Insurance Companies Score Win at Supreme Court
December 26, 2022 —
Mason Fletcher & Ryan Sternoff - Ahlers Cressman & Sleight PLLCIn 2011, the Washington State Department of Transportation (“WSDOT”) contracted with Seattle Tunnel Partners, a joint venture of Dragados USA and Tutor Perini (“STP”) to construct a tunnel (“SR 99 Tunnel”) to replace the dilapidated Alaska Way Viaduct. STP obtained a builder’s “all-risk” insurance policy (“Policy”) from Great Lakes Reinsurance (UK) PLC and several other insurers (collectively, the “Insurers”) which insured against damage to both the project and the tunnel boring machine popularly known as Big Bertha (“Bertha”).
Bertha began excavating in July 2013 but broke down a few months later when the machine stopped working. Work did not resume on the project until December 2015. WSDOT and STP tendered insurance claims for the losses associated with the delays and breakdown of Bertha but the Insurers denied coverage. Thereafter, WSDOT and STP sued.
The Insurers moved the trial court for partial summary judgment to resolve some, but not all, of the coverage disputes. In a unanimous decision, the Washington State Supreme Court affirmed the trial court and Court of Appeals, and held that insurance companies do not have to reimburse WSDOT and STP for costs accrued during a two-year Project delay, under certain provisions of the insurance policies.
Reprinted courtesy of Mason Fletcher, Ahlers Cressman & Sleight PLLC and
Ryan Sternoff, Ahlers Cressman & Sleight PLLC
Mr. Sternoff may be contacted at ryan.sternoff@acslawyers.com
Read the court decisionRead the full story...Reprinted courtesy of
California Supreme Court Confirms the Right to Repair Act as the Exclusive Remedy for Seeking Relief for Defects in New Residential Construction
February 22, 2018 —
Brenda Radmacher – Construction Law BlogThe California Supreme Court recently issued its decision on a critical issue in the residential construction industry – the claims for construction defects that a California homeowner can bring against a builder or seller of new residential properties in California.
Holding
In McMillin Albany v. The Superior Court of Kern County, the Court held that California’s Right to Repair Act (California Civil Code, sections 895, et seq.) (the “Act”) is the exclusive remedy for homeowners claiming defective construction of new residences in California.
Read the court decisionRead the full story...Reprinted courtesy of
Brenda Radmacher, Gordon & ReesMs. Radmacher may be contacted at
bradmacher@grsm.com
Hollywood Legend Betty Grable’s Former Home for Sale
June 30, 2014 —
Catherine Sherman – BloombergWhen it comes to Old Hollywood stars, Betty Grable was “the girl with the million-dollar legs.” She also lived in a million-dollar home just four blocks from the Hotel Bel-Air.
Located at 1280 Stone Canyon Rd, the house is currently on the market for $13.295 million.
“It’s a classic, Hollywood estate,” said listing agent Bjorn Farrugia of Hilton & Hyland. “It’s very picturesque — set back on one of the best streets in Bel-Air.”
Grable moved in after the home was built in 1937, the same year she married actor Jackie Coogan (aka “Uncle Fester” in the 1960s sitcom The Addams Family). Soon after, in 1939, the couple appeared in “Million Dollar Legs,” a movie giving rise to the actress’ nickname.
Read the court decisionRead the full story...Reprinted courtesy of
Catherine Sherman – Bloomberg
Does Your U.S. Company Pull Data From European Citizens? Fall In Line With GDPR by May 2018 or Suffer Substantial Fines
November 15, 2017 —
Jeff Dennis & Ivo Daniele – Newmeyer & Dillion, LLPThe European Union (“EU”) has enacted a strict, comprehensive framework of security regulations aimed to protect its citizens. These regulations, known as the General Data Protection Regulation (“GDPR”), provide a blueprint for a combination of required legal, technological and work habits within an organization. Although this is an EU regulation, the new laws will apply to any organization within or outside the EU that collects or processes data of EU citizens. Therefore, U.S. companies must analyze their data and processes to determine whether compliance with the GDPR is necessary. A quickly-approaching deadline of May 25, 2018 must be met to avoid massive fines.
What is the GDPR?
In order to address the creation of social networking sites, cloud computing, and location-based services, the EU set in motion a process to implement a vigorous set of rules to ensure the right to personal data protection for all European citizens. In April 2016 the European Parliament, the Council, and the Commission adopted a new GDPR, which will take affect on May 25, 2018.
This GDPR will streamline cooperation between the data protection authorities on personal data issues allowing companies to deal with one authority - not each of the 28 EU member states. This will allow for quicker decisions by the data protection authorities and greatly reduce the red tape in both compliance and enforcement under the GDPR. This will also create a level playing field by forcing non-EU companies to comply with the same strict regulations - regardless of whether or not the company is established in the EU.
Territorial scope of the GDPR
The GDPR applies directly to the processing of personal data in the context of the activities of an establishment of a controller or a processor in the EU - regardless of whether the processing takes place in the EU. Additionally, there are specific provisions under the GDPR that apply to non-EU companies if their processing activities relate to (a) the offering of goods or services (irrespective of whether a payment of the data subject is required) or (b) monitoring the behavior of individuals within the EU. Therefore, all companies must determine whether they process or monitor information of EU citizens. If a company falls within one of these categories, compliance with the GDPR is mandatory.
What happens if a company fails to comply with the GDPR?
Failure to comply with the GDPR could subject a company to crushing administrative fines.
The supervisory authority has the power to impose administrative fines under the GDPR. The following violations and breaches would subject a company to administrative fines:
- Not adhering to the core principles of processing personal data,
- Breach of notification to EU citizens by controllers and processors,
- Wrongful transfer of personal data to non-EU countries,
- Breach of obligations regarding certification,
- Ignoring the mandates asserted by the supervisory authority,
- Breach by those responsible for impact assessment, and
- Wrongful processing of employee data.
The extent of the violation and type of personal data involved will dictate the severity of the administrative fines imposed on a company. For example, under the GDPR, a company could be subject to administrative fines up to 20,000,000 EUR, or up to 4% of the total worldwide annual revenue of the preceding financial year. Obviously, these fines would be financially crippling to any company.
Preparing for May 25, 2018
The May 25, 2018 deadline is fast approaching and preparing for full compliance with the GDPR is paramount. Simple steps should be taken to ensure compliance including to:
(1) Review and analyze data repositories for sensitive data,
(2) Perform an analysis/accounting of procedure for data collection, and
(3) Create an oversite committee dedicated to data activities and compliance.
Most importantly, however, is to determine whether compliance with the GDPR is necessary, and strictly follow the requirements of the GDPR to protect from potentially massive fines.
Jeffrey M. Dennis currently serves as Newmeyer & Dillion’s Managing Partner and as a business leader, advises his clients on cybersecurity related issues, introducing contractual and insurance opportunities to lessen their risk. You can reach Jeff at jeff.dennis@ndlf.com.
Ivo Daniele is a seasoned associate in Newmeyer & Dillion’s Walnut Creek office. His practice includes representing private and public companies with both their transactional and litigation needs. You can reach Ivo at ivo.daniele@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Does Your U.S. Company Pull Data From European Citizens? Fall In Line With GDPR by May 2018 or Suffer Substantial Fines
Washington Supreme Court Sides with Lien Claimants in Williams v. Athletic Field
September 30, 2011 —
Douglas Reiser, Builders Council BlogThe Washington Supreme Court issued their opinion today on Williams v. Athletic Field, perhaps the most talked about construction law case in the past few years. I have discussed this case exhaustively here on Builders Counsel. Today we have a resolution.
In an unanimous opinion issued today, the high court sided with lien filers who followed a sample form provided in RCW 60.04.091. Additionally, the court found that a lien company - and presumably other persons - could sign the lien for the lien claimant, as an agent, without invalidating the lien.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Read the court decisionRead the full story...Reprinted courtesy of
L.A. Mixes Grit With Glitz in Downtown Revamp: Cities
May 13, 2014 —
James Nash and Nadja Brandt – BloombergNear streets so gritty they were used as the backdrop for a shootout in the next “Fast & Furious” movie, million-dollar condos and $38 racks of lamb beckon the urban pioneers of Los Angeles.
The rehab of warehouses and factories in the Arts District is the latest wave in a revival transforming the core of the second-largest U.S. city. Since 2011, about $7 billion has been poured into downtown. A decade ago its most prominent residents were the homeless. Now condos sell for a median of $523.36 a square foot -- more than in Beverly Hills. Alma, Bon Appetit magazine’s best new U.S. restaurant in 2013, is a few blocks from the convention center the city plans to renovate.
“All of a sudden, overnight, you have more cranes going up in downtown L.A. than any other neighborhood in Southern California, by far,” said Lew Horne, head of the regional CBRE Real Estate Group Inc. (CBG) office.
Mr. Nash may be contacted at jnash24@bloomberg.net; Ms. Brandt may be contacted at nbrandt@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
James Nash and Nadja Brandt, Bloomberg
Beyond the Flow-Down Clause: Subcontract Provisions That Can Expose General Contractors to Increased Liability and Inconsistent Outcomes
December 10, 2024 —
Phillip L. Parham III - ConsensusDocsFlow-down clauses in construction subcontracts—blanket clauses providing that some or all of the terms and conditions in the prime contract between the general contractor and the property owner apply equally between the subcontractor and general contractor—are an important component to managing risk for a general contractor and reducing the likelihood of disputes with either/both the owner and subcontractor. Put simply, flow-down provisions can provide continuity between the general contractor’s obligations to the owner and the subcontractor’s obligations to the general contractor. Properly drafted, flow-down clauses reduce the general contractor’s risk by ensuring that the subcontractor is legally bound to meet the owner’s objectives for the project in the same way as the general contractor. But relying on blanket flow-down clauses, alone, to protect the general contractor is like a soldier going into battle with nothing but a helmet, leaving significant other areas exposed and unprotected. In other words, a general contractor should look beyond just a singular, blanket flow down of terms to ensure its bases are properly covered.
Accordingly, this article goes beyond the blanket flow-down clause and highlights several key subcontract provisions where inconsistent obligations among the subcontractor, general contractor, and owner expose the general contractor to increased liability and inconsistent outcomes. Specifically, this article will examine disputes resolution clauses, liquidating provisions, notice provisions, and termination provisions. However, this article will not provide a deep examination of these clauses, nor does it highlight every potentially relevant clause. Rather, it focuses on these select clauses to highlight important issues associated with flow-down provisions.
Read the court decisionRead the full story...Reprinted courtesy of
Phillip L. Parham III, Jones Walker LLPMr. Parham may be contacted at
pparham@joneswalker.com
Florida Appeals Court Rules in Favor of Homeowners Unaware of Construction Defects and Lack of Permits
December 09, 2011 —
CDJ STAFFThe Florida Court of Appeals has ruled that a homeowner is not liable for defects in unpermitted alterations, reversing a lower court’s decision in Jensen v. Bailey. The Jensens sold their house to the Baileys. During the sale, the Jensens filled out a property disclosure statement, checking “no” to a question about “any improvement or additions to the property, whether by your or by others that have been constructed in violation of building codes or without necessary permits.”
After moving in, the Baileys discovered several problems with the home. One involved a defective sewer connection leading to repeated backups. The Baileys also found problems with remodeling the Jensens had done in the kitchen, master bath, and bedroom. The remodeling work was not done with required permits nor was it up to code.
The court noted that an earlier case, Johnson v. Davis, established four criteria: “the seller of a home must have knowledge of a defect in the property; the defect must materially affect the value of the property; the defect must not be readily observable and must be unknown to the buyer; and the buyer must establish that the seller failed to disclose the defect to the buyer.” The court found that the first of these criteria was crucial to determining the case.
In the Johnson ruling, the then Chief Justice dissented, fearing that the courts “would ultimately construe Johnson’s requirement of actual knowledge to permit a finding of liability based on constructive knowledge,” quoting Justice Boyd, “a rule of constructive knowledge will develop based on the reasoning that if the seller did not know of the defect, he should have known about it before attempting to sell the property.” The Appeals Court concluded that the lower court hit this point in ruling on Jensen v. Bailey.
Citing other Florida cases, the court noted that the Johnson rule does require “proof of the seller’s actual knowledge of the defect.” The court cited a case in which it was concluded that the seller “should have known” that there was circumstantial evidence was that the seller did know about the defects, as the seller had been involved in the construction of the home.
In the case of the Jensens, the lower court concluded that they did not know that the work was defective, nor did they know that they were obligated to obtain permits for it. The Appeals Court found this one fact sufficient to reverse the decision and remand the case to the lower court for a final judgment in favor of the Jensens.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
