Seattle Washington Building Expert Directory

Montana Court Finds Duty to Defend over Construction Defect Allegation

February 14, 2013 — CDJ STAFF
The U.S. District Court for Montana recently ruled on a case with underlying construction defect issues. Brian Margolies discussed Lukes v. Mid-Continent on the blog run by his firm, Traub Lieverman Straus & Shrewsberry LLP. In the construction defect case, the homeowner “alleged that the siding warped and pulled away from the house, which allowed for water intrusion and resulting exterior and interior damage.” Further, there were claims that “the insured or its subcontractor failed to install proper flashing, which also allowed for water intrusion.” The insured was Bernie Rubio, who had a general liability policy from Mid-Continent. Mid-Continent disclaimed coverage, citing sections of the business risk exclusions. The court did not find the clauses ambiguous, but concluded that they didn’t apply to the facts of the case. While the court concluded that Mid-Continent had a duty to defend, they did not determine if there was a duty to indemnify. Read the court decision
Read the full story...
Reprinted courtesy of

ASCE Releases New Report on Benefits and Burdens of Infrastructure Investment in Disadvantaged Communities

February 05, 2024 — The American Society of Civil Engineers
Washington — The American Society of Civil Engineers today released a new paper, Measuring the Benefits and Burdens of Infrastructure in Disadvantaged Communities. The report looks at how several communities across the country consider equity when investing infrastructure funds, and the impact of those projects on lower-income communities. "Civil engineers are focused on improving quality of life by building systems that improve the public's health, safety, and well-being," said Marsia Geldert-Murphey, P.E., 2024 President, ASCE. "However, the decisions on how and where infrastructure is built can affect communities for decades after a project is complete. By looking at the benefits and burdens of past projects, infrastructure owners and developers can find better ways to consider the impact of infrastructure projects being designed now." Some of the recommendations in the paper include encouraging government and other infrastructure stakeholders to use community engagement and transparent metrics when making decisions about proposed infrastructure investments. It also encourages post-project assessments and the use of existing resources to evaluate the positive and unexpected consequences of past infrastructure projects. Measuring the Benefits and Burdens of Infrastructure in Disadvantaged Communities is available here. ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

NJ Court Reaffirms Rule Against Coverage for Faulty Workmanship Claims and Finds Fraud Claims Inherently Intentional

September 20, 2021 — Anthony L. Miscioscia & Frank J. Perch, III - White and Williams LLP
Awarding summary judgment to an insurer under both liability and directors & officers (D&O) coverage parts, a New Jersey trial court reaffirmed the principle that claims of defective workmanship without resulting “property damage” are not covered under a general liability policy, and further dismissed claims for fraud and breach of fiduciary duty, finding that such claims were inherently intentional and do not state a covered “occurrence.” In Velez v. AR Management Company, et al., 2021 N.J. Super. Unpub. LEXIS 1675 (Law Div. Bergen Co. Aug. 10, 2021), owners of a condominium unit rebuilt after a fire sued the condominium association, several association board members, the association’s property management company and the general contractor for the reconstruction work. The owners’ suit alleged faulty workmanship and incomplete repairs. In addition, the owners asserted fraud and breach of fiduciary duty claims against the management company, alleging conflicts of interest and self-dealing between the management company and the general contractor, which had common ownership. In a third-party complaint, the management company sought coverage from the condo association’s liability and D&O insurer. The court dismissed the D&O coverage claim, noting that the management company was not a director or officer or otherwise entitled to insured status for the D&O coverage part. Reprinted courtesy of Anthony L. Miscioscia, White and Williams LLP and Frank J. Perch, III, White and Williams LLP Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Mr. Perch may be contacted at perchf@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Hawaii Supreme Court Finds Subcontractor Has No Duty to Defend Under Indemnity Provision

