FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Communications between Counsel and PR Firm Hired by Counsel Held Discoverable

March 22, 2017 — Kevin R. Crisp, David W. Evans, & Sarah A. Marsey – Haight Brown & Bonesteel LLP
Counsel handling cases involving newsworthy facts and litigation often hire public relations (“PR”) consultants. In Nicholas Behunin v. The Superior Court of Los Angeles County, 2017 DJDAR 2405 (No. B272225 March 14, 2017) the California Court of Appeal, Second District, denied a petition for writ of mandate concerning a trial court discovery order holding that communications between a plaintiff’s attorney and a public relations firm counsel hired for the purpose of creating a website for the Plaintiff were discoverable, despite claims that such communications were protected from disclosure by attorney-client privilege. Plaintiff sued Defendants -- (the) Charles Schwab and his son Michael Schwab -- over an unsuccessful real estate investment. Plaintiff’s attorneys hired a public relations consultant to create a website (www.chuck-you.com) that sought to link the Schwabs with the late Indonesian dictator Suharto’s family. The court succinctly described the web site as “a social media campaign to induce the Schwabs to settle the case.” Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Kevin R. Crisp, David W. Evans and Sarah A. Marsey Mr. Crisp may be contacted at kcrisp@hbblaw.com Mr. Evans may be contacted at devans@hbblaw.com Ms. Marsey may be contacted at smarsey@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Bright-Line Changes: Prompt Payment Act Trends

September 16, 2024 — Stephanie L. Cooksey - Peckar & Abramson, P.C.
Untimely payment by the owner for contract work and additional work on construction projects can place an unfair financial burden on contractors and subcontractors. Most states have attempted to eliminate or mitigate this inequity in construction contracting through Prompt Payment Acts that govern payment deadlines and provide remedies for untimely payment. This article addresses the legislative trends aimed at minimizing the risk of non-payment, overdue payment, and withholding retainage in favor of downstream parties to a construction contract. Fortifying Contractor Protections with “Bright-Line” Language Over the last decade, states have been tightening prompt payment laws by replacing broad, general statutory language with bright-line rules. What is a bright-line rule? A specific or definite figure, a quantifiable marker—i.e., something owners, contractors, subcontractors, and suppliers should be aware of. Practically speaking, the more bright-line a prompt payment statute is, the greater the likelihood it will affect a construction project in your state. A standard form construction contract, if not reviewed carefully, can create conflicts or confusion if it gives a party more leeway on payment deadlines than the applicable Prompt Payment Act. For example, consider an owner-issued Construction Change Directive (“CCD”) that requires a contractor to commence additional work immediately while a formal change order is negotiated. Consequently, a CCD can push financial burdens downstream, whether inadvertently or not, and may conflict with statutory payment deadlines. Nevertheless, an owner can be justified in its utilization of a CCD to maintain the project schedule. How should the parties competing interests be resolved? Read the court decision
Read the full story...
Reprinted courtesy of Peckar & Abramson, P.C.

---

Eleventh Circuit Rules That Insurer Must Defend Contractor Despite “Your Work” Exclusion, Where Damage Timing Unclear

May 13, 2019 — Michael S. Levine & David M. Costello - Hunton Andrews Kurth
The Eleventh Circuit has reversed an insurer’s award of summary judgment after finding that uncertainty about when the alleged property damage occurred raised questions about whether the damage came within the scope of the “Your Work” exclusion. More specifically, the court found unclear whether the damage occurred before or after the contractor abandoned the job, thereby triggering an exception to the “Your Work” exclusion for damage to work that had “not yet been completed or abandoned.” The decision illustrates how timing can be a critical factor when it comes to triggering coverage for work and completed operations. In Southern-Owners Insurance Company v. MAC Contractors of Florida, LLC, a pair of trustees hired MAC Contractors (doing business as KJIMS Construction) to serve as the general contractor for a custom residence. After construction began, disputes between the trustees and KJIMS caused the contractor to abandon the job before completing the project. The trustees followed with a lawsuit alleging, among other things, that KJIMS had damaged wood floors and a metal roof, which KJIMS had promised to remediate but never did. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and David Costello, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Costello may be contacted at dcostello@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Timber Prices Likely to Keep Rising

October 30, 2013 — CDJ STAFF
Lumber prices are expected to keep rising, and according to Terry Shumacher, who does business acquisition for private equity firms, that’s a sign to invest in lumber stocks. Writing at Seeking Alpha, he looks at one such company, Tembec, the eleventh largest lumber producer in North America. Tembec is headquartered in Canada, but its stock trades on both the Canadian and American markets. Mr. Schumacher points out that one of the advantages of Tembec as an investment is that its stock is currently trading at about $2.59 a share, so a $50 per million board feet increase in the cost of lumber would make a large percentage change to its earnings to price ratio. (As comparison, Mr. Schumacher offers West Fraser, which is trading at about $89.59. There, the increase in lumber prices would have a much smaller effect on the stock price.) There’s going to be a greater demand for lumber, not only due to increased housing starts but that North American firms have started exporting lumber to China. Add to that the loss of trees in some areas due to beetle infestations. The death of standing timber has lead to some sawmills shutting down for lack of logs. All of which points to increased timber prices. Read the court decision
Read the full story...
Reprinted courtesy of

---

Vancouver’s George Massey Tunnel Replacement May Now be a Tunnel Instead of a Bridge

January 06, 2020 — Tim Newcomb - Engineering News-Record
The constant political back-and-forth in British Columbia, Canada, over how to deal with an aging George Massey Tunnel, opened in 1959, has ping-ponged from uncertainty to a $3.5 billion, 10-lane bridge, back to uncertainty, to no bridge and now to an eight-lane submerged tunnel. Tim Newcomb, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Illinois Appellate Court Affirms Duty to Defend Construction Defect Case

August 04, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Illinois Appellate Court affirmed the trial court's ruling that the insurer had a duty to defend a construction defect case. West Bend Mut. Ins. Co. v. Pulte Home Corp., 2015 Ill App. Unpub. LEXIS 1039 (Ill. Ct. App. May 15, 2015). Pulte Home Corporation was a developer who developed and constructed a residential condominium development known as The Reserve of Elgin (The Reserve). G.H. Siding was subcontracted by Pulte to work on the development, including the installation of exterior siding. The Reserve Homeowners Association (HOA) filed suit against Pulte and James Hardie Building Products Inc., the company that manufactured the exterior siding. The complaint alleged that Pulte developed, designed, constructed and sold the units and common areas. Pulte installed siding manufactured by Hardie on the exterior of the units. The siding was allegedly defective. The HOA alleged breach of implied warranty of habitability and breach of contract by Pulte. Hardie was sued for breach of express warranty and breach of implied warrant of habitability. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Home Construction Thriving in Lubbock

December 30, 2013 — CDJ STAFF
The 2013 numbers for home construction aren’t ready yet, but the January through November numbers for Lubbock, Texas show a 42% increase over the number of construction permits issued for single-family homes in the first 11 months of 2012. The number look even better compared to 2011’s totals, according to KFYO. Read the court decision
Read the full story...
Reprinted courtesy of

---