Fairfield Connecticut Building Expert Directory

Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims

August 26, 2024 — David M. McLain – Colorado Construction Litigation
In the case of Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners (2024 COA 78), the Colorado Court of Appeals reviewed a complex contract dispute related to the design and construction of a transit rail line. The project, commissioned by the Regional Transportation District (“RTD”), involved a collaboration between Regional Rail Partners and Ralph L. Wadsworth Construction Company (“Wadsworth”) to build the North Metro Rail Line between Denver Union Station and Thornton. Key Facts:

Contracts and Payments: Regional Rail Partners contracted with Wadsworth to perform specific construction tasks with a total contract value of $60,210,783. By the time of the trial, Regional Rail had paid almost $58 million of this amount.
Disputes and Delays: The project faced numerous delays and disputes, leading to Wadsworth claiming significant financial damages attributed to these disruptions. In April 2018, Wadsworth’s expert estimated that Regional Rail owed them $12,408,496.60.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

General Contractor Gets Fired [Upon] for Subcontractor’s Failure to Hire Apprentices

September 23, 2024 — Garret Murai - California Construction Law Blog
As most public works contractors know, Labor Code section 1777.5 requires the hiring of apprentices on public works projects and, under Labor Code section 1777.7, violations are subject to civil penalties of up $100/day and up to $300/day days for repeated violations within a three-year period. In Lusardi Construction Co. v. Dept. of Industrial Relations, 102 Cal.App.5th (2024), a prime contractor learned the hard way that not only could it be penalized for its failure to hire apprentices but that it could also be liable for its subcontractor’s failure to hire apprentices. Forewarned is to be forearmed. The Lusardi Construction Case In 2014, general contractor Lusardi Construction Company hired subcontractor Pro Works Contracting to perform iron reinforcing work on a public works project owned by the San Marcos Unified School District. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Homeowner's Claim for Collapse Survives Summary Judgment

September 20, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The insurer failed to present adequate evidence on summary judgment that damage caused by the collapse of a swimming pool was not covered. Klein v. State Farm Ins. Co., 2017 N.Y. Misc. LEXIS 3030 (Sup. Ct. N.Y. July 11, 2017). Klein notified State Farm that his in-ground pool collapsed on February 5, 2014, with a side wall falling into the pool, causing damage to brick, borders and the patio around the pool. Upon inspection, State Farm's agent found that the cover of the pool had partially fallen into the pool, and that the vinyl pool liner had a tear. State Farm covered the damage to the pool liner, but denied coverage for the in-ground swimming pool walls, the brick border and the patio surrounding the pool. State Farm maintained that the loss was due to a "collapse," which was excluded under the homeowner's policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Remote Trials Can Control Prejudgment Risk

September 07, 2020 — Robert G. Devine, Victor J. Zarrilli & Kimberly M. Collins - White and Williams LLP
While courts across the country are largely unavailable to litigants demanding a jury trial, pre-judgment interest rules present an increasing penalty risk to a defendant wanting its day in court and may not always make a plaintiff whole. The COVID-19 pandemic has altered the manner in which people and industries operate across the board. In light of the need to maintain social distancing whenever possible, the use of technology to replace in-person appearances is becoming more commonplace. As more attorneys become comfortable with the remote platform, the willingness to consider a remote trial grows. With in-person jury trials suspended until further notice, it is important for attorneys and parties to consider the attendant consequences of the indefinite delay in waiting for a traditional jury trial. Aside from general inconvenience, continued delays may have a substantial financial impact, particularly with regard to the accumulation of pre-judgment interest. Reprinted courtesy of White and Williams LLP attorneys Robert G. Devine, Victor J. Zarrilli and Kimberly M. Collins Mr. Devine may be contacted at deviner@whiteandwilliams.com Mr. Zarrilli may be contacted at zarrilliv@whiteandwilliams.com Ms. Collins may be contacted at collinsk@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

The Real Estate Crisis in North Dakota's Man Camps

October 02, 2015 — Jennifer Oldham – Bloomberg
Chain saws and staple guns echo across a $40 million residential complex under construction in Williston, North Dakota, a few miles from almost-empty camps once filled with oil workers. After struggling to house thousands of migrant roughnecks during the boom, the state faces a new real-estate crisis: The frenzied drilling that made it No. 1 in personal-income growth and job creation for five consecutive years hasn’t lasted long enough to support the oil-fueled building explosion. Civic leaders and developers say many new units were already in the pipeline, and they anticipate another influx of workers when oil prices rise again. But for now, hundreds of dwellings approved during the heady days are rising, skeletons of wood and cement surrounded by rolling grasslands, with too few residents who can afford them. Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Oldham, Bloomberg

Property Insurance Exclusion: Leakage of Water Over 14 Days or More

July 10, 2018 — David Adelstein - Florida Construction Legal Updates
The recent opinion of Whitley v. American Integrity Ins. Co. of Florida, 43 Fla.L.Weekly D1503a (Fla. 5th DCA 2018), as a follow-up to this article on the property insurance exclusion regarding the “constant or repeated seepage or leakage of water…over a period of 14 or more days,” is a beneficial opinion to insureds. In this case, the insured had a vacation home. A plumbing leak occurred that caused water damage to the home. The plumbing leak occurred during a period of time that lasted approximately 30 days. For this reason, the property insurer denied the claim per the exclusion that the policy does not cover loss caused by repeated leakage of water over a period of 14 or more days from a plumbing system. Summary judgment was granted by the trial court in favor of the insurer based on this exclusion. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Colorado SB 15-177 UPDATE: Senate Business, Labor, & Technology Committee Refers Construction Defect Reform Bill to Full Senate

April 01, 2015 — Derek J. Lindenschmidt – Higgins, Hopkins, McLain & Roswell, LLC
On March 18th, following a lengthy hearing with testimony and questioning for and against Senate Bill 15-177, the Senate Business, Labor & Technology Committee voted 6 to 2 to refer the bill, with new amendments, to the full Senate. While the main points of the bill remain strongly intact (check here for Senate Bill 177’s particulars), bill sponsors Senators Scheffler and Ulibarri offered four amendments, designed to bring additional compromise and clarity to the bill. The committee ultimately adopted these amendments, described below. Amendment 16 removed a prior prohibition in the bill that would have prevented attorneys from assisting in the preparation of the notice required to be provided to all homeowners before the commencement of a construction defect claim. Amendment 19 complemented 16 by providing further clarification regarding the contents and specificities required in said notice, including a disclosure of projected attorneys’ fees, costs, duration, and financial impact of pursuing construction defect claims. Amendment 17 permitted homeowners to approve the pursuit of construction defect claims through written consent. Lastly, Amendment 18 provided clarification regarding the bill’s requirement that mediators and arbitrators be selected and approved through mutual agreement of the parties. Read the court decision
Read the full story...
Reprinted courtesy of Derek J. Lindenschmidt, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Lindenschmidt may be contacted at lindenschmidt@hhmrlaw.com

Chattanooga Bridge Collapse Likely Resulted From Impact

April 17, 2019 — Jim Parsons - Engineering News-Record
Tennessee highway officials believe an impact from a vehicle’s oversized load is likely to blame for the April 1 partial collapse of a ramp structure at the I-75/I-24 interchange in Chattanooga. The impact caused the outer box beam and railing of the 148-ft-long bridge’s nearly 51-ft main span to fall onto an access ramp, injuring a motorist whose vehicle collided with the debris. Read the court decision
Read the full story...
Reprinted courtesy of Jim Parsons, ENR
ENR may be contacted at ENR.com@bnpmedia.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES