Fairfield Connecticut Building Expert Directory

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Affirmed: Insureds Bear the Burden of Allocating Covered Versus Uncovered Losses

September 28, 2017 — C. Lily Schurra & K. Alexandra Byrd – Saxe Doernberger & Vita, P.C.
The Second Circuit recently affirmed a district court decision that an insured bears the burden of establishing what portion of a jury verdict constitutes covered damages1. The case arose out of claims for property damage resulting from construction defects in a homebuilding project. The homeowners fired the construction manager, J. Barrows, Inc. (“JBI”), who then sued the homeowners in state court for unpaid fees (the “Underlying Action”). The homeowners counterclaimed, alleging breach of contract and negligence. JBI’s commercial general liability insurer, Harleysville Worcester Insurance Company (“Harleysville”), agreed to defend JBI under a reservation of rights. Reprinted courtesy of C. Lily Schurra, Saxe Doernberger & Vita, P.C. and K. Alexandra Byrd, Saxe Doernberger & Vita, P.C. Ms. Schurra may be contacted at cls@sdvlaw.com Ms. Byrd may be contacted at kab@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Quick Note: October 1, 2023 Changes to Florida’s Construction Statutes

November 13, 2023 — David Adelstein - Florida Construction Legal Updates
Effective October 1, 2023, there were changes to Florida’s statutory scheme dealing with construction projects. This includes Florida’s Lien Law. A copy of these changes can be found below which identify additions in blue and deletions with strikethroughs. No different than before, if you have questions or concerns as to your statutory rights on a construction project, do the prudent thing, consult a construction lawyer. A construction lawyer can help you understand changes to the applicable statutory scheme or how the statutory scheme pertains to your rights. This is important because you want to make sure you understand statutory changes that apply to your work and rights. A noteworthy change, bolded in blue below, is that there is now a basis to lien for a contractor performing construction management services “which include scheduling and coordinating construction and preconstruction phases for the construction project, or who provides program management services”:

Fla. Stat. s. 713.01 (8) “Contractor” means a person other than a materialman or laborer who enters into a contract with the owner of real property for improving it, or who takes over from a contractor as so defined the entire remaining work under such contract. The term “contractor” includes an architect, landscape architect, or engineer who improves real property pursuant to a design- build contract authorized by s. 489.103(16). The term also includes a licensed general contractor or building contractor, as those terms are defined in s. 489.105(3)(a) and (b), respectively, who provides construction management services, which include scheduling and coordinating preconstruction and construction phases for the construction project, or who provides program management services, which include schedule control, cost control, and coordinating the provision or procurement of planning, design, and construction for the construction project.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Pennsylvania Supreme Court’s Ruling On Certificates Of Merit And “Gist Of Action” May Make It More Difficult For An Architect Or Engineer To Seek An Early Dismissal

January 07, 2015 — Jerrold P. Anders and Michael W. Jervis - White and Williams LLP
In Bruno v. Erie Ins. Co., the Pennsylvania Supreme Court clarified the gist of the action doctrine that distinguishes between tort and contract claims. In doing this, the Court also ruled that a Certificate of Merit in a professional liability claim is necessary only if the plaintiff is in a direct client relationship with the licensed professional. This clarification of the Certificate of Merit requirement may limit the ability of architects and engineers to obtain an early dismissal in lawsuits. Bruno v. Erie Ins. Co. involves a common scenario. The Brunos filed a claim with their homeowners’ insurer after discovering mold in their home during remodeling. The policy included an endorsement providing coverage for mold. As part of the claim adjustment, Erie hired an engineer to inspect the mold and to provide an opinion on its severity to determine the extent of remediation required. The engineer hired by Erie reported to Mr. Bruno that the mold was harmless, that concern over health problems due to mold was merely a “media frenzy,” and that the Brunos should continue with their renovations. Reprinted courtesy of Jerrold P. Anders, White and Williams LLP and Michael W. Jervis, White and Williams LLP Mr. Anders may be contacted at andersj@whiteandwilliams.com Mr. Jervis may be contacted at jervism@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Building the Secondary Market for Reclaimed Building Materials