July 14, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii Supreme Court vacated the decision of the Intermediate Court of Appeals [see prior post here] and determined that a subcontractor did not have a duty to defend the developer upon tender under an indemnify provision in the parties' contract. Arthur v. State of Hawaii, 2016 Haw. LEXIS 155 (June 27, 2016). A simplified version of the detailed facts and procedural history follows. The case involved the wrongful death of Mona Arthur. Mona typically gardened on the hillside behind her home. She would cross a concrete drainage ditch and climb over a two-foo-high chain length fence to reach the hillside. Mona was found lying in a concrete ditch with severe head injuries, which ultimately led to her death. Her husband and estate sued for her wrongful death. Claims were asserted for negligence in failing to build a fence higher than two feet, which would have prevented Mona from having access to the garden. Defendants included the Department of Hawaiian Home Lands; Kamehameha Investment Corporation ("KIC"), the developer; Design Partners, Inc., the architect; Coastal Construction Company, the general contractor; and Sato and Associates, the civil engineer. The second amended complaint sought punitive damages against KIC. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Home Prices in 20 U.S. Cities Rise Most Since February 2006

January 29, 2014 — Jeanna Smialek – Bloomberg
Home prices in 20 U.S. cities rose in November from a year ago by the most in almost eight years, providing a boost to household wealth. The S&P/Case-Shiller index of property prices in 20 cities climbed 13.7 percent from November 2012, the biggest 12-month gain since February 2006, after a 13.6 percent increase in the year ended in October, a report from the group showed today in New York. The median projection of 31 economists surveyed by Bloomberg called for a 13.8 percent advance. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

AB 685 and COVID-19 Workplace Exposure: New California Notice and Reporting Requirements of COVID Exposure Starting January 1, 2021

February 01, 2021 — Sewar K. Sunnaa & Nathan A. Cohen - Peckar & Abramson, P.C.
SUMMARY Effective January 1, 2021, a new California law requires employers to notify employees about possible or known exposure to COVID-19 at the workplace. The law requires actual notification to employees within one day. In addition, the law requires notifications to local public health authorities of a COVID-19 outbreak. The law also gives Cal/OSHA a new emergency police power to issue Orders Prohibiting Use (“OPU”), permitting Cal/OSHA to close workplaces that constitute an imminent hazard to employees due to COVID-19. ANALYSIS AND GUIDANCE On January 1, 2021, a new California law took effect, which will enforce stringent new mandatory protocols governing notification of employees of COVID-19 exposures in the workplace. Until now, federal agencies such as the Occupational Safety and Health Administration (“OSHA”) and state agencies such as the California Division of Occupational Safety and Health Administration (“Cal/OSHA”) have released guidance to help employers navigate employee training, workplace surveillance and temperature-taking, among many other issues, that have arisen during the COVID-19 pandemic. Beginning January 1st, the new law places mandatory notice requirements of COVID-19 contact on all public and private employers under Labor Code Section 6409.6, with two exceptions: (1) health facilities, as defined in Section 1250 of the Health and Safety Code and (2) employees whose regular duties include COVID-19 testing or screening, or who provide patient care to individuals who are known or suspected to have COVID-19. Reprinted courtesy of Sewar K. Sunnaa, Peckar & Abramson, P.C. and Nathan A. Cohen, Peckar & Abramson, P.C. Ms. Sunnaa may be contacted at ssunnaa@pecklaw.com Mr. Cohen may be contacted at ncohen@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Randy Okland Honored as 2019 Intermountain Legacy Award Winner

January 06, 2020 — Jennifer Seward - Engineering News-Record
A passion for construction is in Randy Okland’s blood. His family’s business, Salt Lake City’s Okland Construction, was founded in 1918 by his grandfather, John Okland, a Norwegian immigrant and shipbuilder. Randy swept the floors and cleaned and fueled company vehicles while working as a laborer and later as a carpenter and concrete former. After graduating from the University of Utah, Randy worked full time at Okland, eventually taking over leadership of the company from his father in 1980. Jennifer Seward, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES