Quick Note: COVID-19 Claim – Proving Causation
August 03, 2020 —
David Adelstein - Florida Construction Legal UpdatesIn certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk.
No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
San Francisco Office Secures Defense Verdict in Legal Malpractice Action
November 25, 2024 —
Lewis Brisbois NewsroomSan Francisco, Calif. (October 31, 2024) - After a ten-day jury trial in San Francisco Superior Court, Partner Alex Graft recently secured a defense verdict in a legal malpractice action arising out of underlying litigation with the claimants’ homeowners association. The claimants alleged his client attorneys negligently advised them that the terms of the settlement agreement would result in the creation of a so-called independent board of directors for the homeowners association. It did not come to fruition. After the attorneys withdrew, they sued for their outstanding fees, which elicited a cross-complaint alleging malpractice, breach of fiduciary duty, breach of contract and negligent misrepresentation.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
A Word to the Wise: The AIA Revised Contract Documents Could Lead to New and Unanticipated Risks - Part II
October 16, 2018 —
George Talarico - Construction ExecutivePart I addressed general conditions, revised insurance terms, revisions that affect owner’s required insurance and revisions that affect contractor’s required insurance.
REVISIONS THAT AFFECT DISPUTE RESOLUTION
A seemingly minor but noteworthy change is to the definition of “Claim.” Under Section 15.1 a “Claim” is defined to:
- include a request for a modification of contract time; and
- exclude any requirement that an owner must file a claim to impose liquidated damages.
Notably, any request relating to contract time must be brought within the specified time period for Notice of Claim and in the prescribed manner. There are at least two traps for the unwary. First, even though email is regularly used for communications among the parties, the revised contract documents do not recognize email as an acceptable form of delivery of a Notice of Claim. Second, an unwary contractor may wrongly assume that an owner’s failure to assert a claim for LDs means that LDs will not be imposed. This may lull the contractor into failing to timely assert its own claim for a time extension and thereby waiving its ability to do so.
Reprinted courtesy of
George Talarico, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Talarico may be contacted at
gtalarico@sillscummis.com
It’s Time to Start Planning for Implementation of OSHA’s Silica Rule
May 03, 2017 —
Nathan Owens & Louis “Dutch” Schotemeyer – Newmeyer & Dillion LLPGetting a notification from OSHA that your company is being investigated for a health or safety violation is an unwanted disruption to your business that could lead to a hefty monetary fine. Worse yet, if your company is found to have committed multiple violations, OSHA may categorize your company as a severe violator, which makes you subject to follow-up inspections. In the last 6 years, OSHA has added 520 companies to the Severe Violator Enforcement Program - sixty percent of which are in the construction industry.
New OSHA regulations impacting the construction industry may result in more companies facing investigations and fines, or worse yet, laying off workers and unable to compete for new work. In 2013, OSHA proposed a new mandate to reduce silicosis in workers. The mandate, which was revised multiple times before being made final in March 2016, requires that employers ensure their workers are exposed to no more than 50 micrograms of crystalline silica in an eight hour period (down from the current standard of 250 micrograms). Under the new mandate, employers are also held to heightened reporting requirements, protective measures and medical testing for employees with extended exposure to silica.
In the construction industry alone, OSHA believes the new mandate will prevent 1,080 cases of silicosis and more than 560 deaths. Builder and trade groups believe the new mandate will result in the loss of tens of thousands of jobs and cost the building industry billions of dollars. The National Association of Home Builders estimates that the Silica Rule will cost homebuilders $1,500 per start. While the two sides mount their arguments and seek support, how to implement the rule and its long term feasibility are still contested questions.
Recognizing the challenges employers will have with the heightened requirements of the Silica Rule, OSHA just announced that enforcement is being delayed 90 days to develop additional guidance for implementation of the rule in the construction industry. The new start date for enforcement of the Silica Rule is September 23, 2017.*
Many in the industry are hoping the Trump administration repeals the Silica Rule like they have “blacklisting” and the Volks rule. However, until that happens, OSHA expects your company to implement processes to ensure compliance by the new start date.
*The Silica Rule was adopted by Cal/OSHA in August 2016 even though Cal/OSHA’s own silica standard had been in place since 2008. Cal/OSHA adopted the federal standard with the June 23, 2017 effective date; however; in an effort to synchronize with OSHA, Cal/OSHA recently announced that the effective date in California will also be September 23, 2017.
Nathan Owens is the Las Vegas Managing Partner of Newmeyer & Dillion, and represents businesses and individuals operating in a wide array of economic sectors including real estate, construction, insurance and health care in all stages of litigation in state and federal court. For questions related to the OSHA and the Silica Rule, you can reach him at Nathan.Owens@ndlf.com.
