Contract Disruptions: Navigating Supply Constraints and Labor Shortages
January 24, 2022 —
Greg Ross & Tim Lynch - Construction ExecutiveThe biggest worries in today’s economy—supply chain disruptions, labor shortages and the worst inflation in decades—are creating big headaches in the construction industry. What’s worse, large projects underway are often based on contracts hammered out pre-pandemic, before the uncertainties and disruptions that spread around the globe with COVID-19. Construction firms find themselves executing on contracts signed when the potential for delayed timelines and rising costs seemed more remote.
A recent report from the U.S. Chamber of Commerce finds almost all contractors (93%) say they are experiencing a shortage of an important product such as steel, lumber or copper. A rising number of companies on commercial projects (54%) also cite difficulty finding skilled workers. Grant Thornton clients, among them some of the country’s biggest construction companies, report that sourcing materials and hiring workers is a bigger challenge today—and more expensive—than at any other time in recent decades.
Reprinted courtesy of
Greg Ross and Tim Lynch, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
BHA at the 10th Annual Construction Law Institute, Orlando
January 13, 2017 —
Don MacGregor - Bert L. Howe & Associates, Inc.Bert L. Howe & Associates, Inc. is once again proud to be partnering with the Florida Bar Continuing Legal Education Committee and the Construction Law Committee of the Florida Bar Real Property, Probate and Trust Law Section, as a sponsor and exhibitor at the 10th Annual Construction Law Institute to be held March 16th, 17th & 18th, 2017 at the JW Marriott Orlando Grande Lakes in Orlando.
With offices in Miami serving all of Florida, Bert L. Howe & Associates, Inc. (BHA) offers the experience of over 20 years of service to carriers, defense counsel, and insurance professionals as designated experts in nearly 6,500 cases. BHA’s staff encompasses a broad range of licensed and credentialed experts in the areas of general contracting and specialty trades, as well as architects, and both civil and structural engineers, and has provided services on behalf of developers, general contractors and sub-contractors.
BHA’s experience covers the full range of construction and construction defect litigation, including single and multi-family residential (including high-rise), institutional (schools, hospitals and government buildings), commercial, and industrial claims. BHA specializes in coverage, exposure, premises liability, and delay claim analysis as well.
As the litigation climate in Florida continues to change, and as the number of construction defect and other construction related cases continues to rise, it is becoming more important for contractors and builders here to be aggressive in preparing for claims before they are made, and in defending against those claims once they are filed. Since 1993, Bert L. Howe & Associates has been an industry leader in providing construction consulting services, and has been a trusted partner with builders and insurance carriers, both large and small, across the Western and Southern United States. Here in Florida, we have been providing construction defect and construction-claims related forensic expert services for the past decade with a proven track record of successful results.
For those of you planning on attending the conference, or those who may know someone who will be, we encourage you to stop by the BHA booth and we welcome the opportunity to discuss further the broad range of services provided by BHA.
For your convenience, when registration information is made available, a link to the 10th Annual Construction Law Institute should be available here: http://www.rpptl.org/
Read the court decisionRead the full story...Reprinted courtesy of
Don MacGregor, Bert L. Howe & Associates, Inc.Mr. MacGregor may be contacted at
dmac@berthowe.com
The Practical Distinction Between Anticipatory Breach and Repudiation and How to Deal with Both on Construction Projects
June 10, 2024 —
Devon Griger - ConsensusDocsWhen a multilevel construction project is underway and a contractor or subcontractor isn’t performing as expected, it can be difficult to know how to address the low performance without putting the parties’ contract and good working relationship at risk. However, there may come a time when poor performance lapses into a something much worse: an anticipatory breach or repudiation of the subject contract.
Imagine Scenario One: You are a general contractor managing a large-scale construction project and one of your subcontractors is falling behind on their work. The project manager for the subcontractor calls you and says, “Look, I don’t think we’re going to be able to hit our next milestone, and probably not the next one after that.” A conversation like this would generally trigger concern for most general contractors, but it would not necessarily invoke panic. These types of delay conversations are not uncommon on large scale projects.
Compare that example, however, with Scenario Two, where the subcontractor instead says, “We received an offer to work another job for much more money, so we’re leaving the project site today and will not be returning.” This is obviously different (and potentially worse) than Scenario One, and likely cause for much greater concern.
Read the court decisionRead the full story...Reprinted courtesy of
Devon Griger, Jones WalkerMs. Griger may be contacted at
dgriger@joneswalker.com
Mechanic’s Liens- Big Exception
January 22, 2024 —
Christopher G. Hill - Construction Law MusingsMusings has discussed mechanic’s liens on
numerous occasions.
As we discussed in earlier posts, the general rule is that a
mechanic’s lien jumps to the head of the line of liens when filed. This is true in most instances. In the typical case, a contractor puts up a building and, when the owner refuses payment, it files a mechanic’s lien that takes priority over all other liens on that property, including the construction loan
deed of trust (or
mortgage, depending on your state’s property laws).
