SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Hilary Soaks California With Flooding Rain and Snarls Flights

August 21, 2023 — Brian K. Sullivan & Brian Wingfield - Bloomberg
The remnants of Tropical Storm Hilary pummeled California with record rains on Monday, disrupting flights but sparing its largest cities from widespread destruction. Across the region, “the ongoing and historic amount of rainfall is expected to cause life-threatening to locally catastrophic” floods, along with landslides and mudslides, the National Hurricane Center said in a notice early Monday. The storm, now a post-tropical cyclone, has weakened since coming ashore in California late Sunday. As of early Monday, it had maximum sustained winds of about 35 miles (56 kilometers) per hour and is forecast to move across Nevada and dissipate on Monday. Hilary, a rare storm to hit the Southwest, could bring a year’s worth of rain to parts of a region famous for its usually balmy weather. Heavy rain and flash flooding have already disrupted transportation, and officials warned residents to stay off the roads. In the last 10 years, flooding from rainfall has caused the most deaths from hurricanes and tropical storms in the US. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

---

Corporate Transparency Act’s Impact on Real Estate: Reporting Companies, Exemptions and Beneficial Ownership Reporting (webinar)

December 04, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
On October 23, 2023, colleague Andrew Weiner and Kevin Gaunt, counsel at Hunton Andrews Kurth, examined the Corporate Transparency Act (CTA), effective Jan. 1, 2024, and its impact on real estate entities and transactions, including who is considered a reporting company subject to new beneficial ownership information (BOI) reporting requirements and whether an exemption applies. The panel also discussed certain state laws that impose similar reporting requirements as the CTA and described best practices for real estate counsel to assist their clients with preparing for the CTA’s implementation and ongoing compliance. The panel also reviewed other important considerations, including:

1. Which real estate entities will likely be most affected by the CTA’s implementation and why?
2. What exemptions may apply?
3. How will the CTA’s reporting requirements affect real estate transactions for lenders and investors/buyers?
Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team


---

Contractors Pay Heed: The Federal Circuit Clarifies Two Important Issues For Bid Protestors

September 13, 2021 — Andrew Balland - ConsensusDocs
The United States Court of Appeals for the Federal Circuit (Federal Circuit) recently decided two cases that are relevant to many disappointed offerors considering a bid protest. One decision rendered in March 2021 confirmed the authority of the United States Court of Federal Claims (COFC) to hear a protest based on an agency’s breach of an implied-in-fact contract. A second decision issued in February 2021 reversed a COFC decision from last year regarding the timeliness requirements to obtain a CICA stay and their interplay with Department of Defense (DoD) enhanced debriefing regulations. Federal Circuit Confirms The Court Of Federal Claims’ Jurisdiction Over Procurement-Related Implied Contract Claims When a contractor’s bid protest is denied by the Government Accountability Office (GAO), the unsuccessful protestor may challenge the GAO’s decision as arbitrary and capricious in an action before the COFC. While 28 U.S.C. § 1491(b)(1) authorizes the COFC to hear such procurement-related challenges, § 1491(a) also permits the court to adjudicate claims against the United States based on any express or implied contracts. Read the court decision
Read the full story...
Reprinted courtesy of Andrew Balland, Watt, Tieder, Hoffar & Fitzgerald, LLP


---

No Hiring Surge by Homebuilders Says Industry Group

February 14, 2013 — CDJ STAFF
Looking at data from the Bureau of Labor Statistics, the National Association of Home Builders found that while hiring levels in construction remain strong, there hasn’t been a surge in hiring in this particular sector. December found 92,000 open construction position, with the NAHB noting that home builders are still concerned about finding qualified workers. While there has not been surge in hiring, home building is on the increase. The NAHB says that “this could be due to increased hours for existing workers,” which would not be “a sustainable situation.” Read the court decision
Read the full story...
Reprinted courtesy of


---

Time is Money. Unless You’re an Insurance Company

December 02, 2015 — Garret Murai – California Construction Law Blog
Benjamin Franklin may never have been President but he’s better known than most of them. Not least of all for his pithy quotes on a wide range of subjects:

On personal finance – “A penny saved is a penny earned.”

On education – “Tell me and I forget, teach me and I remember, involve me and I learn.”

On getting real – “In this world nothing can be said to be certain, except death and taxes.”

On guests – “Guests, like fish, begin to smell after three days.”

On lawyers – “A countryman between two lawyers is like a fish between two cats.”

On beer – “In wine there is wisdom, in beer there is freedom, in water there is bacteria.”

But if you were to pick one theme that seems to recur the most in Franklin’s quotes, it would be productivity:

“Time is money.”

“By failing to prepare, you are preparing to fail.”

“Never leave that till tomorrow which you can do today.”

“Early to bed and early to rise, makes a man happy, wealthy and wise.”

But, as the next case, Grebow v. Mercury Insurance Company, Case No. B261172, California Court of Appeals for the Second District (October 21, 2015), illustrates, sometimes the most efficient way of doing things may not necessarily be the most financially prudent way of doing things. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Best Lawyers® Recognizes 37 White And Williams Lawyers

September 26, 2022 — White and Williams LLP
Thirty-two White and Williams lawyers were recognized in The Best Lawyers in America© 2023. Inclusion in Best Lawyers® is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers® employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services. In addition, eight lawyers were recognized as "Ones to Watch” by Best Lawyers®. This recognition is given to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States. The firm is also pleased to announce Best Lawyers® has recognized four White and Williams lawyers as "Lawyer of the Year." Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP


---

Metrostudy Shows New Subdivisions in Midwest

October 01, 2014 — Beverley BevenFlorez-CDJ STAFF
Metrostudy surveyed the Chicago, Indianapolis, and Minneapolis/St. Paul markets and found an increase in subdivisions—“[n]ot a re-hashing of existing communities or a re-configuring of existing developments, but new land, being newly developed,” according to Builder magazine. Builder reported that in 2010 only 383 new lots were delivered to the Chicago market, but in just the first six months of 2014, 1,500 new lots have been delivered. Furthermore, the Twin Cities had a total of 964 lots delivered in 2010. “In 2013, there were 3,683 new lot deliveries. Indianapolis has seen a total of 1,400 new lots delivered in the first six months of 2014, compared to just 650 through the first half of 2010.” Read the court decision
Read the full story...
Reprinted courtesy of


---