Mutual Or Concurrent Delay Caused By Subcontractors
March 23, 2020 —
David Adelstein - Florida Construction Legal UpdatesHow are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project?
Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs.
There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project.
The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Blurred Lines: New York Supreme Court Clarifies Scope of Privileged Documents in Connection with Pre-Denial Communications Prepared by Insurer's Coverage Counsel
September 17, 2015 —
Greg Steinberg – White and Williams LLPIn a recent decision, the New York Supreme Court clarified the scope of privileged documents with respect to communications prepared by an insurer’s counsel prior to issuing a denial of coverage letter. The coverage litigation at issue arose out of MF Global Inc.’s claims under fidelity bonds for losses incurred as a result of large trades made by former MF Global employee, Evan Dooley. The trades cost MF Global, Dooley’s former clearing firm, $141 million after it had to reimburse the CME Group, Inc. futures clearinghouse that handled the trade. The insurers that issued the fidelity bonds contested coverage and sued MF Global in 2009.
The opinion underscores the fact that there is no “bright line” rule in New York with respect to disclosure of communications in the insurance context prior to the issuance of a coverage determination – the disclosure requirement will instead turn on what’s actually privileged. In addition, while retention of counsel may not serve as an automatic shield for all documents prepared prior to the coverage decision, insurers will not be required to disclose, among other things, communications which include an “indicia of the provision of legal services.”
Read the court decisionRead the full story...Reprinted courtesy of
Greg Steinberg, White and Williams LLPMr. Steinberg may be contacted at
steinbergg@whiteandwilliams.com
No Duty to Defend Construction Defect Claims under Kentucky Law
March 25, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court determined that the insurer was not obligated to defend construction defect claims under Kentucky law. Westfield Ins. Co. v. Kentuckiana Commercial Concrete, LLC, 2023 U.S. Dist. LEXIS 222674 (W.D. Ky. Dec. 14, 2023).
HRB, the owner of an apartment complex, filed an arbitration demand against the general contractor, Doster Commercial Construction, for allegedly doing faulty concrete work in the construction of the apartments. Doster added its concrete subcontrator Kentuckiana Commercial Concrete - and 16 other subcontractors - to the arbitration. Kentuckiana tendered the claim to its insurer, Westfield. Wesfield defended. Doster claimed it was an additional insured under the Westfield policy and also sought coverage. Westfield refused the defend Doster. Westfield argued there was no "occurrence."
Westfield then sued both Doster and Kentuckiana in federal court, seeking a declaration that it had no duty to defend either. Westfield moved for a judgment on the pleadings.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Real Estate & Construction News Round-Up 01/26/22
February 07, 2022 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThe future of traditional real estate skills for virtual land buys is questioned, China’s property sector might experience policy easing, U.S. commercial real estate sales set records in 2021, and more.
- As the platforms and business case for virtual land buys mature, the future of traditional real estate skills remains unclear when it comes to managing virtual ownership and development. (Patrick Sisson, Bisnow)
- China’s real estate sector is likely to see “significant easing” in the policies that govern it after stricter financing rules for property development set in 2020 were met with debt, causing a contraction in the market. (Reuters)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Carbon Sequestration Can Combat Global Warming, Sometimes in Unexpected Ways
April 02, 2024 —
Michael S. McDonough, Robert A. James & Amanda G. Halter - Gravel2Gavel Construction & Real Estate Law BlogWhether by land, by sea or through human innovation, carbon sequestration is likely coming to (or already happening in) a destination near you. As our planet, overdosed on greenhouse gases, battles climate disasters, a logical solution is to simply stop pumping carbon dioxide into the air. Legislation worldwide is aimed at that target, but reducing output alone may not be enough. There are still billions of tons of extra CO2 already in the atmosphere—this crossroads is where sequestration comes into play.
