Fairfield Connecticut Building Expert Directory

Message from the Chair: Kelsey Funes (Volume I)

November 06, 2023 — Marissa L. Downs - The Dispute Resolver
I am so honored to assume the Division 1 mantle from my friend, Tom Dunn, and look forward to carrying on his good work. For those of you who don’t know me, I’d like to take this opportunity to share a bit about my background. I grew up in New Orleans and went to LSU for undergraduate and law school. (Geaux Tigers!) I started my practice in 1997 at Phelps Dunbar LLP in Baton Rouge, where I still practice today. I manage the litigation group in the Baton Rouge office of the firm. I practice as a construction lawyer full time and serve on the Construction Panel of the American Arbitration Association and serve as a mediator in construction cases. I am married to Dr. Chris Funes (the world’s best pediatrician) and we are the parents to two high schoolers. My son is a high school senior and my daughter is a sophomore. So, when I am not lawyering, I have been spending my time lately touring colleges, prepping for homecoming, and helping to teach my daughter to drive (all very relaxing!!). We also have a very sweet (and very hairy) rescue dog, Maggie, who makes sure we get lots of walks. Read the court decision
Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

Building Inspector Refuses to State Why Apartments Condemned

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
In Lockport, New York, “more than two dozen tenants have been locked out of their apartment building…but they have yet to find out why,” according to WIVB news. Brian Belson, Lockport’s building inspector, condemned the building and ordered the tenants to leave, providing only 15 minutes advanced warning. Once all of the tenants were out, the first floor windows and doors were boarded up. At first, tenants were told that they would be able to return in a few days, but now they are being told it could be weeks. However, WIVB News reported that Brian Belson has not returned any of their phone calls, so they have “filed a Freedom of Information request at Town Hall, seeking that information.” Belson has five days to respond to the request. Read the court decision
Read the full story...
Reprinted courtesy of

Guessing as to your Construction Damages is Not the Best Approach

November 18, 2019 — David Adelstein - Florida Construction Legal Updates
Arbitrarily guessing as to your construction damages is NOT the best approach. Sure, experts can be costly. No doubt about it. Having an expert versus guessing as to your construction damages caused by another party’s breach of contract is a no brainer. Engage an expert or, at a minimum, be in a position to competently testify as to your damages caused by another party’s breach of contract. Otherwise, the guessing is not going to get you very far as a concrete subcontractor found out in Patrick Concrete Constructors, Inc. v. Layne Christensen Co., 2018 WL 6528485 (W.D. New York 2018) where the subcontractor could not competently support its delay-related damages or change orders and, equally important, could not support that the damages were proximately caused by the general contractor’s breach of the subcontract. In this case, the concrete subcontractor entered into a subcontract to perform concrete work for a public project. The project was delayed and the general contractor was required to pay liquidated damages to the owner. Not surprisingly, the subcontractor disputed liability for delays and sued the general contractor for all of its delay-related damages “in the form of labor and materials escalation, loss of productivity, procurement and impact costs, field and home office overhead, idle equipment, inability to take on other work, lost profits, and interest.” Patrick Concrete Constructors, 2018 WL at *1. The general contractor moved for summary judgment as to the plaintiff’s delay-related damages – the subcontractor’s damages were nothing but guesses and the subcontractor could not prove the general contractor was the cause of the subcontractor’s damages. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Quick Note: Can a Party Disclaim Liability in their Contract to Fraud?

April 11, 2022 — David Adelstein - Florida Construction Legal Updates
It is possible for a party to contractually disclaim or otherwise foreclose liability to a fraud claim. However, let’s be honest. It can be done, but rarely is and would require very specific language to EXPLICITLY disclaim or foreclose such liability to a fraud claim. A recent case, discussed here, exemplifies this point where as-is language in a purchase-and-sale agreement was NOT specific to contractually foreclose or disclaim liability to a fraud claim. For a party to contractually waive a fraud claim, there needs to be an express waiver of liability for fraud that might have been made and that any fraudulent misrepresentation, if such fraud was committed, was disclaimed and would not destroy the validity of the parties’ contract. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