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Construction Contract Language and Insurance Coverage Must Be Consistent
July 30, 2015 —
Craig Martin – Construction Contract AdvisorHow often do you review both the additional insured language in the contract and the insurance policy provided by a subcontractor? My guess is, unless the project has gone off the rails, NEVER. Well, perhaps you should to make absolutely sure the extent of the subcontractor’s insurance obligations and whether those obligations are being fulfilled.
This point was recently addressed in a recent DRI article analyzing the Deepwater Horizon/BP lawsuit. My partner, Anne Marie O’Brien, also blogged on this a few months ago.
As you will recall, Transocean’s Deepwater Horizon oil-drilling rig exploded, killing 11 workers, and polluted the Gulf of Mexico. BP demanded that Transocean’s insurer pay for the loss. Transocean’s insurer said no, and the litigation ensued, in state court, federal court, and the Texas Supreme Court. It was quite an odyssey of litigation.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
When Construction Defects Appear, Don’t Choose Between Rebuilding and Building Your Case
October 11, 2021 —
Curtis Martin - ConsensusDocsWhen construction defects occur during construction, they intensify pressure from a schedule that may already be tight. Defects must be analyzed, confirmed, removed, and replaced and this can be time consuming. Or course, a construction schedule rarely anticipates defects, demolition, and rework and the owner will still expect the project to be completed on time; however, pressing forward with immediate remediation may have unintended consequences.
Before starting demolition, consider the evidentiary doctrine of spoliation. Spoilation occurs when a party destroys or unreasonably deprives another party of evidence and courts have imposed sanctions on a party that deprives an opponent of evidence. The doctrine has historically concerned documents, but its application has extended to electronic data, and courts also apply it to building conditions in construction defects cases. So, before tearing out or fixing defective work, consider the need to allow the opposing party to inspect, test and document it.
Imagine this scenario. The concrete in a slab placed by your subcontractor shows low compressive strength results in the 28-day cylinder tests. Tearing out the slab and replacing it will put you at least a month behind schedule and you don’t want to waste any time before removing and replacing it. Nevertheless, while you’re rebuilding the defective slab, be mindful that you are also building a case. If you plan to recover the costs you incur because of the defective concrete from the responsible parties, you should allow the subcontractor (and possibly the concrete supplier and other implicated parties) to examine, preserve, and/or test the work in question. Failure to do so may subject you to spoliation sanctions and jeopardize your right to recover damages.
Read the court decisionRead the full story...Reprinted courtesy of
Curtis Martin, Peckar & AbramsonMr. Martin may be contacted at
cmartin@pecklaw.com
Insurers' Motion to Determine Lack of Occurrence Fails
August 19, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court, interpreting Massachusetts law, found there were genuine issues of fact as to whether the insured's mixing of biodiesel with home heating fuel was an occurrence. United States Fire Ins. Co. v. Peterson's Oil Serv., Inc., 2024 U.S. Dist. LEXIS 106980 (D. Mass. June 17, 2024).
Homeowners sued Peterson's Oil Service, alleging that Peterson sold them fuel for home heating which contained more that 5% biodiesel. The homeowners further alleged that fuel containing more than 5% biodiesel did not meet industry standards and caued damage to their home heating equipment. Peterson allegedly did not fully disclose the presence of biodiesel in their fuel, despite knowing the risk posed by high-biodiesel blended fuel.
The insurers, United States Fire Insurance Company and The North River Insurance Company, defended Peterson under a reservation of rights. United States Fire issued priomary policies with limits of $1,000,000 per occurrence and $2,000,000 as a general aggregate limit. An endorsement titled "Limited Coverage - Failure to Supply" limited the amount covered for "property damage arising out of the failure of any insured to adequately supply gas, oil, water, electricty or steam" to $250,000. North River issued umbrella policies with additional coverage in the amount of $15,000,000 per occurrnce and in the aggregate if property damage was caused by an occurrence. The umbrella policies also contained a "Failure to Supply Exclusion" which excluded coverage for "property damage arising out of the failure of an insured to adequately supply gas, oil, water, electricty or steam."
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
No Repeal Process for Rejected Superstorm Sandy Grant Applications
February 12, 2014 —
Beverley BevenFlorez-CDJ STAFFEven though it’s been revealed that “faulty data” was used to reject many New Jersey recovery grants for victims of Superstorm Sandy, the state has announced that it’s too late to appeal, according to The Wall Street Journal.
“The applicants were informed by letter that they weren't eligible,” state officials told The Wall Street Journal, “and it should have been clear that they needed to appeal last year, so the application process won't be reopened.”
The majority of the rejected applicants that did appeal within the open period were found to be eligible for the grant: “Nearly 80% of people who appealed their rejections ended up winning their cases, according to data released by the Fair Share Housing Center, a public-interest law firm critical of the Christie administration. And of the 8,007 applicants rejected from both programs, 5,583 didn't appeal, or 70%, according to Fair Share Housing Center's analysis.”
U.S. Representative Bill Pascrell called for “an independent monitor” to be “appointed to oversee the state’s storm spending ‘to ensure there isn’t further mismanagement.’”
Read the court decisionRead the full story...Reprinted courtesy of
