Flavia Krause-Jackson, Bloomberg and Kathleen Hunter, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Dispute Over Amount Insured Owes Public Adjuster Resolved

January 14, 2025 — Tred R. Eyerly - Insurance Law Hawaii
The court addressed a dispute over fees that the insureds allegedly owed the public adjuster. Public' Adjuster's, LLC v. Mark Gottesdiener & Co., et al., 2024 Conn. Super. LEXIS 2352 (Conn. Super. Ct. Nov. 6. 2024). The insureds owned an apartment building that was substantially damaged by a fire. The building was insured by Quincy Mutual Group. The insureds signed a Public Adjuster Employment Contract with The Public's Adjuster, LLC (Adjuster). The contract authorized Adjuster to negotiate the reimbursable damages with Quincy on the insureds' behalf. Adjuster was to recover 8 1/2% of any amounts received by the insureds. Because of the extent of the fire damage, the work of negotiating a settlement with Quincy proved to be complex. Adjuster meticulously prepared several detained written estimates to by submitted to Quincy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Out of Eastern Europe, a Window Into the Post-Pandemic Office

September 28, 2020 — Andra Timu & Irina Vilcu - Bloomberg
Special quarantine rooms. Floor-to-ceiling walls in bathroom stalls. Touchless entrances that take your temperature. This is what telecommunications company Ericsson’s office building in Bucharest looks like after coronavirus. The space has become the pilot for a 100-prong coronavirus standard that a real estate investor in Eastern Europe is pitching as a new global “immune” building standard. Liviu Tudor, president of the Brussels-based European Property Federation, hopes the standard will convince more employees to go back to work. He’s gathered a team of experts in construction, health care and engineering, such as such as Adrian Streinu-Cercel, the head of Bucharest's biggest infectious diseases hospital, to develop three tiers of “immune” building certifications that he says are intended to make indoor spaces “pandemic proof.” Read the court decision
Read the full story...
Reprinted courtesy of Andra Timu & Irina Vilcu, Bloomberg

Demanding a Reduction in Retainage

April 01, 2015 — Craig Martin – Construction Contractor Advisor
One of the attendees of the Goldleaf Surety presentation asked a great question about reducing retention under the Nebraska Construction Prompt Pay Act, Nebraska Revised Statutes, 45-1201-45-1211. He wanted to know whether there was any way to reduce and recover retainage during the project. The short answer is retainage should be reduced half way through the project, but there is no right to recover retainge for work performed during the first half of the project. Retainage in Nebraska Under section 45-1204 of the Prompt Pay Act, a contractor may withhold up to 10% retainage. A contract that allows for greater retainage is not enforceable. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES