FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Triple Points to the English Court of Appeal for Clarifying the Law on LDs

July 01, 2019 — Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2Gavel
Can an employer recover liquidated damages (LDs) from a contractor if the contract terminates before the contractor completes the work? Surprisingly, heretofore, English law provided no clear answer to this seemingly straightforward question, and inconsistent case law over the past century has left a trail of confusion. Given the widespread use of English law in international construction contracts, this uncertainty had gone on far too long. The good news is that drafters of construction contracts throughout the world can now have a well-deserved good night’s sleep courtesy of the English Court of Appeal’s March 2019 decision in Triple Point Technology, Inc. v PTT Public Company Ltd [2019] EWCA Civ 230. The Triple Point case concerned the delayed supply by Triple Point (the “Contractor”) of a new software system to employer PTT. The contract provided for payments upon achievement of milestones, however order forms incorporated into the contract set out the calendar dates on which fixed amounts were payable by PTT, resulting in an apparently contradictory requirements on when payment was due. Triple Point achieved completion (149 days late) of a portion of the work milestones, and were paid for that work. Triple Point then sought payment for the work which was not yet completed, relying on the calendar dates in the order forms rather than achievement of milestone payments. Things got progressively worse as PTT refused payment, Triple Point suspended the work for PTT’s failure to pay, PTT terminated the contract and then appointed a new contractor to complete the work. Reprinted courtesy of Vincent C. Zabielski, Pillsbury and Julia Kalinina Belcher, Pillsbury Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Faulty Workmanship Causing Damage to Other Property Covered as Construction Defect

September 30, 2011 — Tred R. Eyerly - Insurance Law Hawaii

In yet another recent construction defect case, the Illinois Court of Appeal found for coverage. See Milwaukee Mut. Ins. Co. v. J.P. Larsen, Inc., 2011 Ill. App. Ct. LEXIS 872 (Ill. Ct. App. Aug. 15, 2011).

Weather-Tite, Inc. hired Larson as a subcontractor to apply sealant to windows installed by Weather-Tite in a condominium building. The windows subsequently leaked and caused water damage. The homeowner’s association sued Weather-Tite for breach of express and implied warranties. Weather-Tite filed a third-party complaint against Larsen alleging that, if it was liable to the association for breach of warranty, Larsen was liable for contribution as a joint tortfeasor. Weather-Tite and Larsen both tendered defenses to Milwaukee Insurance. The tenders were denied and Milwaukee Insurance filed suit to determine rights under the policy.

Cross-motions for summary judgment were filed by all parties. The trial court granted Milwaukee Insurance’s summary judgment motion as to Weather-Tite, but granted Larsen’s cross-motion against Milwaukee Insurance.

On appeal, the appellate court considered whether the underlying pleadings alleged facts demonstrating "property damage" resulting from an "occurrence" within the terms of the policy.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Library to Open with Roof Defect Lawsuit Pending

December 04, 2013 — CDJ STAFF
Repairs to the Medina County District Library in Lodi, Ohio should be complete next spring. The library’s lawsuit over the roof is just beginning. The library building was a $3 million project in 2005, but the building had to close in 2011 when it was determined that the roof was not structurally sound. The lawsuit names six defendants, including the contractor, the framing subcontractor, and the engineering firm. The library seeking damages, legal expenses, and attorney fees. The cost of replacing the roof was $1.5 million. Read the court decision
Read the full story...
Reprinted courtesy of

---

Claimants’ Demand for Superfluous Wording In Release Does Not Excuse Insurer’s Failure to Accept Policy Limit Offer Within Time Specified

September 15, 2016 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Barickman v. Mercury Casualty Co. (No. B260833, filed 7/25/16, ord. pub. 8/15/16) a California appeals court affirmed a $3 million bad faith award against Mercury Casualty Co. based upon its failure to accept a policy limit demand within the time provided, finding that wording inserted by the claimants’ counsel into the release did not affect the insured’s rights such that the refusal to agree to the wording was unreasonable and in bad faith, exposing the insurer to liability for the insured’s stipulated judgment. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

"Your Work" Exclusion Bars Coverage for Contractor's Faulty Workmanship

December 02, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The West Virginia Supreme Court of Appeals found there was no coverage for the contractor's faulty workmanship in constructing a home. State of W. Virginia ex rel. Nationwide Mut. Ins. Co. v. The Honorable Ronald E. Wilson, 2015 W. Va. LEXIS 963 (W. Va. Oct. 7, 2015). In July 2009, Fred Hlad contracted to build a home for the Nelsons and complete construction by November 2009. The Nelsons sued when the house was not timely completed. Nationwide defended under a reservation of rights, but then filed a declaratory judgment action.The circuit court denied Nationwide's request for declaratory relief, determining that the defective workmanship was an "occurrence." Nationwide petitioned the Supreme Court for a writ of prohibition. On appeal, Nationwide argued that eight of the nine counts in the Nelsons' complaint were not caused by his defective workmanship. These allegations included breach of contract claims and intentional torts. Nationwide submitted it was not obligated to indemnify Hlad for damages that may be recovered on those counts. The court agreed that Nationwide's duty to indemnify was limited only to those claims that triggered coverage. Accordingly, Nationwide had no duty to indemnify for the eight counts alleging breach of contract and intentional torts. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Texas Law Bars Coverage under Homeowner’s Policy for Mold Damage

July 13, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Although the insurer paid for some of the mold damage at the insured’s home, the Fifth Circuit eventually determined the homeowner’s policy did not cover such damage. Rooters v. State Farm Lloyds, 2011 U.S. App. LEXIS 12306 (5th Cir. June 15, 2011).



The policy excluded loss caused by hail to personal property unless the direct force of wind or hail made an opening in the roof allowing rain to enter. Further, the policy excluded loss caused by mold or other fungi.



In 1999, hail and rain caused water damage to the roof and interior of the residence. State Farm paid $19,000 to repair the roof. Another $1,800 was paid for repairs to the interior of the building. In 2002, the insured noticed black mold. State Farm issued an additional check for $4,402 for mold abatement.



Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Augmenting BIM Classifications – Interview with Eveliina Vesalainen of Granlund

July 19, 2017 — Aarni Heiskanen - AEC Business
BuildingSMART Finland is supplementing building information modeling (BIM) guidelines in a national standardization project, as a part of the KIRA-digi program. In her Master’s thesis, Eveliina Vesalainen, of Granlund, has compared European BIM classifications for mechanical, electrical, and plumbing (MEP) design. Her study is the groundwork for the upcoming Finnish norms. “I’m a 26-year-old, soon to be Master of Science, and I come from Mäntsälä. I live in Helsinki and work at Granlund, a leading Finnish MEP consultancy,” Eveliina explains. She has a bachelor’s degree in environmental engineering, but became interested in MEP by chance. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

---

Number of Occurrences Depends on Who is Sued

August 20, 2014 — Beverley BevenFlorez-CDJ STAFF
According to David L. Beck of Pillsbury Winthrop Shaw Pittman LLP (as published by Association of Corporate Counsel), an Oregon court “held that property damage incurred to a condominium project resulting from a myriad of construction defects constituted just one occurrence under the relevant excess general liability policy.” In Chartis Specialty Ins. Co. v. American Contractors Ins. Co Risk Retention Group, et al., Chartis argued that “[b]ecause there were multiple defects/conditions resulting in property damage” there were also “multiple occurrences.” However, “[t]he court disagreed, finding that despite various defects, the property damages at issue arose from just one occurrence: the developers' failure to perform its duties.” Read the court decision
Read the full story...
Reprinted courtesy of

---