Seattle Washington Building Expert Directory

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

BHA Sponsors the 9th Annual Construction Law Institute

January 21, 2016 — CDJ STAFF
Bert L. Howe & Associates, Inc. is proud to be partnering with the Florida Bar Continuing Legal Education Committee and the Construction Law Committee of the Florida Bar Real Property, Probate and Trust Law Section, as a sponsor and exhibitor at 9th Annual Construction Law Institute to be held March 11th, 12th & 13th, 2016 at the JW Marriott Orlando Grande Lakes in Orlando. With offices in Miami serving all of Florida, Bert L. Howe & Associates, Inc. (BHA) offers the experience of over 20 years of service to carriers, defense counsel, and insurance professionals as designated experts in nearly 6,000 cases. BHA’s staff encompasses a broad range of licensed and credentialed experts in the areas of general contracting and specialty trades, as well as architects, and both civil and structural engineers, and has provided services on behalf of developers, general contractors and sub-contractors. BHA’s experience covers the full range of construction defect litigation, including single and multi-family residential (including high-rise), institutional (schools, hospitals and government buildings), commercial, and industrial claims. BHA specializes in coverage, exposure, premises liability, and delay claim analysis as well. As the litigation climate in Florida continues to change, and as the number of construction defect and other construction related cases continues to rise, it is becoming more important for contractors and builders here to be aggressive in preparing for claims before they are made, and in defending against those claims once they are filed. Since 1993, Bert L. Howe & Associates has been an industry leader in providing construction consulting services, and has been a trusted partner with builders and insurance carriers, both large and small, across the Western and Southern United States. Here in Florida, we have been providing construction defect and construction-claims related forensic expert services for the past decade with a proven track record of successful results. For those of you planning on attending the conference, or those who may know someone who will be, we encourage you to stop by the BHA booth and we welcome the opportunity to discuss further the broad range of services provided by BHA. For your convenience, here is a link to the registration page for the 9th Annual Construction Law Institute: http://www.floridabar.org/FBWEB/CLEReg.nsf/zLocations2/MAOS-A4UK4Z?OpenDocument Read the court decision
Read the full story...
Reprinted courtesy of

Ruling Finds Builder and Owners at Fault in Construction Defect Case

December 30, 2013 — CDJ STAFF
A Minnesota home owners association has been found 30liable for some of the damage to their homes in a jury trial. The Interlachen Propertyowners Association made a claim of construction defects against Keupers Architects and Builders who had constructed the 24-unit town home complex. According to the association’s lawyer, the half-log siding was improperly installed, leading to water intrusion and rot. The jury did find for the homeowners on the construction defect claim, but found on a claim of negligent repairs that the association was 30% at fault, due to insufficient maintenance of the building. “We don’t think any amount of maintenance would have saved these buildings,” said Jason Tarasek, the lawyer for the association. The association is likely to appeal. Read the court decision
Read the full story...
Reprinted courtesy of

'You're Talking About Lives': The New Nissan Stadium

August 26, 2024 — Grace Austin - Construction Executive
The new Tennessee Titans sports complex rising up on the banks of the Cumberland River in Nashville is a big project no matter how you look at it. Nissan Stadium will have 60,000 seats, cover 1.85 million square feet and cost an estimated $2.1 billion. Four contractors are involved, operating under a joint venture called the Tennessee Builders Alliance: Turner Construction Co., AECOM Hunt, Polk & Associates Construction and I.C.F. Builders & Consultants. And nearly 20,000 workers will play a role over the project’s three-year timeline. The sheer size and scope of the job led Tyler White, TBA’s environmental health and safety director, to think that the project needed to approach safety on a similar scale. The result is a first-of-its-kind public-private partnership between the Tennessee Occupational Safety and Health Administration and TBA. “I thought it would be a good idea,” White says. “I know they’re stretched thin, but [we’re] very appreciate of advocating and allocating their resources.” Reprinted courtesy of Grace Austin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Ten Years After Colorado’s Adverse Possession Amendment: a brief look backwards and forwards

September 25, 2018 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
In response to national outrage over an infamous adverse possession case in Boulder, Colorado, in which a lawyer and a judge intentionally took their neighbors’ undeveloped land through adverse possession, the Colorado legislature amended the state’s adverse possession statute (C.R.S. § 38-41-101) to make the claim significantly harder to prove. It did this because it believed “there were insufficient ‘obstacles’ to establishing a claim for adverse possession under the existing law.”[1] Effective July 1, 2008, the amendment created a heightened burden of proof, additional element requirements, and the possibility of a losing defendant recovering money from successful plaintiffs for the value of the land they took and the taxes the defendant had paid on that land. The Boulder case eventually settled, but the resulting statutory amendments have drastically changed the landscape of Colorado’s adverse possession law. Ten years later, this blog post takes a brief look at the amended statute, the impact it has had, and questions that have yet to be resolved. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Update: New VOSH Maximum Penalties as of July 1

July 26, 2017 — Christopher G. Hill - Construction Law Musings
As those who read Construction Law Musings know, as a construction attorney, I want to assure that not only are my clients successful in their litigation/dispute resolution endeavors, but that they stay out of trouble. I take my problem solving and advising roles quite seriously. As part of this role as advisor, I want to let those that read Musings know that as of July 1, 2017 the Virginia Occupational Safety and Health Administration increased their maximum penalties for safety violations. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Reminder: Your MLA Notice Must Have Your License Number

November 26, 2014 — Christopher G. Hill – Construction Law Musings
Remember a couple of years ago when the Virginia mechanic’s lien rules changed to require inclusion of a claimant’s contractor’s license number (where a license is required)? If not, then this is a reminder of that particular wrinkle in the strictly interpreted mechanic’s lien statute. This requirement applies to all mechanic’s lien memoranda and, like all parts of this crazy statute, will invalidate a lien if not met. Well, another change to the statute happened with a bit less fanfare. The change back in 2013 that came along with the license number requirement for a lien memorandum is a change in the mechanic’s lien agent notice requirement that applies to residential construction. The basic requirement, namely that those performing residential construction must notify any mechanic’s lien agent (“MLA”) listed on a building permit within 30 days of starting work that they are on the job and could file a lien, has not changed. What the amendments to the lien statutes in 2013 added was a requirement that the notice, like a lien memorandum, must include the contractor’s or subcontractor’s license number. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Colorado Supreme Court Grants the Petition for Writ of Certiorari in Vallagio v. Metropolitan Homes

June 22, 2016 — David M. McLain – Colorado Construction Litigation
We have previously reported on the Vallagio v. Metropolitan Homes case, in which the Colorado Court of Appeals upheld a provision in an association's declaration of covenants, conditions, and restrictions, which required declarant consent before an arbitration provision could be amended out of the document. To read the past articles on the case, please review Vallagio v. Metropolitan Homes: The Colorado Court of Appeals' Decision Protecting a Declarant’s Right to Arbitration in Construction Defect Cases and The Vallagio HOA Appeals the Decision from the Colorado Court of Appeals. Today, the Colorado Supreme Court granted the association's petition for writ of certiorari, en banc, on the following reframed issues:

Whether the court of appeals erred by holding as a matter of first impression that Colorado’s Common Interest Ownership Act (“CCIOA”) permits a developer-declarant to reserve the power to veto unit owner votes to amend common interest community declarations.

Read the court decision
Read the full story...
Reprinted courtesy of David M. McClain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McClain may be contacted at mclain@hhmrlaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES