FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Three Recent Cases Strike Down Liquidated Damages Clauses In Settlement Agreements…A Trend Or An Aberration?

November 01, 2021 — Adam M. Tuckman - ConsensusDocs
Beginning more than one century ago, owners and contractors generally have adopted the convention of including liquidated damages in their contracts to fix potential liability for delay (and other losses) at the inception of the project. The proliferation of liquidated damages clauses in modern contracts can be attributed to economic and legal factors. From the owner’s standpoint, it may be exceedingly difficult to prove the actual cost impact of a delayed completion of the project. A properly calculated liquidated damages rate would save the owner the significant expense of quantifying its delay damages. On the contractor’s side, a reasonable amount of liquidated damages may be preferable to uncapped or unknown liability, allowing the contractor to more accurately price its bid and efficiently allocate risk. Coinciding with, or perhaps a leading cause of, the industry’s embrace of liquidated damages provisions, was the shift in courts throughout the country from disfavoring such clauses to accepting them (within limits) as an appropriate exercise of contract rights. While some variation exists among the states, courts have generally recognized that liquidated damages clauses are a viable alternative to proof of actual loss so long as (i) actual losses were difficult to quantify, and (ii) the stipulated sum bears a reasonable relationship to the anticipated loss at the time of contracting. See, e.g., Restatement (Second) of Contracts § 356. Conversely, a clause that penalizes the breaching party rather than serving as an estimate of probable loss is likely to be found unenforceable. Read the court decision
Read the full story...
Reprinted courtesy of Adam M. Tuckman, Watt, Tieder, Hoffar, & Fitzgerald, LLP
Mr. Tuckman may be contacted at atuckman@watttieder.com

---

What the FIU Bridge Collapse Says About Peer Review

September 23, 2019 — Richard Korman & Scott Judy - Engineering News-Record
Attorneys for families of the six people who were killed and for survivors of 2018’s Florida International University pedestrian bridge collapse say Louis Berger Group is the last defendant that has not yet agreed to settle lawsuits in state court in Miami. The legal actions target companies that designed and built the bridge. Reprinted courtesy of Richard Korman, Engineering News-Record and Scott Judy, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Mr. Judy may be contacted at judys@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Congratulations to BWB&O’s Los Angeles Office on Another Successful MSJ!

July 11, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Partner Daniel Crespo and Associate Stefon Jackson successfully argued and won a Motion for Summary Judgment (“MSJ”) for our client, a property owner of an apartment complex. Plaintiff was involved in a physical altercation with one of the tenants at an apartment complex owned by our client. Plaintiff alleged that our client had notice of a propensity for violence claiming that there were prior instances of contentious interactions between this particular tenant and Plaintiff. As a result, Plaintiff alleged that our client had a duty to prevent further interactions between Plaintiff and the tenant presuming that an act of physical violence was reasonably foreseeable. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Property Owner Entitled to Rely on Zoning Administrator Advice

May 16, 2018 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In the recent case of In Re Langlois/Novicki Variance Denial, 175 A.3d 1222, 2017 VT 76 (2017), the Vermont court addressed the question of whether a property owner could enforce – by equitable estoppel principles – a representation by a town zoning administrator that no permit or variance was needed for the property owner’s proposed construction. In that case, a landowner wanted to add a pergola to an existing concrete patio on his land. During a social visit at the property, the property owner asked the town zoning administrator if he needed a permit. The town zoning administrator told the property owner that no permit was needed. The property owner thereafter showed the zoning administrator a sketch of the planned construction, and again asked if a permit was required. The town zoning administrator looked at the sketch and repeated his prior advice that no permit was needed. The property owner then spent $33,000 to build the pergola. After incurring the expense, the property owner was advised that the structure violated zoning regulations. The property owner requested a variance, which the zoning board denied. The Court held that the town was estopped from requiring removal of the pergola. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

---

Reporting Requirements for Architects under California Business and Professions Code Section 5588

December 22, 2019 — Jordan Golden - Gordon & Rees Construction Law Blog
Below is an overview of the changes to California Business and Professions Code Section 5588 and its effect on the reporting requirements, for architects, in the construction industry. Section 5588 Prior to 2005 Legislative Changes Section 5588 of the California Business and Professions Code sets forth the reporting requirements for many business professionals including architects. Since 1979, Section 5588 has required architects and their insurers to report to the California Architect Board (the Board) “any settlement or arbitration award in excess of five thousand dollars ($ 5,000) of a claim or action for damages caused by the license holder’s fraud, deceit, negligence, incompetency, or recklessness in practice.”1 The language of the code section left open for interpretation the question of what types of settlement claims must be reported to the Board. Thus, in 2004, the Attorney General of the State of California published an opinion stating that a reportable settlement includes “any agreement resolving all or part of a demand for money which is based upon an insured architect’s alleged wrongful conduct.”2 He then went on to conclude that the only qualifications placed on the term “claim” for purposes of Section 5588 is that “(1) the demand be premised on the license holder’s alleged ‘fraud, deceit, negligence, incompetency, or recklessness in practice,’ and (2) the value of the claim, as measured by the settlement amount or arbitration award, exceeds $5,000.”3 Read the court decision
Read the full story...
Reprinted courtesy of Jordan Golden, Gordon & Rees Scully Mansukhani

