FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

SunEdison Gets Shinsei Bank Funding for Japan Solar Power Plant

March 12, 2015 — Ehren Goossens – Bloomberg
(Bloomberg) -- SunEdison Inc., a U.S. solar developer, got financing from Tokyo-based Shinsei Bank Ltd. for a large-scale project in the country. The 9.6-megawatt Tarumizu project on the southern Japanese island of Kyushu will power about 3,000 homes, Maryland Heights, Missouri-based SunEdison said Wednesday in a statement. The project is under construction and expected to be completed in September. Financial details weren’t disclosed. Read the court decision
Read the full story...
Reprinted courtesy of Ehren Goossens, Bloomberg
Mr. Goossens may be contacted at egoossens1@bloomberg.net

---

Housing Starts Plunge by the Most in Four Years

May 20, 2015 — Bloomberg
(Bloomberg) -- Housing starts plummeted in February by the most since 2011 as plunging temperatures and snow became the latest hurdles for an industry struggling to recover. Work began on 897,000 houses at an annualized rate, down 17 percent from January and the fewest in a year, the Commerce Department reported Tuesday in Washington. The pace was slower than the most pessimistic projection in a Bloomberg survey of 81 economists. “Today’s report leaves me a little concerned,” said Michelle Meyer, deputy head of U.S. economics at Bank of America Corp. in New York. “While the initial reaction is to dismiss much of the drop because of the bad weather, the level of home construction continues to be depressed.” Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg News

---

Aecmaster’s Digital Twin: A New Era for Building Design

May 06, 2024 — Aarni Heiskanen - AEC Business
I sat down with Anssi Auvinen, the CEO and founder of Finnish startup Aecmaster, to discuss the future of design and how the company plans to make it happen. Anssi envisions data-driven design as the next radical change in the AEC sector. Anssi Auvinen started working in the building industry as a 16-year-old construction worker. Since then, he has acquired two master’s degrees: structural engineering and architecture. During his career, Anssi has witnessed how the digitalization of the design sector has progressed, but the results for both designers and building owners could have been more impressive. That inspired him in 2019 to start up Aecmaster, a software and consulting firm that aims to fulfill the promise of digitalization. The company’s software product launched in January 2024. The need for digital twins Anssi states that you can’t say you own a building until you possess its digital assets, the digital twin. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Colorado’s Federal District Court Finds Carriers Have Joint and Several Defense Duties

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
An issue that has plagued builders in Colorado construction defect litigation is the difficulty of getting additional insured carriers to fully participate in the builder’s defense, oftentimes leaving the builder to fund its own defense during the course of the litigation. Many additional insurers offer a variety of positions regarding why they will not pay for fees and costs during the course of a lawsuit. Some insurers argue that, until after trial, it is impossible to determine its proper share of the defense, and therefore cannot make any payments until the liability is determined as to all of the potentially contributing policies. (This is often referred to as the “defense follows indemnity” approach.) Others may make an opening contribution to defense fees and costs, but fall silent as fees and costs accumulate. In such an event, the builder may be forced to fund all or part of its own defense, while the uncooperative additional insured carrier waits for the end of the lawsuit or is faced with other legal action before it makes other contributions. Recent orders in two, currently ongoing, U.S. District Court cases provide clarity on the duty to defend in Colorado, holding that multiple insurers’ duty to defend is joint and several. The insured does not have to go without a defense while the various insurers argue amongst themselves as to which insurer pays what share. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Release Of “Unknown” Claim Does Not Bar Release Of “Unaccrued” Claim: Fair Or Unfair?

July 15, 2019 — David Adelstein - Florida Construction Legal Updates
A general release of “unknown” claims through the effective date of the release does NOT bar “unaccrued” claims. This is especially important when it comes to fraud claims where the facts giving rise to the fraud may have occurred prior to the effective date in the release, but a party did not learn of the fraud until well after the effective date in the release. A recent opinion maintained that a general release that bars unknown claims does NOT mean a fraud claim will be barred since the last element to prove a fraud had not occurred, and thus, the fraud claim had not accrued until after the effective date in the release. See Falsetto v. Liss, Fla. L. Weekly D1340D (Fla. 3d DCA 2019) (“The 2014 [Settlement] Agreement’s plain language released the parties only from “known or unknown” claims, not future or unaccrued claims. Because there is a genuine issue of material fact as to whether the fraud claim had accrued — that is, whether Falsetto [party to Settlement Agreement] knew or through the exercise of due diligence should have known about the alleged fraud at the time the 2014 Agreement was executed — the trial court erred in granting summary judgment on those fraud claims.”). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Construction Spending Drops in March

May 10, 2013 — CDJ STAFF
Reuters reports that construction spending dropped by 1.7 percent in March, bringing it to the lowest level since August, more than wiping out February’s increase of 1.5 percent. Economists had predicted a mild gain of 0.7 percent. Spending fell due to a 4.1 percent drop in public construction projects, bringing it to its lowest in six and a half years. Read the court decision
Read the full story...
Reprinted courtesy of

---

Wisconsin Court Applies the Economic Loss Doctrine to Bar Negligence Claims for Purely Economic Losses

August 17, 2020 — Rahul Gogineni - The Subrogation Strategist
In Mech. Inc. v. Venture Elec. Contrs., Inc., No. 2018AP2380, 2020 Wisc. App. LEXIS 170, the Court of Appeals of Wisconsin, District Two, considered whether a party may bring a negligence claim for purely economic damages. In upholding the lower court, the appellate court found that a party is barred by the Economic Loss Doctrine from bringing a negligence claim for purely economic damages. Both parties involved in this action were subcontractors on a building project at the Great Lakes Research Facility for the University of Wisconsin-Milwaukee. As a result of Venture Electrical Contractors, Inc. (Venture) not paying for requested work, Mechanical, Inc. (Mechanical) sued Venture for $11,961.31. Venture, in turn, countersued in negligence for $1.1 million for costs incurred due to delays and untimely performance. Mechanical sought dismissal of the negligence claim based upon the Economic Loss Doctrine. Finding that the Economic Loss Doctrine applies to purely economic losses, the trial court dismissed Venture’s negligence claim. Venture appealed to the Court of Appeals of Wisconsin. Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

---