SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

---

Kadeejah Kelly Named to The National Black Lawyers’ “Top 40 Under 40” List

October 17, 2022 — Lewis Brisbois
New York, N.Y. (October 6, 2022) – New York Associate Kadeejah J. Kelly was recently named to The National Black Lawyers (NBL) “Top 40 Under 40” list. The NBL “Top 40 Under 40” recognizes the most talented black attorneys under the age of 40 who have an outstanding reputation among peers, the judiciary and the public. The honorees on this list are nominated from leading lawyers, current members, and Executive Committee members. Ms. Kelly is a member of the General Liability and Professional Liability Practices. She has extensive experience defending owners, contractors, developers and corporations in high exposure construction cases including New York Labor Law matters, premises liability and construction defect claims. She also has experience defending malpractice claims against attorneys, accountants, architects, engineers, funeral home directors and other miscellaneous professionals. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Trial Court’s Grant of Summary Judgment On Ground Not Asserted By Moving Party Upheld

December 17, 2015 — Laura C. Williams & R. Bryan Martin – Haight Brown & Bonesteel LLP
In Marlton Recovery Partners, LLC v. County of Los Angeles, et al. (filed 11/20/15), the California Court of Appeal, Second Appellate District, affirmed summary judgment in favor of the defendants County of Los Angeles, the County Treasurer-Tax Collector and Board of Supervisors (collectively the “County”) despite the fact summary judgment was granted on grounds not raised by the County. The Court of Appeal determined that because the plaintiff could not have shown a triable issue of material fact on the ground of law relied upon by the trial court, summary judgment was proper. In the underlying case, plaintiff sought cancellation of penalties on delinquent property taxes for 26 parcels under Revenue and Taxation Code §4985.2, which allows the tax collector to cancel such penalties under certain circumstances. The County denied the request prompting plaintiff to challenge the denial on a petition for peremptory writ of mandate to the trial court. Reprinted courtesy of Laura C. Williams, Haight Brown & Bonesteel LLP and R. Bryan Martin, Haight Brown & Bonesteel LLP Ms. Williams may be contacted at lwilliams@hbblaw.com Mr. Martin may be contacted at bmartin@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Deck Collapse Raises Questions about Building Defects

July 31, 2013 — CDJ STAFF
The Inquisitor reports that twenty-one people were injured when a deck collapsed at a rental apartment in Ocean Isle Beach, North Carolina. Most of the injuries were not serious. The mayor of Ocean Isle Beach attributed the problem to more people crowding onto it than it was designed for. “I do not think the N.C. building code anticipates 20 to 30 to people in a small deck at one time,” she said. Read the court decision
Read the full story...
Reprinted courtesy of

---

“Bound by the Bond”

September 02, 2024 — Daniel Lund III - Lexology
A New York trial court granted judgment in favor of a performance bond surety on a construction project, based upon the failure of the claiming party to abide by the terms of the bond. The “AIA Document A312” bond form – described by the court (quoting surety law authority) to be “one of the clearest, most definitive, and widely used type of traditional common law ‘performance bonds’ in private construction” – contains various procedures which must be honored as a “condition precedent to an action to recover” on the bond/against the surety. One of those prerequisites is a “declaration of default” concerning the contractor principal (here, a subcontractor). The case involved the construction of an 85-story skyscraper in midtown Manhattan, and the performance of the subcontract for the building’s superstructure. The bonded contract was at a value of approximately $25,000,000 and obligated the sub to provide a performance bond “in a form similar to the [A312 bond],” and which was otherwise satisfactory to the obligee/construction manager. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

The Latest News on Fannie Mae and Freddie Mac

May 01, 2014 — Beverley BevenFlorez-CDJ STAFF
The Federal Housing Finance Agency released a report on April 30th, which stated that in a severe economic downturn Fannie Mae (FNMA) and Freddie Mac (FMCC) “could require an additional bailout of as much as $190 billion… according to the results of stress tests,” according to Clea Benson writing for Bloomberg. “These results of the severely adverse scenario are not surprising given the company’s limited capital,” FNMA Senior Vice President Kelli Parsons said in a statement, as reported by Benson published in Bloomberg. “Under the terms of the senior preferred stock purchase agreement, Fannie Mae is not permitted to retain capital to withstand a sudden, unexpected economic shock of the magnitude required by the stress test.” Furthermore, in another Bloomberg article, Cheyenne Hopkins and Clea Benson reported that Democrats remain divided on how to replace FNMA and FMCC. “If we don’t get this right, we’ll create major disturbances in the housing market which will have a profound impact on families, on homeownership and certainly on our national economy,” Oregon Democrat Jeff Merkley said in an interview, as reported by Cheyenne and Benson. “Merkley described himself as ‘still in negotiations’ with the bill’s sponsors.” Read the full story, Clea Benson Article... Read the full story, Cheyenne Hopkins & Clea Benson Article... Read the court decision
Read the full story...
Reprinted courtesy of

---

Who Is To Blame For Defective — And Still LEED Certified — Courthouse Square?

September 01, 2011 — Douglas Reiser, Builders Council Blog

Remember Courthouse Square? I sure do. We have talked about the closed and evacuated LEED certified building a couple of times here on Builders Counsel. Well, it’s back in the news. This time building professionals are pointing fingers — but there is some talk about a fix. Still, its LEED certification remains.

If you read my past articles about Courthouse Square, you can get caught up on this mess. The short of it is that Salem, Oregon had the five-story government building and bus mall completed in 2000 for $34 Million. It was awarded LEED certification during the USGBC’s infancy. Last year, it became public that the building had significantly defective concrete and design. The Salem-Keizer Transit District worked with the City of Salem to shut the building down, and it has not been occupied since.

Last fall, Courthouse Square failed thorough forensic testing leading to a lengthy bout with a number of insurers.  The contractors and designers had been hauled into court, but the Transit District was able to settle with the architect and contractors. The only remaining party involved in the lawsuit appears to be the engineering firm, Century West Engineering. Most expert reports have pinned the responsibility for the poor design and materials on Century West’s shoulders.

Read the full story…

Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Seabold Construction Ties Demise to Dispute with Real Estate Developer

April 29, 2024 — Richard Korman - Engineering News-Record
When Harry W. Seabold, co-founder and CEO of Seabold Construction, died unexpectedly in January 2023 at age 69, the Beaverton, Ore.-based general contractor, which had been in business since 1984, kept chugging along for a year on two adjacent North Portland apartment projects. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---