Louis “Dutch” Schotemeyer is an associate in Newmeyer & Dillion’s Newport Beach office. Dutch’s practice concentrates on the areas of business litigation, labor and employment law, and construction litigation. For questions related to OSHA or the Silica Rule, you can reach him at Dutch.Schotemeyer@ndlf.com
Read the court decisionRead the full story...Reprinted courtesy of
Impact of Lis Pendens on Unrecorded Interests / Liens
September 15, 2016 —
David Adelstein – Florida Construction Legal UpdatesIn a previous article, I discussed the importance of recording a lis pendens in a construction lien foreclosure action.
There is another noteworthy point relating to the impact of lis pendens that can provide quite a bit of consternation.
Florida Statute 48.23(1)(d) provides:
Except for the interest of persons in possession or easements of use, the recording of such notice of lis pendens, provided that during the pendency of the proceeding it has not expired pursuant to subsection (2) or been withdrawn or discharged, constitutes a bar to the enforcement against the property described in the notice of all interests and liens, including, but not limited to, federal tax liens and levies, unrecorded at the time of recording the notice unless the holder of any such unrecorded interest or lien intervenes in such proceedings within 30 days after the recording of the notice. If the holder of any such unrecorded interest or lien does not intervene in the proceedings and if such proceedings are prosecuted to a judicial sale of the property described in the notice, the property shall be forever discharged from all such unrecorded interests and liens. If the notice of lis pendens expires or is withdrawn or discharged, the expiration, withdrawal, or discharge of the notice does not affect the validity of any unrecorded interest or lien.
Read the court decisionRead the full story...Reprinted courtesy of
David M. Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Colorado Senate Committee Approves Construction Defect Bill
March 19, 2015 —
Jesse Howard Witt – Acerbic WittLate last night, the Colorado Senate Business, Labor, and Technology Committee voted to refer
SB 15-177 to the committee of the whole. The vote followed nearly seven hours of testimony from those in favor of construction defect legislation and those opposed.
As I have
previously discussed, the bill sponsors have argued that their measure will encourage the construction of more affordable housing by giving builders de facto immunity for claims of defective workmanship and property damage in common interest communities. The bill achieves this by establishing difficult voting and disclosure requirements for homeowner associations and requiring costly, private arbitration of any disputes that can overcome the procedural hurdles. During the recent hearing, proponents echoed these statements and testified that insulating homebuilders from claims would lower home prices and rents by increasing the supply of cheaply-built condominiums.
Opponents questioned whether the bill contained any provisions that would actually help the affordable housing market. They also argued that it was improper for the legislature to shift the cost of fixing construction defects onto those homeowners who can least afford to pay for necessary repairs.
Read the court decisionRead the full story...Reprinted courtesy of
Jesse Howard Witt, The Witt Law FirmMr. Witt welcomes comments at www.acerbicwitt.com
New York Converting Unlikely Buildings into Condominiums
July 23, 2014 —
Beverley BevenFlorez-CDJ STAFFThe New York Times reported that New York has seen a boom of buildings such as power plants, churches, schools, parking garages, and theaters converted to apartment and condo spaces. Part of the reason for the surge was due to land scarcity—but the New York Times also stated that zoning on the “old-time structures are far bigger than what zoning would allow on their lots today.” Plus, “[a]daptive reuse can also be speedier.”
However, Toby Moskovits, president of Heritage Equity Partners, stated that the real reason might be curb appeal: “There’s a general movement now that goes beyond real estate, a reaction to a world that’s become increasingly electronic. People are more comfortable with something that feels authentic.” Heritage Equity Partners is currently converting a church-and-school complex into apartments in Williamsburg, Brooklyn.
Read the court decisionRead the full story...Reprinted courtesy of
Arctic Fires Are Melting Permafrost That Keeps Carbon Underground
December 27, 2021 —
Eric Roston - BloombergFew things signal something's gone haywire on the planet quite like frozen land on fire. Now scientists have determined that Arctic fires, even milder ones, can reshape a landscape for decades, in ways that may make it even harder to keep global heating from eclipsing international goals.
It's mostly rising temperatures that are thawing out frozen Arctic ground but northern blazes — already increasing — are now understood to play a disproportionate role, according to a study
published last week in the journal
One Earth.
Previous research has shown that higher temperatures, drier soil and more lightning storms will lead to
more fires. That work, with the new paper, mean that “in the future we might expect to see an outsized influence on thaw from the fires that will likely increase," said Róisín Commane, a Columbia University assistant professor who studies atmospheric composition and wasn’t involved in the new study.
Read the court decisionRead the full story...Reprinted courtesy of
Eric Roston, Bloomberg
