Columbus Ohio Building Expert Directory

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

Denial of Claim for Concealment or Fraud Reversed by Sixth Circuit

October 01, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Sixth Circuit reversed the district court's order granting summary judgment to State Farm based upon the insured's alleged concealment of the truth when questioned about a fire that destroyed his home. Rose v. State Farm Fire & Cas. Co., 2014 U.S. App. LEXIS 17312 (6th Cir. Sept. 8, 2014). A fire destroyed the insured's home. He reported the loss to State Farm, who assigned Rob Raker to investigate the claim. Coverage was denied because State Farm contended that the "Intentional Acts" and "Concealment or Fraud" conditions of the homeowner's policy were violated. The insured sued State Farm. The district granted summary judgment to State Farm after finding that some of the answers the insured gave to Raker were misleading and material. The court determined that the insured failed to identify multiple tax liens and judgments when questioned about his financial status. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The General Assembly Seems Ready to Provide Some Consistency in Mechanic’s Lien Waiver

March 14, 2018 — Christopher G. Hill – Construction Law Musings
Back in 2015, the Virginia General Assembly amended the mechanic’s lien statute (Va. Code 43-3) here in Virginia to preclude any contractual provision that diminishes a subcontractor or supplier’s “lien rights in a contract in advance of furnishing any labor, services, or materials.” However, this amendment was only applicable to subcontractors and suppliers. For political and other reasons, general contractors in Virginia were left out of this change. This omission by the legislature put Virginia general contractors in the position of potentially being forced by project owners to waive their mechanic’s lien rights without the ability to run that risk downstream to their subcontractors and suppliers. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Partner John Toohey and Senior Associate Sammy Daboussi Obtain a Complete Defense Verdict for Their Contractor Client!

December 11, 2023 — Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is excited to share that Newport Beach attorneys John Toohey and Sammy Daboussi obtained a complete defense verdict after years-long litigation in favor of their concrete contractor client. This lawsuit arises from a claim made by Plaintiff for construction defects in a high-end single-family home. Our client was hired to perform concrete work on the foundations of the home. It was alleged that the home’s foundation was incorrectly built. It was further alleged that the construction defects/errors led to delays and substantial expenses. We argued that our client relied on the certifications provided to them by design professionals and the City. We further argued that our client, like any reasonable concrete/foundation subcontractor, has no responsibility or obligation, contractual or otherwise, to review and recheck the work completed by a licensed professional. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

Show Me the Money: The Good Faith Dispute Exception to Prompt Payment Penalties

March 13, 2023 — Garret Murai - California Construction Law Blog
California has a number of prompt payment penalty statutes on the books. Among them is Civil Code section 8800 which requires project owners on private works projects to pay progress payments to direct contractors within 30 days after demand for payment pursuant to contract or be subject to prompt payment penalties of two percent (2%) per month on the amount wrongfully withheld. Like California’s other prompt payment penalty statutes, however, there is an important carve out: If there is a good faith dispute between the project owner and the direct contractor the project owner may withhold up to 150% of the dispute amount and not be subject to prompt payment penalties. And that, my friends, is a higher-tiered party’s “get out of jail free” card. In a case of first impression, the 1st District Court of Appeals, in Vought Construction Inc. v. Stock (2022) 84 Cal.App.5th 622, examined whether a project owner’s claim for liquidated damages constitutes a good faith dispute under Civil Code section 8800. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Microwave Transmission of Space-Based Solar Power: The Focus of New Attention

July 24, 2023 — Robert A. James & William E. Fork - Gravel2Gavel Construction & Real Estate Law Blog
Scientists have long proposed that solar electricity generation in space could be an integral component of the world’s carbon-free future. In the 1970s, a U.S. Navy experiment showed that it might be possible to capture solar power and wirelessly transmit it from outer space using microwave beams. Progress stalled after that early test—the models used were at such a massive scale that creating a real-world system felt like science fiction. Recently, amid growing concerns about power grid security and intensifying legislation around carbon emissions, renewed attention focused on a smaller, more lithe microwave transmission system. This time around, the military is not the only interested party. Scientists around the world are conducting similar research. As investors and governments stand at the edge of a fresh green power opportunity, we look at microwave power transmission and some of the projects in this emerging field. The basic premise of space-based solar power technology is simple enough: photovoltaic panels on a satellite in space convert the sun’s energy to electromagnetic waves at microwave frequencies. The satellite then beams the microwave energy to a receiver on Earth that transforms it into direct current. Until recently, this technique had been performed on the ground over short distances, but nobody had attempted to launch a solar panel into space. The status quo has shifted over the past few years as researchers have begun to send prototypes into orbit. In early 2023, CalTech was the first to report a breakthrough. Its model successfully beamed power from space back to their receiver atop a building in California. Reprinted courtesy of Robert A. James, Pillsbury and William E. Fork, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Mr. Fork may be contacted at william.fork@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Attorneys’ Fees and the American Arbitration Association Rule

September 09, 2024 — Bill Wilson - Construction Law Zone
A common question from clients, when a dispute arises on a construction project, is whether they can recover their attorney’s fees from the other side if they pursue a case and win. More often than not, such fees are not recoverable. As a general rule (commonly known as the “American Rule”), each party to a dispute must bear their own attorney’s fees unless there is some statutory provision or contractual agreement between the parties allowing otherwise. Since most construction disputes involve claims for breach of contract and/or negligence, no realistic statutory provision often allows for attorney’s fees. Many construction contracts do not typically provide a prevailing party the right to collect attorney’s fees from the other side. However, even if the American Rule applies, there may be another path to recovering attorney’s fees if the parties agree to arbitrate their dispute under the American Arbitration Association (AAA) rules. Reprinted courtesy of Bill Wilson, Robinson & Cole LLP Mr. Wilson may be contacted at wwilson@rc.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The Latest News on Fannie Mae and Freddie Mac

May 01, 2014 — Beverley BevenFlorez-CDJ STAFF
The Federal Housing Finance Agency released a report on April 30th, which stated that in a severe economic downturn Fannie Mae (FNMA) and Freddie Mac (FMCC) “could require an additional bailout of as much as $190 billion… according to the results of stress tests,” according to Clea Benson writing for Bloomberg. “These results of the severely adverse scenario are not surprising given the company’s limited capital,” FNMA Senior Vice President Kelli Parsons said in a statement, as reported by Benson published in Bloomberg. “Under the terms of the senior preferred stock purchase agreement, Fannie Mae is not permitted to retain capital to withstand a sudden, unexpected economic shock of the magnitude required by the stress test.” Furthermore, in another Bloomberg article, Cheyenne Hopkins and Clea Benson reported that Democrats remain divided on how to replace FNMA and FMCC. “If we don’t get this right, we’ll create major disturbances in the housing market which will have a profound impact on families, on homeownership and certainly on our national economy,” Oregon Democrat Jeff Merkley said in an interview, as reported by Cheyenne and Benson. “Merkley described himself as ‘still in negotiations’ with the bill’s sponsors.” Read the full story, Clea Benson Article... Read the full story, Cheyenne Hopkins & Clea Benson Article... Read the court decision
Read the full story...
Reprinted courtesy of

COLUMBUS OHIO BUILDING EXPERT DIRECTORY AND CAPABILITIES