When Is a Project Delay Material and Actionable?
January 11, 2022 —
Rick Erickson - Snell & Wilmer Real Estate Litigation BlogWelcome to 2022! This year, the construction industry will undoubtedly reflect on the last two years as unprecedented times plagued by construction project delays. The COVID-19 pandemic contributed to suspension of work and closure of construction projects worldwide in 2020. The end of 2021 brought additional delays caused by an inexplicable clog in the supply chain of construction materials. The combined impact of these events on project milestones and completion deadlines led our clients to ask, with unusual and particular urgency, who is liable for such delays and how do contracting parties lessen the consequences from such unexpected and uncontrollable delays.
Granted that project delays are nothing new or unusual. They were common enough before inflation caused shipping complications and pandemic decimated the construction labor force. All delays, whatever the source, variably cause loss to all players on a construction project. But not all delays matter when it comes to claims and remedies available to the contracting parties in dispute resolution, where the determinative focus is on material delays impacting the entire project and on delays the claimant can credibly prove.
Most, if not all, jurisdictions interpret actionable delays from the contract documents for the project. The contract is definitely where you should start before pursuing any delay remedies. Delay remedies may be a time extension only, or a time extension plus your additional general conditions. Some delay remedies may be barred by the contract’s express terms and may be enforced adversely by the courts when such contract terms are indisputable. See Quinn Constr. v. Skanska USA Bldg., Inc., 730 F. Supp. 2d 401, 411 (D.C. Pa. 2010) (enforcing the subcontractor’s contractual waiver of claims for delay and disruption damages). On the other hand, delay damages that are expressly allowed by the contract—like overtime necessitated by the delays—are usually actionable and recoverable. Id. However, not only the contract terms, but applicable law, may affect the outcome.
Read the court decisionRead the full story...Reprinted courtesy of
Rick Erickson, Snell & WilmerMr. Erickson may be contacted at
rerickson@swlaw.com
New Jersey/New York “Occurrence”
July 30, 2014 —
Scott Patterson – CD CoverageIn National Union Fire Insurance Co. of Pittsburgh, PA v. Turner Construction Co., 986 N.Y.S.2d 74 (N.Y. App. Div. 2014), Turner was the general contractor for a high rise office building constructed in New Jersey for owner GSJC. Turner subcontracted with Permasteelisa for the building’s exterior curtain wall which consisted of granite and glass with an attached network of decorative pipe rails. A segment of the pipe rails fell from the building onto the street. GSJC determined that a significant percentage of the pipe rail connections to the curtain wall did not conform to specifications or were defective. GSJC sued Turner and Permasteelisa in New Jersey state court for breach of contract, breach of warranty, and negligence, seeking damages for the damage to the curtain wall and the danger of additional pipe rail falling in the future. National Union, which had issued an OCIP policy for the project, defended Turner and Permasteelisa under a reservation of rights and then filed a declaratory judgment action in New York state court. The New York trial court entered judgment for National Union. On appeal, the intermediate court of appeals affirmed. As to choice of law, the court stated that “it is undisputed that the law of New Jersey governs this action, which turns on insurance policy interpretation, and that New Jersey and New York law are consistent as to the issues in dispute here.”
Read the court decisionRead the full story...Reprinted courtesy of
Scott Patterson, CD Coverage
Elevators Take Sustainable Smart Cities to the Next Level
May 26, 2019 —
Chris Smith - Construction ExecutiveFrom electric cars to solar panels, technology has been at the forefront of innovation in sustainability efforts. As greenhouse gas emissions continue to be a critical global concern, developing smart cities and sustainable energy practices are more important than ever.
In fact, Gartner predicts that by 2020, half of all smart city objectives will be centered around climate change, resilience and sustainability. To build truly intelligent cities, we need to optimize the sharing of information at a foundational level, starting with the structures on which these cities are built.
Where do we begin?
The United Nations estimates that almost 40 percent of today’s global greenhouse gas emissions come from buildings. To reduce these levels, the industry needs to begin creating smarter structures that use data insights to streamline functions in the building, and this starts with the infrastructural backbone: the elevator.
Reprinted courtesy of
Chris Smith, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Floors Collapse at Russian University in St. Petersburg
February 27, 2019 —
The Associated Press - BloombergSt. Petersburg, Russia (AP) -- Part of the roof and several floors of university building in Russia's second-largest city collapsed Saturday, but officials say there were no casualties.
The Emergencies Ministry said the collapse at the Saint Petersburg National Research University of Information Technologies, Mechanics and Optics took place as construction work was underway. An investigation into criminal violation of construction safety has been opened.
Read the court decisionRead the full story...Reprinted courtesy of
The Associated Press, Bloomberg
SB800 Is Now Optional to the Homeowner?
August 30, 2013 —
James Ganion - Ulich & Terry, LLPThe following communication republished courtesy of James Ganion, Ulich & Terry, LLP
Dear Builders, Colleagues, and Interested Parties:
I attach for your review a copy of this week’s opinion of the California Court of Appeal in our case of Liberty Mutual v. Brookfield. This opinion represents a significant change to the right of California builders to repair homes under SB800, California’s Right to Repair Act.
In a nutshell, the Court determined that SB800 was not intended to replace prior applicable law, but merely be supplemental to prior law. Thus, a homeowner, or in this case the homeowner’s insurer, can pick and choose among SB800 and prior law, or even allege both in the alternative. In so deciding, the Court of Appeal reversed the holding of the trial court which had held, as so many trial courts have since 2003, that SB800 was intended to be the new exclusive remedy for construction defect claims.
While we of course take issue with most of what the Court of Appeal has to say, the real life net effect is that SB800 is now optional to the homeowner, meaning the “right” to repair now lies in the hands of the homeowner who can elect to simply bypass that law and proceed with the filing of a lawsuit under prior law. Hardly what any of us believe the legislature intended.
ULICH & TERRY LLP as counsel for Brookfield in this case will be filing a petition for rehearing with the Court of Appeal by September 6, 2013. Anyone interested in supporting the petition may file a letter with the Court of Appeal, preferably by September 13, 2013. Thereafter, assuming the Court of Appeal does not grant rehearing, we will be filing a petition for review with the California Supreme Court.
Our firm, as appellate counsel, has established a website
libertymutualvbrookfieldcrystalcove.com and through it will be providing information regarding the case, including copies of pleadings, orders, deadlines, and information on how to provide support for this case, which is of interest to the home building industry.
Read the court decisionRead the full story...Reprinted courtesy of
James Ganion James Ganion can be contacted at
jganion@ut-law.com
Discovery Requests in Bad Faith Litigation Considered by Court
June 10, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe federal district court considered a variety of discovery requests by the insured in a bad faith case against State Farm. Stephens v. State Farm Fire and Cas. Co., 2015 WL 1638516 (M.D. Pa. April 13, 2015).
The insured plaintiff was a quadriplegic. His complaint alleged that he notified State Farm, through its agent, that he would have to leave his residence for medical treatment and intended to rent the home while he received care for his disabling condition. The complaint further alleged that the insured was told by State Farm's agent that his insurance would remain unaffected by his departure while he sought medical care. Nevertheless, when the insured reported loss due to vandalism and water damage at his home, State Farm relied upon his departure from the residence to cancel his insurance.
In discovery, the insured requested three categories of documents from State Farm. First, he requested State Farm's claims manuals, guidelines and instructions materials relating to insurance claims like those made by this insured. Second, the plaintiff requested performance reviews and performance incentive programs for all of State Farm's employees who played a role in decisions in this case from 2009 to the present. Finally, the plaintiff demanded that State Farm compile information relating to other insurance lawsuits brought against State Farm involving theft, vandalism and water damage claims, as well as all lawsuits or complaints regarding the conduct of this particular claims adjuster. When the materials were not produced, plaintiff filed a motion to compel.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Chinese Lead $92 Billion of U.S. Home Sales to Foreigners
July 09, 2014 —
John Gittelsohn – BloombergForeigners purchased $92.2 billion of U.S. homes in the 12 months through March, led by buyers from China, according to the National Association of Realtors.
Spending by Chinese buyers soared 72 percent from a year earlier to $22 billion, with their purchases accounting for 24 percent of spending by international buyers, the trade association said today from Washington. Total investments by foreigners jumped 35 percent.
Chinese buyers acquired 16 percent of houses sold to foreigners, up 4 percentage points, spurred by currency appreciation, rising affluence and concerns about an economic slowdown in the world’s most-populous country, the group said.
Read the court decisionRead the full story...Reprinted courtesy of
John Gittelsohn, BloombergMr. Gittelsohn may be contacted at
johngitt@bloomberg.net
An Obligation to Provide Notice and an Opportunity to Cure May not End after Termination, and Why an Early Offer of Settlement Should Be Considered on Public Works Contracts
August 17, 2020 —
Jeff Kaatz - Ahlers Cressman & SleightIn 2015, the City of Puyallup (“City”) and Conway Construction Company (“Conway”) executed a public works contract for road improvements (“Project”). On March 9, 2016, approximately four months after work started on the Project, the City issued Conway a notice of suspension and breach of contract and identified nine defective and uncorrected work and safety concerns. Conway denied any wrongdoing, and on March 25, 2016, the City issued a notice of termination for default and withheld payments due to Conway.
Conway subsequently filed suit in Pierce County Superior Court and alleged the City’s termination for default breached the contract and sought a determination that the City’s termination for default was improper and should be deemed a termination for convenience. Conway sought approximately $1.25 million in damages and recovery of its attorney fees and costs. Following a bench trial, the Trial Court found the City breached the contract and awarded Conway damages, attorney fees, and costs. The City appealed.[1]
On appeal, after affirming the trial court’s determination that the City improperly terminated Conway, the Court of Appeals considered two other issues raised by the City. First, whether the City was entitled to a set-off for replacing defective work discovered after Conway was terminated. Second, whether Conway is entitled to attorney fees if it did not make the statutorily required offer of settlement per RCW 39.04.240.
Read the court decisionRead the full story...Reprinted courtesy of
Jeff Kaatz, Ahlers Cressman & SleightMr. Kaatz may be contacted at
Jeff.Kaatz@acslawyers.com