The Future for Tall Buildings Could Be Greener

October 01, 2013 — CDJ STAFF
Skidmore, Owens and Merrill made its reputation by creating iconic structures of steel, concrete, and glass, but in a new report, the firm puts forth ways in which the first item would be wood. Building codes in many cities stipulate that buildings taller than four stories be built of steel and concrete, but the firm says that it has come up with a way of building structures of 30 stories or more using wood. The tallest wood-framed building currently is only ten stories tall. In order to calculate a comparison, Skidmore, Owens and Merrill designed a forty-two story building based on the design of an existing apartment building. Actually building it would require almost 4 million board-feet of wood. Unlike a typical single-family home (and its 20,000 board-feet of wood), these building would use glue-laminated timber and slabs. The study found that the building would weigh less than half as much, allowing a less massive foundation. If the wood came from sustainable sources, its environmental impact would be drastically reduced. They calculated that instead of 9,500 tons of CO2 emissions for the conventional tower, the wood structure would be responsible for only 2,100 tons of emissions. Skyscrapers will continue to be a feature of large cities. But instead of urban canyons of steel and concrete, in the future those towering buildings might be made of wood. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Professionals Could Face More Liability Exposure Following California Appellate Ruling

December 17, 2024 — Jamison Rayfield & Brian Slome - Lewis Brisbois
San Diego/San Francisco, Calif. - The California Court of Appeal recently reversed a summary judgment ruling in favor of a geotechnical engineering firm that had conducted a brief inspection of a residential construction project's footing trench for $360. The case arose when homeowner Cheryl Lynch experienced significant property damage after her home's foundation failed and the structure began subsiding into a slope. Lynch sued Peter & Associates for professional negligence and nuisance, despite having no direct contractual relationship with the firm, which had been hired by her contractor to perform the geotechnical inspection. The court distinguished this case from Bily v. Arthur Young & Co. (1992) 3 Cal.4th 370, which had limited auditors' professional duty to third parties, noting that Bily dealt with purely economic damages, whereas Lynch involved physical property damage, making Bily's policy concerns about unlimited liability inapplicable. The court emphasized that construction professional negligence cases, particularly those involving residential property damage, warrant a different analysis than cases involving economic loss. Reprinted courtesy of Jamison Rayfield, Lewis Brisbois and Brian Slome, Lewis Brisbois Mr. Rayfield may be contacted at Jamison.Rayfield@lewisbrisbois.com Mr. Slome may be contacted at Brian.Slome@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Retainage on Pennsylvania Public Contracts

January 31, 2018 — Wally Zimolong - Supplemental Conditions
Ah yes, retainage, what could represent your profit on a project and something frequently abused by owners on private and public projects alike. Fortunately, Pennsylvania law offers public works contractors some protection from retainage abuse. The Public Prompt Payment Act dictates when retainage can be withheld and when it must be released. Agencies that fail to follow the Prompt Payment Act’s retainage rules can end up owing you interest, penalty, and attorney’s fees. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC

The Cost of Overlooking Jury Fees

February 07, 2022 — Nicholas B. Brummel, Arezoo Jamshidi & Lawrence S. Zucker II - Haight Brown & Bonesteel
On January 21, 2022, the Court of Appeal, Second Appellate District, Division Two (Los Angeles), certified for publication a 2-1 decision that serves as an important reminder to California attorneys to post jury fees in a timely manner and to use appropriate channels and consult with appellate counsel in seeking appellate relief from contested rulings. In TriCoast Builders, Inc. v. Nathaniel Fonnegra, (B303300, Jan. 21, 2022), a construction defect dispute, the trial court set a jury trial at defendant’s request. However, on the day trial was set, defendant waived jury trial. Plaintiff objected and made an oral request for jury trial. The trial court denied the request finding that plaintiff waived its right to a jury trial by failing to timely post jury fees. The matter proceeded to a bench trial, and the court ruled in favor of defendant. Plaintiff appealed, having failed to seek a writ of mandate, which the appellate court noted “is the proper remedy to secure a jury trial allegedly wrongfully withheld.” Reprinted courtesy of Nicholas B. Brummel, Haight Brown & Bonesteel, Arezoo Jamshidi, Haight Brown & Bonesteel and Lawrence S. Zucker II, Haight Brown & Bonesteel Mr. Brummel may be contacted at nbrummel@hbblaw.com Ms. Jamshidi may be contacted at ajamshidi@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES