Fairfield Connecticut Building Expert Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Ambiguous Application Questions Preclude Summary Judgment on Rescission Claim

July 19, 2017 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Duarte v. Pacific Specialty Ins. (No. A143828; filed 6/12/17, ord. pub. 6/29/17) a California appeals court held that an insurer was not entitled to summary judgment on its rescission claim because the disputed questions in the insurance application were ambiguous. In Duarte, the insured/owner purchased a tenant-occupied property in Oakland. Several years later the tenant’s daughter moved in, and continued living there after the tenant died. The insured/owner served the daughter with an eviction notice and shortly thereafter applied for Owners, Landlords & Tenants (“OLT”) liability coverage. The tenant/daughter responded to the eviction notice by filing a habitability lawsuit, claiming emotional distress and physical injury, among other things. The insurer denied coverage and a defense, drawing a bad faith lawsuit for failure to defend and “wrongful cancellation” of the policy. The insurer answered and raised rescission as an affirmative defense, based on alleged fraud and misrepresentation in the OLT policy application. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

California Contractors – You Should Know That Section 7141.5 May Be Your Golden Ticket

February 18, 2020 — Amy L. Pierce, Mark A. Oertel & John Lubitz - Lewis Brisbois Bisgaard & Smith LLP
Under California’s Contractors’ State License Law, Cal. Bus. & Prof. Code §§ 7000 et seq., all contractors’ and subcontractors’ licenses expire two years from the last day of the month in which the license issued, or two years from the date on which the renewed license last expired. The Contractors State License Board (CSLB) sends licensees a renewal application 60 to 90 days prior to the date the license is set to expire. Most contractors have various controls in place to make sure that the renewal application is timely filed and the required fee paid. Even so, we are only human and mistakes are made, and a renewal application filing deadline can be missed for a variety of reasons, e.g., the licensee’s mailing address has not been updated on the CSLB’s records, the individual responsible for filing the license renewal is out on leave, there has been a death in the family or a serious health issue, etc. Quoting Robert Burns, even “[t]he best-laid schemes of mice and men go oft awry” (To a Mouse, 1786). General contractors should be cognizant of both their and their subcontractors’ license renewal obligations and deadlines. If a licensee missed timely filing its renewal application, Business & Professions Code Section 7141.5may provide some relief. Section 7141.5 provides that the Registrar of Contractors,

“may grant the retroactive renewal of a license if the licensee requests the retroactive renewal in a petition to the registrar, files an application for renewal on a form prescribed by the registrar, and pays the appropriate renewal fee and delinquency fee prescribed by this chapter. This section shall only apply for a period not to exceed 90 days from the due date and only upon a showing by the contractor that the failure to renew was due to circumstances beyond the control of the licensee.”

Reprinted courtesy of Lewis Brisbois Bisgaard & Smith LLP attorneys Amy Pierce, Mark Oertel and John Lubitz Ms. Pierce may be contacted at Amy.Pierce@lewisbrisbois.com Mr. Oertel may be contacted at Mark.Oertel@lewisbrisbois.com Mr. Lubitz may be contacted at John.Lubitz@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Two More Lawsuits Filed Over COVID-19 Business Interruption Losses

April 13, 2020 — Michael S. Levine - Hunton Andrews Kurth
Two more lawsuits were filed yesterday concerning business interruption losses resulting from the COVID-19 pandemic. The plaintiffs, the Chickasaw and Choctaw nations, filed their lawsuits, copies of which can be found here and here, in Oklahoma state court against a litany of property insurers, led by AIG. The lawsuits seek an order that any financial losses suffered by the nations’ casinos, restaurants and other businesses as a result of the coronavirus pandemic are covered by the nations’ insurance policies. According to the complaints:

On or about March of 2020, the United States of America became infected by COVID 19 resulting in a pandemic. As a result of this pandemic and infection, the Nation’s Property sustained direct physical loss or damage and will continue to sustain direct physical loss or damage covered by the policies, including but not limited to business interruption, extra expense, interruption by civil authority, limitations on ingress and egress, and expenses to reduce loss. As a direct result of this pandemic and infection, the Nation’s Property has been damaged, as described above, and cannot be used for its intended purpose.

Read the court decision
Read the full story...
Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth
Mr. Levine may be contacted at mlevine@HuntonAK.com

Vietnam Expands Arrests in Coffee Region Property Probe

February 19, 2024 — Mai Ngoc Chau - Bloomberg
Vietnam authorities detained the Communist Party chief of coffee-producing province Lam Dong as they expand an investigation into alleged bribery tied to a tourist and residential project, the public security ministry said in a website statement. Party chief Tran Duc Quan was arrested for allegedly abusing his power and position, according to the statement. Quan allegedly violated the law while giving instructions to the Dai Ninh property project in the province, causing severe consequences, it said. A Lam Dong Provincial Party Committee representative declined to provide a comment about the arrest. A representative for Quan was not available. Read the court decision
Read the full story...
Reprinted courtesy of Mai Ngoc Chau, Bloomberg

Environmental Suit Against Lockheed Martin Dismissed

August 13, 2014 — Beverley BevenFlorez-CDJ STAFF
A federal judge dismissed an environmental suit against Lockheed Martin, finding that contamination levels on the plaintiffs’ Moorestown, New Jersey properties were not high enough to pose a health threat, according to the New Jersey Law Journal. Two owners who live across the street from the plant had “sued under the Resource Conservation & Recovery Act, the Comprehensive Environmental Response, Compensation & Liability Act and various state statutes.” However, “while the suit was pending, the New Jersey Department of Environmental Protection raised the threshold for concentration levels of substances such as TCE and PCE to warrant additional testing.” Read the court decision
Read the full story...
Reprinted courtesy of

Thieves Stole Backhoe for Use in Bank Heist

July 31, 2013 — CDJ STAFF
You can do a lot with a backhoe, but maybe not use it for bank robbery. The New York Daily News wasn’t clear on how many were involved, but described them as “a brazen crew of bandits.” They stole a backhoe from a construction site and used it to pry an ATM from a bank. When they couldn’t get the ATM open, they jumped into a black SUV and left the scene. The bandits were engaging in a sort of ATM spree. They did manage to open two ATMs, each holding more than $7,000 in cash. They were less successful at their use of heavy machinery. In an earlier heist, they used a tow truck to try to remove an ATM, but the chain snapped and the bank’s alarm rang. The Daily News quotes one former tow truck driver who said that it was “stupid to use a tow truck.” In her experience, “those chains snap at any time.” Read the court decision
Read the full story...
Reprinted courtesy of

Construction Law Alert: Builder’s Alternative Pre-litigation Procedures Upheld Over Strong Opposition

April 01, 2014 — Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel, LLP
Last week, the Court of Appeal, Fifth Appellate District, was tasked with evaluating the enforceability of provisions in home purchase contracts containing alternative pre-litigation procedures which differ from the standard Right to Repair Act procedures. The Court of Appeal, in McCaffrey v. Superior Court of Fresno, et al. ultimately upheld the contractual provisions, and in overturning the trial court's decision, preserved the rights of builders to contract around certain requirements set forth in the Right to Repair Act. The McCaffrey Group, Inc. constructed single-family homes in a Fresno development. Plaintiffs consisted of 24 homeowners within the development who brought suit against McCaffrey for construction defects in their homes. The homeowners were comprised of three categories: (1) the original purchasers who bought their homes from McCaffrey before January 1, 2003 and had a 2001 version of McCaffrey's contract; (2) the original purchasers who bought their homes from McCaffrey on or after January 1, 2003 and signed a 2003 version of McCaffrey's contract; and (3) the subsequent purchasers who did not buy their homes directly from McCaffrey, but purchased their homes subject to either the 2001 or 2003 version of McCaffrey's home purchase agreement. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES