Fairfield Connecticut Building Expert Directory

Washington State Supreme Court Issues Landmark Decision on Spearin Doctrine

September 29, 2021 — Cameron Sheldon - Ahlers Cressman & Sleight PLLC
The Washington State Supreme Court’s recent decision in Lake Hills Invs., LLC v. Rushforth Constr. Co. No. 99119-7, slip op. at 1 (Wash. Sept. 2, 2021) marks the first time in over 50 years that it has ruled on the Spearin doctrine. The Court’s opinion clarified the contractor’s burden when asserting a Spearin defense and affirmed the jury’s verdict in favor of contractor AP Rushforth Construction Company (AP). The decision is a major win for Ahlers Cressman & Sleight PLLC attorneys Scott Sleight, Brett Hill, and Nick Korst, who represented AP throughout its long-running dispute with Lake Hills Investments, LLC (LH), including the two-month jury trial and the appeal. Leonard Feldman of Peterson | Wampold | Rosato | Feldman | Luna and Stephanie Messplay of Van Siclen Stocks & Firkins also represented AP on appeal. At trial, the owner—Lake Hills Investments, LLC (LH)—asserted it was entitled to $3 million in liquidated damages and $12.3 million for defects it alleged were caused by AP’s deficient workmanship. AP denied responsibility for the delays and most of the defects and requested payment of $5 million. Regarding LH’s defect claims, AP argued as an affirmative defense that the defects were caused by deficiencies in the plans and specifications provided by LH. This affirmative defense was rooted in the Spearin doctrine, which states that when the contractor follows plans and specifications provided by the owner, the contractor is not responsible for defects caused by the plans and specifications. Read the court decision
Read the full story...
Reprinted courtesy of Cameron Sheldon, Ahlers Cressman & Sleight PLLC
Ms. Sheldon may be contacted at cameron.sheldon@acslawyers.com

Judgment for Insured Upheld After Insurer Rejects Claim for Hurricane Damage

April 15, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court of Appeals affirmed a trial court's judgment as modified against Lloyds for improperly denying a claim for damage caused by Hurricane Ike. Nat'l Lloyds Ins. Co. v. Lewis, 2015 Tex. App. LEXIS 1573 (Tex. Ct. App. Feb. 19, 2015). Lewis sued Lloyds, alleging that, although her home and personal property were seriously damaged by Hurricane Ike, her claim was denied. At trial, Lloyds testified that the damage to Lewis' home had been previously caused by Hurricane Rita and Lloyds had already paid for repair of the roof. Nevertheless, Lewis had not used the payment for roof repairs. Lewis admitted that she used some of the payment after Hurricane Rita to purchase a generator and for evacuation expenses, but the majority of the payment was used for roof repairs. Lewis' expert engineer testified that the damage to Lewis' home was caused by wind and water intrusion through a hole caused by a tree limb that fell during Hurricane Ike. The expert further opined that the cost to mitigate the damage to the home and bring it up to livable standard was $156,155. Further, the home was a constructive total loss. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

HUD Homeownership Push to Heed Lessons From Crisis, Castro Says

January 14, 2015 — Clea Benson – Bloomberg
Now that regulators have fixed the worst abuses of the 2008 credit crisis, it’s time to start promoting homeownership again, according to the top U.S. housing official. The Department of Housing and Urban Development will do its part, spending this year focusing on ways to help more Americans buy homes, HUD Secretary Julian Castro said today in a Washington speech outlining the agency’s priorities. Read the court decision
Read the full story...
Reprinted courtesy of Clea Benson, Bloomberg
Ms. Benson may be contacted at cbenson20@bloomberg.net

Insurer Not Entitled to Summary Judgment on Construction Defect Claims

February 10, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The insurer unsuccessfully moved for summary judgment, contending it had no obligation to defend two related underlying construction defect cases. Amerisure Ins. Co. v. R.L.Lantana Boatyard, Ltd., 2012 U.S. Dist. LEXIS 2466 (S.D. Fla. Jan. 9, 2012).

An engineering report noted design construction defects and deficiencies in visible, physical improvements at The Moorings at Lantana Condominium. In two lawsuits, The Moorings sued the developer, R.L. Lantana Boatyard ("RLLB"), and the contractor, Current Builders of Florida.

Current Builders was insured by Amerisure. RLLB was named as an additional insured under the Amerisure policy.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

16 Wilke Fleury Attorneys Featured in Sacramento Magazine 2021 Top Lawyers!

September 20, 2021 — Wilke Fleury LLP
Congratulations to Wilke Fleury’s featured attorneys who made the Sacramento Magazine’s Top Lawyer List for 2021! The voting for Professional Research Services’ survey to determine the top attorneys in 2021 for Sacramento Magazine was open to all licensed attorneys in Sacramento, Calif. Attorneys were asked whom they would recommend among 56 legal specialties, other than themselves, in the Sacramento area. Each attorney was allowed to recommend up to three colleagues in each given legal specialty. Once the online nominations were complete, each nominee was carefully evaluated on the basis of the survey results, the legitimacy of their license, and their current standing with the State Bar of California. Attorneys who received the highest number of votes in each specialty are reflected in the following list. – Sacramento Magazine

Kathryne E. Baldwin – Insurance
Adriana C. Cervantes – Medical Malpractice
Heather M. Claus – Health Care
Aaron R. Claxton – Health Care
Daniel L. Egan – Bankruptcy and Creditor/Debtor
Daniel J. Foster – Litigation Insurance
David A. Frenznick – Litigation Construction
George Guthrie – Construction
Neal C. Lutterman – Medical Malpractice
Stephen K. Marmaduke – Business/Corporate
Gene E. Pendergast Jr. – Estate Planning & Probate
Michael G. Polis – Health Care
Matthew W. Powell – Business Litigation
Trevor Stapleton – Estate Planning & Probate
Steve Williamson – Bankruptcy and Creditor/Debtor

Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Uniformity in Florida’s Construction Bond Laws Brings About Fairness for the Industry

August 17, 2020 — Gary L. Brown - Construction Executive
Before Florida updated its laws for construction bonds, there were some significant differences between how liens and bond claims were litigated. Forms and procedures lacked uniformity that created unnecessary challenges for the construction industry and legal practitioners serving the industry. Now, more consistency among the laws should benefit contractors, as well as lower-tiered subcontractors and suppliers. Since the updates were instated in October 2019, some of the procedures and rules used for lien enforcement have been extended to bond claims, which may make it easier to resolve differences over payment and performance. That should come as a relief to local contractors and law firms, as well as to the numerous developers and construction companies based outside of Florida that operate in the state or are considering doing so. Florida is now the number one destination for new residents, especially from high-tax states, according to IRS data. With them come new homes, retail centers, offices, industrial space, roads and other infrastructure in what is now the third-most-populous state in the nation. Reprinted courtesy of Gary L. Brown, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Brown may be contacted at gbrown@kklaw.com

Loaded Boom of Burning Tower Crane Collapses in Manhattan, Injuring Six

August 07, 2023 — James Leggate - Engineering News-Record
The boom of a tower crane, with its engine on fire, collapsed July 26 at a high-rise construction site in midtown Manhattan—hitting the face of the building across the street as it dropped its 16-ton load. City officials said they would investigate the mishap, which caused minor injuries to two firefighters and four others. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES