Fairfield Connecticut Building Expert Directory

Courts Take Another Swipe at the Implied Warranty of the Plans and Specifications

December 15, 2016 — John P. Ahlers – Ahlers & Cressman PLLC
Implied warranties are warranties created by law, legislation, or courts. In the construction industry, one of the most prominent implied warranties is that owners who provide plans and specifications to their contractors impliedly warrant the adequacy of their plans and specifications.[i] That implied warranty had its beginning in the 1918 US Supreme Court decision of U.S. v. Spearin[ii] and is, therefore, popularly known as the Spearin Doctrine. Under the Spearin Doctrine, if the contractor completes the work in accordance with the owner’s plans and specifications, but there is a deficiency or failure, the owner, not the contractor, is responsible. When the owner breaches its implied warranty, in most instances, the contractor is entitled to additional compensation for extra work performed, delays experienced, and other additional expense or loss occasioned by the warranty breach. A recent case demonstrates that this implied warranty is not “immunity.” The contractor must still act reasonably and diligently, particularly when the contract provisions so require. In the recent Fifth Circuit case of Dallas/Ft. Worth International Airport v. INet Airport Systems,[iii] the court, despite the implied warranty that existed, did not grant the contractor summary judgment on claims involving admitted plan deficiencies, since factual issues existed regarding the contractor’s cooperation and participation in the solution to the defects. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman, PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

Why Ethiopia’s $5 Billion Dam Has Riled Its Neighbors

September 12, 2022 — Samuel Gebre & Fasika Tadesse - Bloomberg
Ethiopia has been at loggerheads with downstream neighbors Egypt and Sudan for years over a $5 billion mega-dam it’s building on the Nile River. A third phase of filling a 74 billion cubic-meter (2.6 trillion cubic-foot) reservoir behind the Grand Ethiopian Renaissance Dam was completed in August, a process that’s reignited tensions. Egypt has described the unilateral action as a violation of international law and its foreign minister, Sameh Shoukry, wrote to the United Nations Security Council in July, reiterating its objections and accusing Ethiopia of derailing attempts to resolve the standoff. 1. Why is the dam so significant? The Nile is the most important source of fresh water in a largely arid region that is very vulnerable to drought and climate change and is experiencing rapid population growth. Egypt relies on the 4,000-mile-long river for as much as 97% of its supply, and much of eastern Sudan’s population depends on it for survival. Ethiopia is counting on a 5,150-megawatt hydropower plant on its new dam to help supply electricity to the 60% of its population that don’t have access, and sustain its manufacturing industries. The plant began generating power in 2022, some of which will be sold to neighboring countries. Reprinted courtesy of Samuel Gebre, Bloomberg and Fasika Tadesse, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Lawyer Claims HOA Scam Mastermind Bribed Politicians

June 28, 2013 — CDJ STAFF
The lawyer defending one of the accused in the Las Vegas HOA scam is now claiming that the FBI investigated bribery of public officials. Chris Rasmussen represents Edith Gillespie, the half-sister of Leon Benzer. Benzer has been accused of being one of the masterminds behind the scheme to pack homeowner boards with members who would make construction defect settlements that were beneficial to the scam’s participants. Rasmussen is trying to get his client tried separately from her half-brother. Rasmussen did not name any public officials. The Justice Department did not comment on his claims. Read the court decision
Read the full story...
Reprinted courtesy of

Contractual Setoff and Application When Performance Bond Buys Out of its Exposure

July 02, 2024 — David Adelstein - Florida Construction Legal Updates
The theory of “setoff” is an important theory in construction disputes. Florida’s Fourth District Court of Appeal recently provided worthy discussion on contractual setoffs:

Setoffs in contract claims are governed by [Florida Statute] section 46.015(2), which provides that if a plaintiff has released “any person in partial satisfaction of the damages sued for, the court shall [setoff] this amount from the amount of any judgment to which the plaintiff would be otherwise entitled at the time of rendering judgment.” The setoff statute intends to prohibit plaintiffs from getting double recoveries.

A setoff requires that settling and non-settling parties be jointly and severally liable. The settled damages must also be the same damages for which the setoff is sought; stated differently, a setoff is not proper where the trial damages to be setoff are separate and distinct from the settled damages.

Close Construction, LLC v. City of Riviera Beach Utility Special District, 49 Fla.L.Weekly D1184d (Fla. 4th DCA 2024) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

When Must a New York Insurer Turn Over a Copy of the Policy?

December 23, 2023 — Nicholas P. Hurzeler - Lewis Brisbois
New York, N.Y. (December 7, 2023) - It has long been the rule in New York that a defendant should disclose all insurance policies that might provide coverage to the plaintiff for an underlying claim. McKiernan v Vaccaro, 168 AD3d 827 [2d Dept 2019]; Keenan v Harbor View Health & Beauty Spa, 205 AD2d 589 [2d Dept 1994]. This rule applies to all tort cases, including motor vehicle; however, it does not apply to lawsuits seeking to recover No Fault expenses (see, CPLR 3101(f)(5)). Frequently, a plaintiff will demand a copy of the policy even when the claim is still pre-suit. This raises the question of when the insurer must comply with this specific type of discovery demand in New York. Read the court decision
Read the full story...
Reprinted courtesy of Nicholas P. Hurzeler, Lewis Brisbois
Mr. Hurzeler may be contacted at Nicholas.Hurzeler@lewisbrisbois.com

With Wildfires at a Peak, “Firetech” Is Joining Smart City Lineups

October 21, 2024 — James P. Bobotek - Gravel2Gavel Construction & Real Estate Law Blog
The threat of extreme wildfires has doubled in the past 20 years, with almost 20,000 fires blazing across the United States in 2024 alone. These high-intensity fires can be deadly, expensive, and create lingering health and environmental consequences. While we are used to seeing firefighters on the frontlines, researchers hope that next-generation smart technology, augmented by artificial intelligence (AI), will also play a key role in battling these conflagrations. Many municipalities, particularly those near wildfire-prone forests, are beginning to incorporate fire-focused advances (or “firetech”) into their smart city ecosystems. “Smart cities” are urban centers enhanced by utilities, emergency services, traffic signals and more that are linked through information and communications technology. Though the concept can spark cybersecurity-related concerns, many locales are gradually implementing many different kinds of smart tech. Following the 2023 wildfire that devastated Maui, for example, Hawaii installed a network of cloud-based fire and wind sensors that use AI to detect wildfires in real time. Smart tools like these can aid in predicting and discovering fires, streamlining emergency alert protocols, calculating vital analytics and improving firefighter safety. The National Fire Protection Association (NFPA) is actively studying these innovations, particularly in terms of environmental (smart buildings or robotics), operational (communications) and personnel (PPE sensors or biometrics). Below are a few of the key technologies to watch in this emerging field:

Smart Sensors. A total of 80 sensors (64 wildfire sensors and 16 wind sensors) were placed throughout Hawaii starting in March of 2024. Attached to existing utility poles, they detect heat in the air, and then engage AI and smart learning to distinguish smoke particles and gases produced by fires from those commonly found in Hawaii’s atmosphere—such as volcanic ash and ocean salt. Positioned in “strings,” the sensors “talk” to each other and send text messages to officials when they find a problem.

Read the court decision
Read the full story...
Reprinted courtesy of James P. Bobotek, Pillsbury
Mr. Bobotek may be contacted at james.bobotek@pillsburylaw.com

Are Construction Defect Laws a Factor in Millennials Home Buying Decisions?

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
Kimberly A. O’Hagan of Otten Johnson Robinson Neff + Ragonnetti PC discussed Millennials in Denver, Colorado, and how their desire to buy may cause them to leave the area due to a lack of affordable housing. O’Hagan describes various possible reasons for the lack of affordable housing: “Some cite the inability to qualify for financing and low demand as the reasons for the decreased number of condominium projects. Others, including Denver’s Mayor Hancock, credit the chill on condominium construction to Colorado’s construction defect laws, which they say have resulted in increased insurance costs that make condominium development economically infeasible.” Read the court decision
Read the full story...
Reprinted courtesy of

Burden of Proof Under All-Risk Property Insurance Policy

January 31, 2018 — David Adelstein - Florida Construction Legal Updates

A recent Florida case, Jones v. Federated National Ins. Co., 43 Fla. L. Weekly D164a (Fla. 4th DCA 2018) discusses the burden of proof of an insured in establishing coverage under an all-risk property insurance policy. Getting right to this critical point, the court explained the burden of proof as follows:

1. The insured has the initial burden of proof to establish that the damage at issue occurred during a period in which the damaged property had insurance coverage. If the insured fails to meet this burden, judgment shall be entered in favor of the insurer.

–

2. If the insured’s initial burden is met, the burden of proof shifts to the insurer to establish that (a) there was a sole cause of the loss, or (b) in cases where there was more than one cause, there was an “efficient proximate cause” of the loss.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES