Fairfield Connecticut Building Expert Directory

Construction Defect or Just Punch List?

December 11, 2013 — CDJ STAFF
A couple in Dickinson, North Dakota have put big, green “buyer beware” signs on their home. They’re not planning on selling, but just trying to warn prospective neighbors of the problems they’ve had since moving into their new home. Andrea Thermes said her problems included leaking windows and uneven floors. “I absolutely love my house,” she said. “If we didn’t have the issues, I would be the happiest girl in the world.” One problem was a leaking picture window in her living room. The builder replaced it, but the first window that arrived was the wrong size. The new home is still under a warranty and the builder has been fixing issues as they arise. “They are upset with some of the problems they have had,” said William Henry, president of B-Dev, the builder of the home. Since Ms. Thermes’s window wasn’t repaired in time for Thanksgiving, Mr. Henry sent wine and beer to her home. “Not that that makes up for not having their window, but we’re trying to make this work and trying to appease them,” he said. But Mr. Henry said that some of the problems “are not really material defects,” characterizing them as “punch-list and warranty items.” Read the court decision
Read the full story...
Reprinted courtesy of

The One New Year’s Resolution You’ll Want to Keep if You’re Involved in Public Works Projects

January 07, 2015 — Garret Murai- California Construction Law Blog
New Year’s resolutions are hard to keep. In fact, studies (which I have a sneaking suspicion may have been paid for by the tobacco, donut and vacation timeshare lobbies) have found that only 8% of New Year’s resolutions are kept. But, here’s one you’ll want to make sure you keep. Mandatory Registration and Notice Requirements If you’re a public works contractor or subcontractor you only have until March 1, 2015 to register through the California Department of Industrial Relations (“DIR”) to bid and enter into public works contracts on state and local public works projects. And if you’re a state or local public agency you must provide notice of the DIR’s new registration requirements in all call for bids and contract documents beginning January 1, 2015. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Construction Defects Are Not An Occurrence Under New York, New Jersey Law

June 18, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The New York Supreme Court, Appellate Division, determined there was no coverage for construction defects under New York or New Jersey law. Nat'l Union Fire Ins. Co. of Pittsburgh, PA v. Turner Constr. Co., 2014 N.Y. App. Div. LEXIS 3546 (N.Y. App. Div. May 15, 2014). The property owner retained Turner Construction to serve as the general contractor. Turner subcontracted with Permasteelisa North America Corporation to design and build the exterior wall, a "curtain wall," which consisted of granite and glass. A segment of the pipe rail system fell to the street from the eighth floor of the building. An investigation determined that more than 20% of the pipe rail connections surveyed did not conform to the building plans. Additional problems included inconsistencies in the method of rail attachment, bent brackets on the pipe rail system, cracked glass louvers, cracked glass panels, and water infiltration. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

California to Require Disclosure of Construction Defect Claims

October 30, 2013 — CDJ STAFF
California Governor Jerry Brown has signed Senate Bill 625. Starting in July 2014, anyone who sells a home will have to disclose all claims made of construction defects and the status of these claims. Read the court decision
Read the full story...
Reprinted courtesy of

Subcontractor Strikes Out in its Claims Against Federal Government

July 08, 2024 — David Adelstein - Florida Construction Legal Updates
Is it a good idea for a subcontractor to sue the federal government? A recent case would suggest NO–way too many huge hurdles for the subcontractor to overcome. No matter how creative the arguments may be, it’s a high mountain to climb. In Fox Logistics & Construction Co. v. U.S., 2024 WL 2807677 (Fed.Cl. 2024), a subcontractor sued the federal government when it was not paid by the prime contractor. The subcontractor claimed it was a third-party beneficiary under the government’s modifications to the prime contractor’s payment procedure, or alternatively it had an implied-in-fact contract with the government. The Court of Federal Claims granted summary judgment in favor of the government. The subcontractor, while creative, struck out in its claims based on the hurdles in a subcontractor suing the federal government. This case involved upgrading an air force base. The subcontractor performed most of the work. The prime contractor had cash flow problems and did not pay the subcontractor. The government got involved to enforce provisions of its contract to force the prime contractor to pay subcontractors and even modified the payment procedure by having future payments to the prime contractor deposited into a new bank account that government could monitor. This ultimately did not work, and the prime contractor filed for bankruptcy. The subcontractor claimed it was owed millions–apparently, it was not able to recover the money through the prime contractor’s bankruptcy—and pursued claims against the federal government in an effort to recover money it was owed. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Hennigh Law Corporation Wins Award Against Viracon, Inc In Defective Gray PIB Case

July 11, 2022 — Scott Hennigh - Hennigh Law Corporation
LOS ANGELES, July 08, 2022 (GLOBE NEWSWIRE) -- Hennigh Law Corporation has announced that, after an over four-year battle in and out of court, a three arbitrator panel issued a 93-page interim award in finding Viracon, Inc., liable for $13,682,840 in direct damages for defrauding the owner of the premier office building in Burbank, California, The Pointe. The matter now enters the second phase, where the arbitration panel will rule on the amount of punitive damages to assess, as well as attorney fees and interest. Scott Hennigh, trial attorney, states, "The California construction industry is very robust with high standards. The arbitration panel appears to have recognized that California law does not tolerate large out-of-state companies misleading customers. They appear poised to send a message to Viracon about its lack of corporate responsibility." The premier Class-A office building in Burbank, California, The Pointe, serves high-end tenants in entertainment industries such as Warner Brothers. Constructed in 2009, the 13 exterior curtain wall of the 13-story building is encased in seamless glass panels. Read the court decision
Read the full story...
Reprinted courtesy of Scott Hennigh, Hennigh Law Corporation
Mr. Hennigh may be contacted at Scott.hennigh@hennighlaw.com

Storm Eunice Damage in U.K. Could Top £300 Million

February 28, 2022 — Press Association - Bloomberg
Hundreds of thousands of homes are still without power due after Storm Eunice tore through the country, while insurers have indicated the clean-up could cost more than £300 million. At least four people were killed in the UK and Ireland during one of the worst storms in decades, with a gust of 122mph provisionally recorded at the Needles on the Isle of Wight, which, if verified, would be the highest ever recorded in England. Energy Networks Association (ENA) has said nearly 400,000 homes had no electricity on Friday night, with network providers recording 156,000 disrupted customers for UK Power Networks, 120,000 for Scottish & Southern, 112,000 for Western Power, 6,000 for Northern Power and 260 for Electricity North West. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES