How the Cumulative Impact Theory has been Defined
November 30, 2020 —
David Adelstein - Florida Construction Legal UpdatesLargely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”).
To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Federal Judge Refuses to Limit Coverage and Moves Forward with Policyholder’s Claims Against Insurer and Broker
December 07, 2020 —
Michael S. Levine & Casey L. Coffey - Hunton Insurance Recovery BlogOn November 10, 2020, a New York federal judge dismissed an insurer’s counterclaims seeking to cap its exposure under a $15 million sublimit and an order estopping the policyholder from pursuing any additional amounts.
In February 2017, Plaintiff Pilkington North America, Inc. (Pilkington), suffered between $60 and $100 million in damage from a tornado that struck its glass manufacturing factory in Illinois. Pilkington sought coverage for its loss under a commercial property and business interruption policy issued by Defendant Mitsui Sumitomo Insurance Company (MSI). Pilkington also claimed its insurance broker, Aon Risk Services Central, Inc. (Aon), is liable for faulty advice provided while brokering the policy. Aon’s negligence allegedly gave way to MSI’s fraudulent revision of the insurance policy, which caused the losses from the tornado to not be fully compensable.
Pilkington’s fraud and faulty brokering claims stem from MSI’s revision of an endorsement contained in the policy. The revision changed the wording of a windstorm sublimit. Allegedly, Aon was informed by MSI of the changes and failed to inform Pilkington that the revision would substantially reduce coverage for windstorms, including tornados.
Read the court decisionRead the full story...Reprinted courtesy of
Michael S. Levine, Hunton Andrews KurthMr. Levine may be contacted at
mlevine@HuntonAK.com
David M. McLain to Speak at the CLM Claims College - School of Construction - Scholarships Available
July 28, 2016 —
David M. McLain – Colorado Construction LitigationI am happy to have been asked to serve as an instructor at this year's CLM Claims College – School of Construction, to be held at the Marriott Baltimore Waterfront in Baltimore, Maryland on Wednesday, September 7, 2016 through Saturday, September 10, 2016.
Overview of the 2016 School of Construction
Construction claims present myriad complexities in claim handling. Construction defect lawsuits are often multi-party cases with cross claims and third-party claims between and among the numerous defendants. Insurance coverage is intertwined and complex due to the interplay of primary, excess, wrap, and additional insurers for the numerous defendants. All this is further complicated by statutes and regulations, inconsistent case law and procedural peculiarities throughout the United States. The economic stakes are high as the damages claims can be in the multi-millions.
Read the court decisionRead the full story...Reprinted courtesy of
David M. McLain, Higgins, Hopkins, McLain & Roswell, LLCMr. McLain may be contacted at
mclain@hhmrlaw.com
Construction Reaches Half-Way Point on San Diego's $2.1 Billion Mid-Coast Trolley
May 06, 2019 —
Greg Aragon - Engineering News-RecordProject officials for the $2.1-billion Mid-Coast Trolley in San Diego recently celebrated the halfway point of construction. The event was held at the construction staging yard near the Voigt Drive Trolley station, where workers gather for their morning briefings.
Read the court decisionRead the full story...Reprinted courtesy of
Greg Aragon, ENRENR may be contacted at
ENR.com@bnpmedia.com
Hunton Insurance Lawyer, Adriana Perez, Selected to the National Association of Women Lawyers’ 2023 Rising List
March 27, 2023 —
Hunton Insurance Recovery BlogCongratulations to
Adriana Perez on her selection to the
National Association of Women Lawyers’ (NAWL) 2023 Rising List. Adriana is a member of Hunton Andrews Kurth’s national Insurance Recovery practice and is based in the Firm’s Miami, Florida office.
Hunton Insurance Recovery Partner, Michael Levine, commented on the enormous success the team has had in recent years, with recognitions like Adriana’s being emblematic of the team’s high caliber practice and visibility. Team Head, Syed Ahmad, added that the recognition is a tribute to Adriana’s growth as a young lawyer and her trajectory to become an industry leader.
Read the court decisionRead the full story...Reprinted courtesy of
Hunton Andrews Kurth LLP
Daily Construction Reports: Don’t Leave the Job Without Them
January 11, 2022 —
Patrick Barthet - Construction ExecutiveTrying to remember exactly what was done at a job site last week, last month or last quarter along with knowing who worked at the site is nearly impossible without a written, video or electronic record for reference. That’s why daily construction reports are so important.
Yet many contractors fail to create these reports. And those that do create them, may do it only at the beginning of a project or sporadically throughout the progress of a job, and generally only when they are reminded to do so. Daily reports only become truly effective when they are, in fact, done daily. Whether it is to help resolve a pending delay issue or clarify a job site access claim, or any number of other matters where what happened at the time is so critical, those daily construction reports should be completed daily.
Be Timely
The reason that daily reports are admissible in court (with corroborating testimony) is that they are interpreted as being recorded at or about the time the events in question occurred. Field managers should, therefore, write up these reports daily while the work is occurring or very soon thereafter to capture as accurate an account as possible. If these reports are not created until the end of the week or month, the information will not be as accurate and may not be as helpful in supporting a particular position.
Reprinted courtesy of
Patrick Barthet, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Barthet may be contacted at
pbarthet@barthet.com
The Secret to Success Is Doing Things a Little Bit Differently
November 16, 2020 —
Charlie Kimmel - Construction ExecutiveThroughout the 1960s and 1970s, Rick Barry made his mark on the world of college and professional basketball. He was a skilled small forward who averaged 37.4 points per game during his senior year at the University of Miami, and he was the second overall pick in the 1965 NBA draft. But he’s best remembered as a prolific free-throw shooter: he led the NBA in free-throw percentage for several consecutive years. When he retired in 1980, his free-throw percentage (.900) was the highest in NBA history.
So what was the secret to his success? He did things a little bit differently. While the vast majority of basketball players shoot overhand free throws, Barry was famous for his unorthodox underhanded shots. This technique was not only incredibly effective, but it also set him apart as a player and contributed to his popularity.
Construction companies can learn a lot from Barry’s strategy of doing things a little bit differently to achieve success. Most companies don’t need to worry about their employees’ free-throw techniques. But all of them need to set themselves apart from their competition and establish strong reputations in today’s highly competitive market.
Reprinted courtesy of
Charlie Kimmel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
California Supreme Court Confirms the Right to Repair Act as the Exclusive Remedy for Seeking Relief for Defects in New Residential Construction
February 22, 2018 —
Brenda Radmacher – Construction Law BlogThe California Supreme Court recently issued its decision on a critical issue in the residential construction industry – the claims for construction defects that a California homeowner can bring against a builder or seller of new residential properties in California.
Holding
In McMillin Albany v. The Superior Court of Kern County, the Court held that California’s Right to Repair Act (California Civil Code, sections 895, et seq.) (the “Act”) is the exclusive remedy for homeowners claiming defective construction of new residences in California.
Read the court decisionRead the full story...Reprinted courtesy of
Brenda Radmacher, Gordon & ReesMs. Radmacher may be contacted at
bradmacher@grsm.com