Cambridge Massachusetts Building Expert Directory

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Nevada Assembly Passes Construction Defect Bill

October 30, 2013 — CDJ STAFF
The Nevada Speaker says that AB401 gives contractors what they want, but a contractors’ group has asked a Senate committee to kill the bill. Supporters of AB 401 say that it clarifies what qualifies as a construction defect and shortens the statute of limitations. Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (06/28/23) – Combating Homelessness, U.S. Public Transportation Costs and the Future of Commercial Real Estate

August 07, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, we examine the Supreme Court’s ruling regarding water supply responsibilities, the federal reserve chair’s reaction to possible banking losses, several analyses of the future of commercial real estate, and more!

California Representative Maxine Waters has introduced several pieces of legislation aimed at combating homelessness and fixing the increasingly tumultuous affordable housing situation. (Eliza Relman, Business Insider)
The Supreme Court ruled in favor of the federal government in a case that decided responsibility over water supply as well as the overall dissemination of water usage for the Navajo Nation. (Ariane de Vogue, CNN)
Unlike other nations with similar construction, the United States’ public transportation has extremely high costs. (Darian Woods, Corey Bridges, Viet Le, NPR)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Construction Defect Lawsuits Hinted for Dublin, California

February 07, 2013 — CDJ STAFF
Without naming the community, the blog Around Dublin says that a condo community in Dublin, California may be prepping for a construction defect lawsuit. According to the article, the problems include a façade peeling away from the building, cracks in walls and granite countertops, and issues with both the HVAC systems and the plumbing. The homeowners association is said to have insufficient reserve funds to address the problems. Read the court decision
Read the full story...
Reprinted courtesy of

Digitalizing the Hospital Design Requirements Process

April 02, 2019 — Aarni Heiskanen - AEC Business
Decisions made at the early stages of a hospital project can have a huge impact on its life cycle value. To make sure that a hospital will be a good investment, its future users should be involved in helping set out the design requirements. A Finnish team of experts wanted to see if they could improve the process and set up an experiment to see how it could be done digitally. Currently, over one billion euros are budgeted to hospital construction and renovation in Finland. Globally, the sum is around US$400 billion. You would imagine that the design for such large investments would be very efficient from the start. Unfortunately, that is not the case. During the design phase, doctors, specialists, nurses, and other stakeholders take part in workshops in which they express their needs and requirements. For a large hospital project, 40 to 100 workshops are the norm. The work is done with a variety of tools, with sticky notes being the predominant technique. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Property Damage, Occurrences, Delays, Offsets and Fees. California Decision is a Smorgasbord of Construction Insurance Issues

November 15, 2017 — Garret Murai - California Construction Law Blog
I read once that 97 percent of cases never go to trial. However, there are still the ones that do. And, then, there are the ones that do both. The following case, Global Modular, Inc. v. Kadena Pacific, Inc., California Court of Appeals for the Fourth District, Case No. E063551 (September 8, 2017), highlights some of the issues that can arise when portions of cases settle and other portions go to trial, the recovery of delay damages on a construction project through insurance, and the recovery of attorneys’ fees. Global Modular, Inc. v. Kadena Pacific, Inc. The U.S. Department of Veterans Affairs contracted with general contractor Kadena Pacific, Inc. (Kadena) to oversee construction of its Center for Blind Rehabilitation in Menlo Park, California. Kadena, in turn, contracted with subcontractor Global Modular, Inc. (Global) to construct, deliver and install 53 modular units totaling more than 37,000 square feet for a contract price of approximately $3.5 million. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Former SNC-Lavalin CEO Now Set for Trial in Bribe Case

December 11, 2018 — Debra K. Rubin - Engineering News-Record
Pierre Duhaime, the former CEO of Canadian design-build giant SNC-Lavalin—who resigned from the firm in 2012 in the wake of a contracting bribery scandal in which he was arrested for his alleged role—is now set for a February trial start in Quebec Superior Court. The case relates to payoffs on one project, a multibillion-dollar Montreal hospital on which the firm led the public-private construction consortium. Read the court decision
Read the full story...
Reprinted courtesy of Debra K. Rubin, ENR
Ms. Rubin may be contacted at rubind@enr.com

Preserving Lien Rights on Private Projects in Washington: Three Common Mistakes to Avoid

September 16, 2024 — Kristina Southwell - Ahlers Cressman & Sleight PLLC
The Washington Construction Lien Statute, RCW 60.04 et seq., exists to help secure payment for work performed for the improvement of real property.[1] The statute grants “any person furnishing labor, professional services, materials, or equipment for the improvement of real property” the authority to claim “a lien upon the improvement for the contract price of labor, professional services, materials, or equipment furnished.” RCW 60.04.021. Exercising lien rights is one of the most useful tools available to a contractor or supplier trying to recover payment owed on a project. A properly recorded lien binds the project property, which is typically the most valuable asset held by the owner, as security for the amounts owed to the lien claimant. Additionally, the lien statute provides a basis for the claimant to recover the costs of recording the lien and its attorneys’ fees and expenses incurred in litigating the foreclosure of the lien. While the lien statute authorizes the right to lien, it also provides a series of strict requirements and procedures that a claimant must follow to properly exercise its rights. The claimant must carefully comply with all statutory requirements. This article does not endeavor to explain all the intricacies of the lien statute, but rather discusses three of the most common mistakes that result in the loss of lien rights. See our lien and bond claim manual for a more detailed guide to construction liens in Washington. Read the court decision
Read the full story...
Reprinted courtesy of Kristina Southwell, Ahlers Cressman & Sleight PLLC
Ms. Southwell may be contacted at kristina.southwell@acslawyers.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES