FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Beyond the Disneyland Resort: World Class Shopping Experiences

May 03, 2018 — Beverley BevenFlorez-CDJ STAFF
If you don’t want to venture far from the Disneyland Resort, consider heading to the Outlets at Orange. Formerly known as the Block of Orange, this open air shopping center features outlet stores such as Neiman Marcus Last Call, Nordstrom Rack, and Sax Fifth Avenue’s Off Fifth, as well as an AMC movie theater, restaurants, Lucky Strike Bowling Alley, and Dave and Buster’s. For another local option, head to the Brea Mall, where you can find department stores such as Macy’s and Nordstrom’s and a host of other stores like Apple, Guess, and Tommy Bahama. For a more exclusive shopping experience, travel to south Orange County's Fashion Island of Newport Beach. Their department stores include Bloomingdale’s, Macy’s, Neiman Marcus’s, and Nordstroms, and the shopping center also contains many boutique shops and eateries. Read the court decision
Read the full story...
Reprinted courtesy of

---

WSHB Expands to Philadelphia

July 28, 2016 — Beverley BevenFlorez-CDJ STAFF
Wood Smith Henning & Berman LLP (WSHB) announced “the opening of its newest regional office at One Liberty Place, 1650 Market Street, 36th Floor, Philadelphia, Pennsylvania 19103,” according to a press release. Elizabeth Chalik will be the managing partner at the new location. Chalik is “a highly regarded litigator with close to 15 years of trial experience” and her practice has focused on products liability, casualty, toxic tort and transportation litigation. Furthermore, Chalik is admitted to practice law in both New Jersey and Pennsylvania. “It is fitting that as we celebrate WSHB’s 19th year, we are opening our 19th office,” said Daniel Berman, Firm Chairman and Co-founder. “With this expansion, we continue our pattern of strategic long term growth. That, coupled with Liz’s proven track record and many years in Philadelphia, further expands our ability to better serve our clients in the Northeast.” Chalik has been recognized on the Super Lawyers List of Rising Stars for three years running. “I am thrilled to be joining Wood Smith Henning & Berman. WSHB’s long-standing reputation and dedication to their clients drew me to them and I knew that this would be the right place for me,” said Chalik. “I could not be more excited about the opportunity to manage WSHB’s new Philadelphia office!” WSHB also has offices located in Connecticut, Denver, Fresno, Glendale, Las Vegas, Los Angeles, Miami, New Jersey, New York, Northern California, Orange County, Phoenix, Portland, Rancho Cucamonga, Riverside, San Diego, Seattle and Tampa. Read the court decision
Read the full story...
Reprinted courtesy of

---

Lack of Flood Insurance for New York’s Poorest Residents

September 10, 2014 — Beverley BevenFlorez-CDJ STAFF
Property Casualty 360 reported that for residents of the flood-prone area of Queens, New York, even “the slightest downpour could mean evacuating their homes for a night or even weeks at a time.” The problem is that “[m]uch of Southeast Queens, an area that includes the neighborhoods of Jamaica, St. Albans and Hollis, and parts of the Rockaways, sits on a massive aquifer that swells with groundwater and spills over into streets and eventually into basements and homes after heavy rains.” However, according to Property Casualty 360, Southeast Queens residents “have been battling insurance agencies for over a decade.” “I would say more than 90% of the homeowners I speak to out here, they’re looking for insurance and they’re not getting it,” Councilman Donovan Richards, who represents Roseland and Far Rockaway, told Property Casualty 360. “Insurance companies obviously don’t want to take the risk.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Real Estate & Construction News Round-Up (10/05/22) – Hurricane Ian, the Inflation Reduction Act, and European Real Estate

October 24, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up features Hurricane Ian’s effect on the construction labor pool, the Inflation Reduction Act’s projected impact on the real estate and construction industry, Europe’s real estate market, and more.

• The Inflation Reduction Act (IRA), designed to reduce the nation’s carbon footprint by jump-starting innovation and adoption of cleaner energy sources, also contains large segments aimed at real estate and construction. (Chava Gourarie, Commercial Observer)
• Damage caused by Hurricane Ian’s massive storm surge, flooding and winds is projected to hike demand for experienced construction workers. (Zachary Phillips, Construction Dive)
• According to the National Multifamily Housing Council’s monthly construction survey released Sept. 29, 2022, almost all developers are experiencing construction delays. (Paul Bergeron, Globest)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Substitutions On a Construction Project — A Specification Writer Responds

July 03, 2022 — Melissa Dewey Brumback - Construction Law in North Carolina
In response to the post about Substitute Materials on a construction project, Phil Kabza explains how his company, SpecGuy, handles tracking of all such materials on a project. Phil writes: Excellent and important topic, about which there is much confusion among design professionals and contractors. We try to maintain definitions for:

• Pre-bid requests for prior approval of proposed comparable products where products are named in the specifications
• True pre-bid substitution requests that present an alternate type of product from that specified (ie., not “comparable” but perhaps suitable)
Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett
Ms. Brumback may be contacted at mbrumback@rl-law.com

---

Paris ‘Locks of Love’ Overload Bridges, Threatening Structures

June 11, 2014 — Helene Fouquet and Mark Deen - Bloomberg
Le Pont des Arts, the landmark Paris footbridge that links the Louvre museum to the Saint Germain neighborhood, is buckling under the weight of “love locks.” The Paris mayor’s office closed the bridge last night to replace a grate after thousands of locks weighed down its structure. Its railings are crumbling, threatening pedestrians on the bridge and cruise boats that ply under it on the Seine River. The bridge was reopened today after it was checked for safety, with two fire-department boats standing by to avert any potential incident. Although the origins of the trend are unclear, it has become a tradition for lovers to attach a lock to the railing on the sides of bridges in Paris to seal their love. Each lock weighs about 54 to 90 grams. The mayor of Paris’s 6th arrondissement, where the bridge is located, says the locks on the Pont des Arts weigh as much 10 tons, or 22,000 pounds. The grate that collapsed yesterday weighed about 200 kilos and the bridge has about 50 of them. Ms. Fouquet may be contacted at hfouquet1@bloomberg.net; Mr. Deen may be contacted at markdeen@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Helene Fouquet and Mark Deen, Bloomberg


---

Warning! Danger Ahead for Public Entities

July 30, 2019 — Michael J. Baker - Snell & Wilmer Under Construction Blog
Public entities are known to assert False Claims actions “to up the ante” to intimidate and aggressively address contractor construction claims. This strategy in the case of John Ross of Industrial Sheet Metal, Inc. (JRI) V. City of Los Angeles Department of Airports (LAWA), 29 Cal. App. 5th 378 (2018), backfired on the public entity, LAWA, in a big way and should serve as a warning to public entities about expanding claims to include False Claim actions. In this case, LAWA was awarded $1 in contract damages, its California False Claims Act (CFCA) claim was rejected by the jury as were JRI’s claims against LAWA. Despite losing on the substantive contract claims, the trial court found that JRI “prevailed in the action” under the relevant CFCA fee provision, Government Code 12652, subd. (g)(9)(B), regardless of JRI’s failure to prevail in the action as a whole. The California Appellate Court (hereinafter “Court”) affirmed the trial court’s finding. The CFCA is analogous to the federal False Claims Act (FFCA; 31 U.S.C. 3729 et seq.). Since the CFCA is patterned on similar federal legislation, it was appropriate for the Court to look to precedent construing this similar federal act in interpreting the CFCA provisions. Accordingly, the Court looked at the False Claims Act cases for guidance in upholding the trial court’s decision in its determination that JRI was the “prevailing party” for determining an attorney’s fees award against LAWA. Read the court decision
Read the full story...
Reprinted courtesy of Michael J. Baker, Snell & Wilmer
Mr. Baker may be contacted at mjbaker@swlaw.com

---