---

Structural Engineer Found Liable for Defects that Rendered a Condominium Dangerously Unsafe

June 22, 2016 — Paul R. Cressman, Jr. – Ahlers & Cressman Construction Law Blog
On May 3, 2016, the Washington State Court of Appeals affirmed a jury’s verdict in favor of a condominium HOA against a structural engineer for $1,149,332 in damages.[1] The project in question was The Pointe, an upscale condominium building in Westport, Washington. The developer was Dodson-Duus, LLC. The architect was Elkins Architects (“Elkins”). The structural engineer was Engineers Northwest, Inc. (“ENW”). ENW contracted with Elkins for the structural engineering work. Birds flying past 3 construction cranesBoth the design and construction of the building suffered from defects. In particular, the lateral force resistance system was insufficient to withstand a large seismic event. The defects included improperly nailed shear walls, weak connections between shear walls and floor joists, improperly-sized floor sheathing, a weak second-floor diaphragm, and omitted hold-downs connecting shear walls to a steel beam. The use of gypsum sheathing also created a risk of corrosion to the building’s steel structure. Evidence tied each of these defects to some aspect of ENW’s structural calculations and designs. Evidence also tied omission of the hold-downs to the contractor’s construction decisions. Read the court decision
Read the full story...
Reprinted courtesy of Paul R. Cressman, Jr., Ahlers & Cressman PLLC
Mr. Cressman may be contacted at pcressman@ac-lawyers.com

---

Insurer Must Defend Contractor Against Claims of Faulty Workmanship

May 30, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The magistrate judge recommended that the insurer's motion for summary judgment seeking to determine there was no coverage for claims of faulty workmanship be denied. Greystone Multi-Family Builders v. Gemini Ins. Co., 2018 U.S. Dist. LEXIS 56770 (S.D. Tex. Feb. 26, 2018). TPG (Post Oak) purchased an OCIP policy to cover construction of an apartment complex. TPG was sued by the contractor, Greystone, after TPG cancelled the construction contract. TPG filed a counterclaim against the contractor, alleging that Greystone had failed to properly perform in building a luxury apartment complex which resulted in monetary damages to TPG. The complaint further alleged that the project was nine months behind its substantial completion date, far from complete, and over budget when TPG cancelled the contract. The cost to fix the mismanagement caused by Greystone was $18.9 million. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

HOA Has No Claim to Extend Statute of Limitations in Construction Defect Case

October 28, 2011 — CDJ STAFF

The California Court of Appeals ruled on September 20, 2011 in the case of Arundel Homeowners Association v. Arundel Green Partners, a construction defect case involving a condominium conversion in San Francisco. Eight years after the Notice of Completion was filed, the homeowners association filed a lawsuit alleging a number of construction defects, including “defective cabinets, waterproofing membranes, wall-cladding, plumbing, electrical wiring, roofing (including slope, drainage and flashings), fire-rated ceilings, and chimney flues.” Three years of settlement negotiations followed.

Negotiations ended in the eleventh year with the homeowners association filing a lawsuit. Arundel Green argued that the suit should be thrown out as California’s ten-year statute of limitations had passed. The court granted judgment to Arundel Green.

The homeowners then filed for a new trial and to amend its complaint, arguing that the statute of limitations should not apply due to the doctrine of equitable estoppel as Arundel Green’s actions had lead them to believe the issues could be solved without a lawsuit. “The HOA claimed that it was not until after the statute of limitations ran that the HOA realized Arundel Green would not keep its promises; and after this realization, the HOA promptly brought its lawsuit.” The trial court denied the homeowners association’s motions, which the homeowners association appealed.

In reviewing the case, the Appeals Court compared Arundel to an earlier California Supreme Court case, Lantzy. (The homeowners also cited Lantzy as the basis of their appeal.) In Lantzy, the California Supreme Court set up a four-part test as to whether estoppel could be applied. The court applied these tests and found, as was the case in Lantzy, that there were no grounds for estoppel.

In Arundel, the court noted that “there are simply no allegations that Arundel Green made any affirmative statement or promise that would lull the HOA into a reasonable belief that its claims would be resolved without filing a lawsuit.” The court also cited Lesko v. Superior Court which included a recommendation that the plaintiffs “send a stipulation?Ķextending time.” This did not happen and the court upheld the dismissal.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---