Is There Direct Physical Loss Under A Property Policy When COVID-19 is Present?
April 06, 2020 —
Tred R. Eyerly - Insurance Law HawaiiMost property policies provide coverage for property damage only when there is "direct physical loss" to covered property. Early indications are that COVID-19 remains on surfaces. The duration can last from a few hours to three weeks, depending on the type of surface material. If an employee is infected and the store or restaurant must closed because the virus may rest on surfaces within the building, is there direct physical loss, even though the building structure itself is unharmed?
To answer this question, cases from jurisdictions outside Hawaii may provide guidance. In a case from Louisiana, the homeowner had to move out of her home when excessive levels of organic lead were discovered in the kitchen, living room, master bedroom, and attic. Widder v. La. Citizens Prop. Ins. Corp., 82 So. 3d 294 (La. Ct. App. 2011). The insurer denied coverage because there was no direct physical loss. The trial court agreed; since the home was still intact, no direct physical loss had occurred, so there was no coverage under the policy. The appellate court reversed. It compared the presence of inorganic lead in the home to cases that found a direct physical loss from the existence of Chinese drywall, from which gaseous fumes were released, rendering the home unusable or uninhabitable. Physical damage was not necessary.
What if smoke from a nearby wildfire fills an outdoor theater, forcing cancellation of performances and loss of business income? This was the situation in Oregon Shakespeare Festival Ass'n v. Great Am. Inc. Co., 2016 U.S. DIst. LEXIS 74450 (D. Ore. Jun 7, 2016). Wildfires in the area caused smoke, soot, and ash to accumulate on the surface of seats and concrete ground of the open-air theater. The air quality was poor, but no federal, state or local agency ordered cancellation of the performances. Further, the theater did not suffer any permanent or structural damage to its property. The insurer denied coverage, contending that the loss or damage must be structural to the building itself. After all, the smoke in the air at the theater did not require any repairs to the structure of the property. The court disagreed. The theater sustained "physical loss or damage to property" when the wildfire smoke infiltrated the theater and rendered it unusable for its intended purpose. The decision in Oregon Shakespeare Festival was eventually vacated by a joint stipulation of the parties. Oregon Shakespeare Festival Ass'n v. Great Am. Ins.Co., 2017 U.S. Dist. LEXIS 33208 (D. Ore. March 6, 2017), but the reasoning is still sound.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Five Issues to Consider in Government Contracting (Or Any Contracting!)
September 02, 2024 —
David Adelstein - Florida Construction Legal UpdatesThe appeal of Appeals of – Konecranes Nuclear Equipment & Services, LLC, ASBCA 62797, 2024 WL 2698011 (May 7, 2024) raises interesting, but important, issues that should be considered. In this case, the government (in a supply contract) procured four portal cranes from the claimant. After an initial test of one of the cranes failed, the government refused to accept delivery even after the issue was addressed by the claimant. The government did not accept the manner in which the claimant addressed the issue and would only accept cranes if the claimant employed “an unnecessary alternative solution [that] caused further delay and increased [claimant’s] costs.” On appeal, it was determined the government’s decision to delay delivery based on its demand for the alternative solution was not justified, i.e., constituted a breach of contract. Below are five issues of consideration in government contracting, or, for that matter, any contracting.
Issue #1- Patently Ambiguous Specifications
The government argued that the specifications were patently ambiguous and because the claimant failed to inquire regarding the ambiguous specifications prior to performance, its interpretation of the ambiguous specifications should govern. The contractor countered that the specifications were unambiguous and it met the specifications.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
California Expands on Scope of Coverage for Soft Cost Claims
February 14, 2023 —
Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage.
The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project.
As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.Ms. Rabiyan may be contacted at
CRabiyan@sdvlaw.com
West Coast Casualty’s Construction Defect Seminar Returns to Anaheim May 15th & 16th
February 25, 2014 —
Beverley BevenFlorez-CDJ STAFFThis year will be the twenty-first anniversary of West Coast Casualty’s Construction Defect Seminar, which brings together industry professionals locally as well as internationally. Early registration begins in the evening of Wednesday, May 14th, while the main events take place on May 15th and 16th at the Disneyland Hotel and Resort.
For attendees who wish to explore more of southern California before or after the seminar, you can show your badge and save at many venues including the Warner Bros. VIP Studio Tour, Medieval Times, Pinot Provence, Crossroads at House of Blues, Morton’s Steakhouse, as well as many other establishments.
You may register for the seminar online. They are offering a $50 discount to attendees who register before April 15th.
Download an invitation or register for the event...
Show Your Badge and Save... Read the court decisionRead the full story...Reprinted courtesy of
Read the Property Insurance Policy to be Sure You are Complying with Post Loss Obligations
January 04, 2021 —
David Adelstein - Florida Construction Legal UpdatesI have discussed this before in prior postings, but it is worth repeating. It is imperative for an insured to comply with post loss obligations in a property insurance policy. Not doing so gives the insurer the argument that its insured forfeited coverage under the policy. Naturally, this is never what an insured wants as this is contrary to submitting an insurance claim to begin with. To avoid this situation, an insured should consult with counsel and read the policy including endorsements issued to the policy to be sure that post loss obligations are complied with and, if they are not, there is a basis supported by case law.
In a recent case, Goldberg v. Universal Property and Casualty Ins. Co., 45 Fla. L. Weekly D2118b (Fla. 4th DCA 2020), the property insurance policy for hurricanes and windstorms contained the following through an endorsement issued to the policy:
You must give notice of a claim, a supplemental claim, or reopened claim for loss or damage caused by the peril of windstorm or hurricane, with us in accordance with the terms of this policy and within three years after the hurricane first made landfall or the windstorm caused the covered damage. For purposes of this Section, the term “supplemental claim” or “reopened claim” means any additional claim for recovery from us for losses from the same hurricane or windstorm which we have previously adjusted pursuant to the initial claim. . . .
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
California Case Adds Difficulties for Contractors & Material Suppliers
August 20, 2014 —
Beverley BevenFlorez-CDJ STAFFGarret Murai in his California Law Blog declared that “things just got a lot tougher for contractors and material suppliers in the Golden State.” In his blog, Murai analyzed the recent case Golden State Boring & Pipe Jacking, Inc. v. Eastern Municipal Water District, Case No. E054618 (July 23, 2014), in which “the California Court of Appeals for the Fourth Appellate District found that a subcontractor’s public works payment bond claim was time barred because its stop payment notice was served ‘before’ a notice of completion was recorded.”
Murai explained the importance of the ruling and how it changed the status quo: “Whereas before, it was commonly understood that you could serve a stop payment notice ‘during’ construction (after all, that was the point wasn’t it, to stop construction funds before they are paid out), now you may have only have a 30 day window (probably less) to serve a stop notice within 30 days after a notice of completion or notice of cessation is recorded.”
Read the court decisionRead the full story...Reprinted courtesy of
Insurer’s Discovery Requests Ruled to be Overbroad in Construction Defect Suit
October 28, 2011 —
CDJ STAFFThe US District Court has ruled in the case of D.R. Horton Los Angeles Holding Co. Inc. v. American Safety Indemnity, Co. D.R. Horton was involved in a real estate development project. Its subcontractor, Ebensteiner Co., was insured by ASIC and named D.R. Horton as an additional insured and third-party beneficiary. D.R. Horton, in response to legal complaints and cross-complaints, filed for coverage from ASIC under the Ebensteiner policy. This was refused by ASIC. ASIC claimed that “there is no potential coverage for Ebensteiner as a Named Insurer and/or D.R. Horton as an Additional Insured.” They stated that “the requirements for coverage are not satisfied.”
The case same to trial with the deadline for discovery set at March 1, 2011. ASIC stated they were seeking the developer’s “job file” for the Canyon Gate project. D.R. Horton claimed that ASIC’s discovery request was overbroad and that it would be “unduly burdensome for it to produce all documents responsive to the overbroad requests.”
D.R. Horton did agree to produce several categories of documents, which included:
“(1) final building inspection sign-offs for the homes that are the subject of the underlying litigation;(2) an updated homeowner matrix for the underlying actions; (3) the concrete subcontractor files; (4) the daily field logs for D.R. Horton’s on-site employee during Ebensteiner’s work; (5) documents relating to concrete work, including documents for concrete suppliers; (6) documents relating to compacting testing; (7) documents relating to grading; and (8) D.R. Horton’s request for proposal for grading”
The court found that the requests from ASIC were overbroad, noting that the language of the ASIC Request for Production of Documents (RFP) 3-5 would include “subcontractor files for plumbing, electric, flooring, etc. - none of these being at issue in the case.” The court denied the ASIC’s motion to compel further documents.
The court also found fault with ASIC’s RFPs 6 and 7. Here, D.R. Horton claimed the language was written so broadly it would require the production of sales information and, again, subcontractors not relevant to the case.
Further, the court found that RFPs 8, 10, 11, and 13 were also overbroad. RFP 8 covered all subcontractors. D.R. Horton replied that they had earlier complied with the documents covered in RFPs 10 and 11. The court concurred. RFP 13 was denied as it went beyond the scope of admissible evidence, even including attorney-client communication.
The court denied all of ASIC’s attempts to compel further discovery.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Michigan Finds Coverage for Subcontractor's Faulty Work
August 24, 2020 —
Tred R. Eyerly - Insurance Law HawaiiThe Michigan Supreme Court held that under a CGL policy, an "accident" may include unintentional subcontractor work that damages the insured's work product. Skanska USA Building Inc. v. M.A.P. Mechanical Contractors, Inc., et al., 2020 Mich. LEXIS 1194 (Mich. June 29, 2020).
Skanska USA Building Inc. was the construction manager on a renovation project for a medical centre. The heatng and cooling portion of the project was subcontracted to M.A.P. Mechanical Contractors, Inc. (MAP). MAP installed a steam builder and piping for the heating system. The installation included several expansion joints. After completion, Skanska learned that MAP had installed some of the expansion joints backward. This caused significant damage to concrete, steel and the heating system. The medical center sent a demand letter to Skanska, who send a demand letter to MAP. Skanska did the repairs and replacement of the damaged property. Skanska then submitted a claim of $1.4 million for its work to Amerisure Insurance Company. The claim was denied.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