Carbon sequestration is exactly what it sounds like—the storage of CO2. Once carbon is sucked out of the air, or in some cases pulled directly from industrial smokestacks, sequestration can be undertaken in a lot of different ways. Carbon storage happens naturally, when forests and oceans absorb and convert CO2 into organic matter, but carbon dioxide can also be artificially injected into deep underground rock formations (or wells), or in some cases technological approaches repurpose carbon into a resource like concrete, or as a catalyst in a closed-loop industrial system. However it’s accomplished, the point of sequestration is to stabilize carbon and ensure it doesn’t creep back into our atmosphere. Researchers, like those at the United Nations’ Intergovernmental Panel on Climate Change, now say that CO2 removal is vital to keeping global warming to 1.5 degrees Celsius (past that threshold, climate change could reach catastrophic levels). A 2023 University of Oxford study estimated that, currently, about two billion metric tons of carbon dioxide are being removed each year, primarily through land management (i.e., planting trees), and suggested that we need to double that amount to avoid dangerous global warming levels.
Reprinted courtesy of
Michael S. McDonough, Pillsbury,
Robert A. James, Pillsbury and
Amanda G. Halter, Pillsbury
Mr. McDonough may be contacted at michael.mcdonough@pillsburylaw.com
Mr. James may be contacted at rob.james@pillsburylaw.com
Ms. Halter may be contacted at amanda.halter@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Planned Everglades Reservoir at Center of Spat Between Fla.'s Gov.-Elect, Water Management District
January 02, 2019 —
Miami Herald - Engineering News-RecordDec. 11 -- Florida's incoming governor stopped short of demanding South Florida water managers step down over a contentious land deal with sugar farmers, saying he would instead await a recommendation from his transition team. That doesn't mean their days may not be numbered.
Read the court decisionRead the full story...Reprinted courtesy of
Engineering News-RecordENR may be contacted at
ENR.com@bnpmedia.com
Despite Increased Presence in Construction, Women Lack Size-Appropriate PPE
September 26, 2022 —
Robin Marth - Construction ExecutiveFit. Functionality. Comfort. These are absolute musts for any employee wearing personal protective equipment (PPE) for work. Yet for many women in the workplace, finding PPE that fits well remains a challenge.
In 2021, women comprised 11% of construction workers, 7.9% of truck drivers and 29% of manufacturing employees (Bureau of Labor Statistics), and their numbers in these fields continue to increase. Unfortunately, their options for proper-fitting PPE are not growing.
"It's difficult to find PPE that fits women, because there is limited availability of these products, or suppliers do not offer them at all," says Brandy Bossle, owner and principal consultant at Triangle Safety Consulting LLC. "We really need suppliers to go out of their way to offer PPE that's cut for both men and women."
Private fleet driver and Women in Trucking Image Team member Carol Nixon agrees, saying, "You can find men's hats, gloves, jackets and safety vests everywhere, but not with a female fit."
Women can be shaped differently from head to toe—their faces, shoulders, waists, fingers and toes are often narrower, and they often have shorter torsos, among other differences.
In order for PPE to fit many women comfortably and properly, these proportions need to be taken into account. In fact, OSHA states on its website that PPE used by women should be based on female body measurement data and that employers should offer PPE in sizes suitable for women.
Reprinted courtesy of
Robin Marth, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Ms. Marth may be contacted at
media@jjkeller.com
Five Haight Attorneys Selected for Best Lawyers in America© 2021
September 07, 2020 —
Haight Brown & Bonesteel LLPFive Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers in America© 2021. Congratulations to William Baumgaertner, Bruce Cleeland, Peter Dubrawski, Michael Leahy and Denis Moriarty.
Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 94,000 industry leading lawyers are eligible to vote (from around the world), and Best Lawyers has received over 11 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. Lawyers are not required or allowed to pay a fee to be listed; therefore inclusion in Best Lawyers is considered a singular honor. Corporate Counsel magazine has called Best Lawyers “the most respected referral list of attorneys in practice.”
Read the court decisionRead the full story...Reprinted courtesy of
Haight Brown & Bonesteel LLP