Fairfield Connecticut Building Expert Directory

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

CSLB Begins Processing Applications for New B-2 License

June 21, 2021 — Garret Murai - California Construction Law Blog
As we wrote about in our 2021 Construction Law Update, one of the new laws to take effect on January 1, 2021 was the enactment of SB 1189 which created a new B-2 Residential Remodeling Contractor’s license. The new license is available to contractors working on existing homes with residential wood frame structures requiring at least three (3) unrelated trades or crafts under a single contract. Beginning June 1, 2021, the Contractors State License Board began accepting applications for the B-2 Residential Remodeling Contractor’s license. According to a press release from the CSLB:

The B-2 classification provides a pathway to licensure for many unlicensed people who are currently working on remodeling and small home improvement projects that don’t qualify for a B-General Building License because the contracted work does not include framing or rough carpentry. Consumers employing a licensed contractor have reduced liability and greater consumer protection. Licensees benefit from licensure as they have opportunities to lawfully advertise, and compete on a level playing field for jobs.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Suing a Local Government in Land Use Cases – Part 2 – Procedural Due Process

February 16, 2017 — Wally Zimolong – Supplemental Conditions
n my last post I discussed suing a local government for a substantive due process violation. In this post, I discuss a the right to procedural due process. The Fourteenth Amendment of the United States Constitution protects prohibits the government from depriving an individual or business of life (in the case of an individual), liberty, or property without due process of law. Unlike the somewhat abstract and subjective concept of substantive due process, procedural due process is direct and objective. Generally, if an individual or business maintains a property or liberty interest, a local government must afford that individual or business notice that the government intends to deprive them of a liberty or property interest and a reasonable opportunity to be heard to contest the proposed deprivation. Unless there is an emergency, the notice and opportunity to be heard must be given before the government deprives an individual or business of a liberty of property interest. This is known as a pre-deprivation hearing. Because of the clear contours of the right, procedural due process violations are typically easier to prove than substantive due process violations. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

First Railroad Bridge Between Russia and China Set to Open

August 06, 2019 — Saibal Dasgupta - Engineering News-Record
Work was completed on the first-ever railroad bridge connecting Russia to China in early April, as Russian engineers installed the final steel beam in its section of the structure over the river called the Amur in Russian and the Heilongjiang. China finished its part of the work last October, as the structure successfully spanned the world's 10th longest river, which markets the boundary between the two countries. Officials say the bridge will open for public use after the necessary inspections in July this year. Read the court decision
Read the full story...
Reprinted courtesy of Saibal Dasgupta, ENR
ENR may be contacted at ENR.com@bnpmedia.com

The COVID-19 Impact: Navigating the Legal Landscape’s New Normal

July 27, 2020 — Amanda Mathieu - Lewis Brisbois
While most of the country has been at a standstill since March, you might be wondering, what about my lawsuit or my administrative charge? For the past couple of months, most litigation cases have largely been put on pause in the courts and at administrative agencies. However, as we adjust to what is clearly a new normal in both our lives and the legal landscape as we know it, cases will begin to pick up speed again, albeit with new strategies and challenges to keep in mind. As courts begin to reopen, judges are emphasizing in many jurisdictions that criminal cases will take priority in an effort to attend to constitutionally required timelines. Nevertheless, it will remain just as important as before the pause button was hit to keep cases moving forward. This ramp up period presents a unique opportunity for clients and attorneys to invest meaningful time into investigating and developing defenses to claims while the court system and related case pace remains slowed. Read the court decision
Read the full story...
Reprinted courtesy of Amanda Mathieu, Lewis Brisbois
Ms. Mathieu may be contacted at Amanda.Mathieu@lewisbrisbois.com

Courthouse Reporter Series: Louisiana Supreme Court Holds Architect Has No Duty to Safeguard Third Parties Against Injury, Regardless of Knowledge of Dangerous Conditions on the Project

July 31, 2024 — Stu Richeson - The Dispute Resolver
In Bonilla v. Verges Rome Architects, 2023-00928 (La. 3/22/24); 382 So.3d 62, the Louisiana Supreme Court held because the terms of the agreement between the architect and the public owner did not give the architect responsibility for the means and methods of construction or for safety on the project, the architect did not have a duty to safeguard third parties against injury, regardless of whether the architect may have had knowledge of dangerous conditions on the project. In Bonilla, the City of New Orleans entered into a contract for the renovation of a building owned by the city. The city also entered into an agreement with Verges Rome Architects (“VRA”) to serve as the project architect. The general contractor on the project subcontracted the demolition work to Meza Services, Inc. (“Meza”). An employee of Meza was injured while attempting to demolish a “vault” on the project. The vault was a ten-foot by ten-foot cinderblock room with a nine-foot-high concrete slab ceiling located on the second floor of the building. The walls of the vault had been partially demolished when one of the employees of Meza was directed by his supervisor to stand on the ceiling of the vault with a jackhammer to continue the demolition. Shortly after beginning the task, the vault structure collapsed and caused the employee to suffer significant injury. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

Tallest U.S. Skyscraper Dream Kept Alive by Irish Builder

May 01, 2014 — Brian Louis – Bloomberg
Garrett Kelleher, the Irish developer trying to restore Chicago’s status as home to the tallest building in the U.S., has one last chance to keep his dream alive. The planned lakefront skyscraper is nothing more than a hole in the ground six years after the financial crisis derailed Kelleher’s ambitions. To salvage the project, he must line up money to get out of bankruptcy, then obtain financing for the 2,000-foot (610-meter), Santiago Calatrava-designed Chicago Spire condominium tower, which would surpass New York’s 1 World Trade Center by 224 feet. “I never understood how that project was going to work, frankly,” said Alan Lev, chief executive officer of Belgravia Group Ltd., a Chicago-based housing developer uninvolved in the project. “It’s a real eyesore sitting in the ground, so I hope somebody does something with it.” Read the court decision
Read the full story...
Reprinted courtesy of Brian Louis, Bloomberg
Mr. Louis may be contacted at blouis1@bloomberg.net

Federal Magistrate Judge Recommends Rescission of Policies

February 12, 2024 — Craig Rokuson - Traub Lieberman
In the recent case of Union Mut. Fire Ins. Co. v. 142 Driggs LLC, 2023 U.S. Dist. LEXIS 220393, Magistrate Judge Lois Bloom of the United States District Court for the Eastern District of New York recommended granting the insurer's default judgment and holding that of three policies issued to 142 Driggs LLC ("Driggs") be rescinded ab initio. Driggs had represented on its insurance applications that it did not provide parking to anyone other than itself, tenants, and its guests at the subject insured premises. However, Union Mutual learned that Driggs had been renting out three garages to non-tenants. Second, Driggs represented that the mercantile square footage was around 1,000 square feet, when in actuality, it was larger than allowed under the policies. Union Mutual provided underwriting guidelines in connection with its default motion, which state that "parking provided for anyone other than the insured, tenants and their guests," presents an "unacceptable risk." The guidelines also state that answering yes to any "preliminary application questions (which presumably included those regarding mercantile square footage and parking) is an "unacceptable risk." The court held that these guidelines supported a finding that Driggs made material misrepresentation and that Union Mutual relied on these misrepresentations in issuing the policies. The court, as such, recommended that the policies at issue be rescinded from inception. Read the court decision
Read the full story...
Reprinted courtesy of Craig Rokuson, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES