FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Occurrence Found, Business Risk Exclusions Do Not Bar Coverage for Construction Defects

May 13, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that the supplier of cement for the construction of pools had coverage for alleged construction defects in the finished pools. Harleysville Worcester Ins. Co. v. Paramount Concrete, Inc., 2014 U.S. Dist. LEXIS 43889 (D. Conn. March 31, 2014). R.I. Pools sued Paramount, a manufacturer and supplier of shotcrete, after cracking appeared in nineteen pools built by R.I. Pools using Paramount's shotcrete. The jury awarded R.I. Pools compensatory damages of $2,760,000. Paramount's insurer, Harleysville, defended under a reservation of rights. After the verdict, Harleysville filed for a declaratory judgment that there was no coverage under the CGL policy. Paramount filed for partial summary judgment. Harleysville first argued there was no occurrence. The policy's definition of occurrence included the phrase, "continuous exposure." This broadened the term "occurrence" beyond the word accident to include a situation where damage occurred over a period of time, rather than suddenly or instantaneously. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Construction Resumes after Defects

June 28, 2013 — CDJ STAFF
When inspectors found defective bolts in the construction of the Media Arts Center at L. A. Mission College, the contractor walked off the job. The project had been underway for about eighteen months. After problems were found with welds and bolts, the contractor informed the school that it could not complete the job. The California Division of the State Architect then required inspection of every weld and joint, leading to a dispute as to who was going to pay for it. At this point, only the first story has been inspected. Although the other two stories must be inspected, the new contractor is about to begin work on the building. James O’Reilly, the executive director for facilities, planning and development, said that “the main focus is on fixing the defective issues and getting construction completed so we can serve the Mission campus.” Still at question is how much SMC Construction received before they walked off the job. Read the court decision
Read the full story...
Reprinted courtesy of

---

Ensuing Losses From Faulty Workmanship Must be Covered

May 10, 2012 — Tred R. Eyerly - Insurance Law Hawaii

Coverage for damages resulting from faulty workmanship in the construction of an apartment complex was at issue in The Bartram, LLC v. Landmark Am. Ins. Co., 2012 U.S. Dist. LEXIS 44535 (N.D. Fla. March 30, 2012).



The owner of the apartments, Bartram, had primary coverage and three layers of excess coverage. Each contract excluded loss from faulty workmanship. The policies provided, however, "if loss or damage by a Covered Cause of Loss results, we will pay for that resulting loss or damage."



Bartram contended water intrusion occurred because of faulty workmanship, which caused damage to the buildings’ exterior and interior finishes, wood sheathing, framing, balcony systems, drywall ceilings and stucco walls. This damage was separate from the work needed to simply fix the faulty workmanship. Therefore, Bartram argued, the ensuing losses that resulted from the water intrusion was covered.



The insurer argued the ensuing loss exception was not applicable if the ensuing loss was directly related to the original excluded loss.



Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

 Read the court decision
Read the full story...
Reprinted courtesy of

---

Render Unto Caesar: Considerations for Returning Withheld Sums

January 18, 2021 — William E. Underwood Partner, Jones Walker LLP - ConsensusDocs
Withholding sums during a dispute can be an effective and perfectly legitimate means to protect against the harms caused by another party’s breach. However, withholding too much money during a dispute can turn a position of strength into one of weakness. “Why should I fund the other side’s litigation war chest?” and “Isn’t this just a display of weakness?” are common questions raised by contractors when this issue is discussed. Often, the contractor is well within its contractual or legal rights to withhold money from a breaching subcontractor (another topic for another day). But it may not always be in a contractor’s best interest to withhold every single penny available. This article addresses some of the long-term implications for failing to return withheld sums, including the potential to recover attorneys’ fees, possible bad faith, accruing interest, and overall litigation costs. Admittedly, it can be hard to give money back in the middle of a dispute. But sometimes it can positively impact the overall outcome of the case. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Connecticut Supreme Court Finds Duty to Defend When Case Law is Uncertain

October 12, 2020 — Eric B. Hermanson & Austin D. Moody - White and Williams
The Connecticut Supreme Court recently addressed whether an insurer has a duty to defend when faced with legal uncertainty as to whether coverage is owed: for example, when there is no Connecticut case law on point, and courts outside of the state have reached conflicting decisions. The Court suggested that an insurer, in these circumstances, should defend the insured, and should seek a declaratory judgment from a court as to whether coverage is owed. The issue in Nash St., LLC v. Main St. Am. Assurance Co.,[1] arose out of a home collapse in Milford, Connecticut. The owner of the home (Nash) hired a contractor (New Beginnings) to renovate the home. New Beginnings, in turn, retained a subcontractor to lift the house and to do concrete work on the foundation. While the subcontractor was lifting the house, the house shifted off the supporting cribbing and collapsed. Reprinted courtesy of Eric B. Hermanson, White and Williams and Austin D. Moody, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwiliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Do Hurricane-Prone Coastal States Need to Update their Building Codes?

April 15, 2015 — Beverley BevenFlorez-CDJ STAFF
Property Casualty 360 reported that “a number of coastal states took no action to improve their building code systems since 2012, and a few have weaker systems in place, according to the Insurance Institute for Business & Home Safety (IBHS).” The IBHS released their “Rating the States” report that published the results of their study of “the 18 most hurricane-prone states located along the Gulf of Mexico and the Atlantic Coast on their building regulations.” States can receive up to 100 points, with a higher score reflecting better state building requirements. Delaware scored lowest with a mere 17 points—the same score it received in 2012. Virginia, the highest scored state, earned 95 points. Read the court decision
Read the full story...
Reprinted courtesy of

---

North Carolina Supreme Court Addresses “Trigger of Coverage,” Allocation and Exhaustion-Related Issues Arising Out of Benzene-Related Claims

January 04, 2023 — White and Williams LLP
On December 16, 2022, the North Carolina Supreme Court decided Radiator Specialty Co. v. Arrowood Indem. Co., 2022 N.C. LEXIS 1122 (Dec. 16, 2022), in which it addressed coverage issues arising out of claims by individuals alleging injury from exposure to benzene contained in the insured’s products. Affirming in part and reversing in part the intermediate appellate court’s decision, the court held: (1) an “exposure trigger” applied; (2) defense and indemnity costs were subject to pro-rata allocation; and (3) vertical exhaustion applied to the duty to defend under certain umbrella policies. Two justices concurred in part and dissented in part. I. Background In Radiator Specialty, the insured (RSC) was named in hundreds of underlying suits arising from individual plaintiffs’ alleged exposure to benzene contained in its products. Between 1971 and 2012, RSC was insured under primary, umbrella and excess liability policies issued by various insurers. In 2013, RSC sued the insurers in North Carolina state court, seeking coverage for approximately $45 million in defense and indemnity costs incurred for the underlying claims. In 2016, the trial court decided motions for summary judgment on a number of coverage issues. Following a bench trial in 2018, the trial court entered final judgment, which required the insurers to reimburse $1.8 million of RSC’s past costs. The rulings were appealed to the North Carolina Court of Appeals, which issued a decision in 2020. In 2021, the North Carolina Supreme Court granted RSC’s and certain insurers’ petitions for discretionary review of the Court of Appeals’ decision. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---