FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Lack of Workers Holding Back Building

May 10, 2013 — CDJ STAFF
Builders are hiring again, or at least they’re trying to. According to an article in the Los Angeles Times, many of the workers who were laid off during the construction bust have gone on to work in other areas. John Nunan of Unger Construction told the Times that “we’re starting to see spot shortages of labor.” One problem is that despite the boom, wages haven’t risen. Rising costs for materials and land have put an additional squeeze on builders. One building supervisor noted that during the boom, he was making $26 an hour and entry level workers $17. Now he earns $16 an hour. From bust to recovery was about five years, and its labor pool could not just wait those years. Industry representatives told the Times that it has created a perception that construction is not a stable form of employment. Brian Turmail of the Associated General Contractors of America cited “pretty consistent news coverage about the fact that there are no jobs in construction.” Read the court decision
Read the full story...
Reprinted courtesy of

---

What You Need to Know About Notices of Completion, Cessation and Non-Responsibility

June 30, 2016 — Garret Murai – California Construction Law Blog
We talk a lot about contractors on the California Construction Law Blog. Owners? Not so much. So this one’s for you. Why are Notices of Completion, Cessation and Non-Responsibility Important to Owners? California recognizes three types of statutory notices on construction projects available to owners:

• Notices of completion;
• Notices of cessation; and
• Notices of non-responsibility.
Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Brief Discussion of Enforceability of Anti-Indemnity Statutes in California

September 10, 2014 — William M. Kaufman – Construction Lawyers Blog
California Civil Code Section 2782 has been amended numerous times over the last several years. Essentially, Anti-indemnity statutes may not be fully effective for contracts entered into before January 1, 2009. Some developers and general contractors attempted to comply with the new law, and changed the indemnity provisions of their contracts post January 1, 2006. The time bracket, or zone of danger if you will, is between 1/1/06 and 1/1/09—during those three years California Civil Code §2782 was amended several times. After 1/1/09 Type I indemnity is gone in a residential construction context. The 2005 amendment to Civil Code §2782 rendered residential construction contracts entered into after 1/1/06 containing a Type I indemnity provision in favor of builders unenforceable; The 2007 amendment added contractors not affiliated with the builder to the list of contracting parties who could not take advantage of a Type I indemnity provision; However, the 2008 amendment changed the effective date to 1/1/09, dropped any mention of 2006, and added GCs, other subs, their agents and servants, etc., to the list of possible contracting parties who could not take advantage of a Type I indemnity provision[.] Reprinted courtesy of William M. Kaufman, Lockhart Park LP Mr. Kaufman may be contacted at wkaufman@lockhartpark.com, and you may visit the firm's website at www.lockhartpark.com Read the court decision
Read the full story...
Reprinted courtesy of


---

Forecast Sunny for Solar Contractors in California

June 06, 2018 — Amy Pierce - Gravel2Gavel Construction & Real Estate Law Blog
On May 9, the California Energy Commission announced that it has “adopted building standards that require solar photovoltaic systems starting in 2020.” The 2019 Building Energy Efficiency Standards are expected to “reduce greenhouse gas emissions by an amount equivalent to taking 115,000 fossil fuel cars off the road.” California will be the first in the nation to require solar. The new standards take effect on January 1, 2020. Read the court decision
Read the full story...
Reprinted courtesy of Amy L. Pierce, Pillsbury Winthrop Shaw Pittman LLP
Ms. Pierce may be contacted at amy.pierce@pillsburylaw.com

---

Zetlin & De Chiara Ranked in the Top Tier for Construction Law by Legal 500 USA

June 21, 2021 — Zetlin & De Chiara LLP
Zetlin & De Chiara was named a Band 1 Construction Law firm in the United States by the Legal 500 US in its annual guide. Described as a "boutique construction law firm with a deep bench and understanding of how a construction project is built and how to address disputes when they happen," Zetlin & De Chiara is routinely involved in projects across the US and internationally. Legal 500 selected Michael Zetlin, Michael De Chiara and Michael Vardaro to the Leading Lawyers list. Michael De Chiara was praised as an "expert in the field." Michael Zetlin was lauded for his representation of national and multi-national construction companies as well as premier owners, developers and contractors. Other members of the "very pragmatic" team who were recognized were Tara Mulrooney and Jim Terry. The Legal 500 US 2021 guide is a highly regarded legal directory which annually ranks law firms and legal professionals. It highlights legal teams who are providing the most cutting edge and innovative advice to corporate counsel. Rankings are based on feedback from clients worldwide, submissions from law firms and interviews with leading private practice lawyers. About Zetlin & De Chiara: Zetlin & De Chiara LLP provides sophisticated legal and business counsel and advice to members of the construction community across the country including real estate owners and developers, design professionals, construction managers and contractors, and financial institutions. Read the court decision
Read the full story...
Reprinted courtesy of Zetlin & De Chiara LLP


---

Limitations: There is a Point of No Return

September 06, 2023 — Amy Anderson - ConsensusDocs
After nearly any event that causes inefficiency, delay, or extra cost on a project, there are some things you should always do: review the contract and document the inefficiency, delay, or cost. However, how you document the particular issue likely changes depending on what is in your contract, your position on the project, and the outcome you hope to reach. In reviewing the inefficiency, delay, or cost, one thing to always consider is how long you have to actually recoup damages you may incur if they were caused by another party on the project. In every jurisdiction (state or federal), there is likely to be some outer limit to when you can bring litigation or arbitration against an opposing party to recover damages another party causes to you. This is generally called a statute of limitations or statute of repose, although it goes by other names depending on your state. The length of time will be specific to the locality. For example, in Texas, you have four years to bring a breach of contract claim but only two years to bring a negligence claim. Whether you fall under the two year or four year period may be highly fact intensive, depending on your claims. Do you have a contract directly with the party that is at fault? Is the claim based on your contract or some tort outside of the contract? Read the court decision
Read the full story...
Reprinted courtesy of Amy Anderson, Jones Walker LLP (ConsensusDocs)
Ms. Anderson may be contacted at aanderson@joneswalker.com

---

Key Economic & Geopolitical Themes To Monitor In 2024

January 16, 2024 — Global Insights Center Staff - The Hartford
Slowing US Economic Growth and Flattening Interest Rates Growth in the first half of 2023 averaged approximately 2.0%, driven mainly by private sector investments outside of the residential housing sector, government spending, and strong consumer demand. In 2024, The Hartford’s Global Insights Center is expecting investments and government spending to continue and may support growth in the year. However, consumer health may start to weaken due to elevated leverage, higher interest rates, and sticky inflation. Since the Federal Reserve began to increase interest rates, consumer activity and household finances have not been tremendously affected. However, as revolving interest rates (credit card loans) continue to reset that may change, especially since household savings rates fell below pre-pandemic levels and may affect consumer demand. Read the court decision
Read the full story...
Reprinted courtesy of Global Insights Center Staff, The Hartford


---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---