August 30, 2021 — Christopher G. Hill - Construction Law Musings
For this week’s guest post Friday, Musings welcomes Mark Rabkin of Deconstruction Management, Inc., the first, dedicated, for-profit deconstruction management firm in the country. Based in Northeast Ohio, it through all stages of building removal from property acquisition to deconstruction to recycling and architectural salvage. With 10 years of professional experience as an independent risk advisor focusing on sustainable real estate and development, Mark counsels his clients on effective strategies to reduce hazards and mitigate losses. Mark oversees the marketing and administrative functions of Deconstruction Management, Inc. and is responsible for managing the architectural salvage and the upcycled material reuse and resale side of the business. Mark is a leader in the advocacy of sustainable building strategies both locally and nationally. Mark serves as the volunteer Director of Advocacy for the Northeast Ohio Chapter of the United States Green Building Council. He is also an active contributor on many of the chapter’s strategic implementation teams. Mark is a member of Entrepreneurs for Sustainability, the Council of Smaller Enterprises’ Sustainability Task Force and is an active participant in the Sustainable Cleveland 2019 Initiative. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

AECOM Out as General Contractor on $1.6B MSG Sphere in Las Vegas

January 18, 2021 — Doug Puppel - Engineering News-Record
Developers of the $1.66-billion MSG Sphere in Las Vegas have removed AECOM as general contractor on the project and will bring construction management in-house for the 875,000-sq-ft entertainment venue, according to a Madison Square Garden Entertainment Corp. statement released Dec. 17. Reprinted courtesy of Doug Puppel, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Wildfire Insurance Coverage Series, Part 3: Standard Form Policy Exclusions

July 11, 2022 — Scott P. DeVries & Yosef Itkin - Hunton Insurance Recovery Blog
Even when claims are within the scope of coverage, insurers often rely on exclusions in an attempt to avoid coverage for wildfire claims. In this post in the Blog’s Wildfire Insurance Coverage Series, we discuss the interplay between coverage grants and exclusions, and the “anti-concurrent cause” provision. Insurers may cite exclusions in an attempt to reduce or avoid liability. The insurance industry has long relied on the Insurance Services Office (ISO) to draft standard form policy language and secure approval as required by state regulatory agencies. ISO Form HO 00 03 10 00 (Section I—Exclusions, Part B) provides the following form exclusionary language: We do not insure for loss to property described in Coverages A and B caused by any of the following. However, any ensuing loss to property described in Coverages A and B not precluded by any other provision in this policy is covered. Reprinted courtesy of Scott P. DeVries, Hunton Andrews Kurth and Yosef Itkin, Hunton Andrews Kurth Mr. DeVries may be contacted at sdevries@HuntonAK.com Mr. Itkin may be contacted at yitkin@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Scope of Alaska’s Dump Lien Statute Substantially Reduced For Natural Gas Contractors

March 16, 2020 — Trevor Lane - Ahlers Cressman & Sleight PLLC
In All American Oilfield, LLC v. Cook Inlet Energy, LLC,[1] the Supreme Court of Alaska clarified and substantially reduced a natural gas contractor’s ability to secure a preferred lien for its contribution to a natural gas well. Alaska’s dump lien statute (AS § 34.35.140) authorizes a laborer to claim a lien for the amount owed for their labor in the production of a “dump or mass” of “extracted, hoisted and raised” matter from a mine. While Alaska’s dump lien statute is one of three Alaskan statutes allowing laborers to attach liens to mines, mining equipment or minerals,[2] the dump lien statute is unique because it is prior and preferred over other liens, increasing the laborer’s chance of being paid in a bankruptcy proceeding. Attaching a lien to a “dump or mass” of hard-rock minerals piled outside a mine or oil stored in a tank is relatively straightforward. However, natural gas is typically left in its natural reservoir until removed by a pipeline that carries the gas to a location far from the mine. Natural gas is not extracted and stored in a “dump or mass” like other minerals, and until August 2019, controversy existed over how—or if—the dump lien statute could be used by natural gas contractors. Read the court decision
Read the full story...
Reprinted courtesy of Trevor Lane, Ahlers Cressman & Sleight PLLC
Mr. Lane may be contacted at trevor.lane@acslawyers.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES