Contractor’s Burden When It Comes to Delay
October 26, 2020 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:
When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.
Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Civil Engineers: Montana's Infrastructure Grade Declines to a 'C-'
December 23, 2024 —
American Society of Civil EngineersHelena, MT — The Montana Section of the
American Society of Civil Engineers (ASCE) today released the
2024 Report Card for Montana's Infrastructure, assigning 14 categories of infrastructure a cumulative grade of 'C-', which is on par with the national average from the
2021 Report Card for America's Infrastructure. This is a one-notch decrease from the 'C' grade Montana received in its last report in 2018, citing increasingly severe weather events putting strain on aging and underfunded assets, and one of the fastest growing populations requiring expansions of transportation, water and energy infrastructure.
The report includes the first-ever chapter on Montana's broadband infrastructure, assigning an 'I' grade for 'incomplete' due to a lack of sufficient condition data; however, the chapter does note that 71% of Montana residents have access to adequate broadband service, and the IIJA provided nearly $630 million to expand this access across the state.
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 160,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
Read the court decisionRead the full story...Reprinted courtesy of
California Court of Appeal: Inserting The Phrase “Ongoing Operations” In An Additional Endorsement Is Not Enough to Preclude Coverage for Completed Operations
September 14, 2017 —
Gary Barrera - California Construction Law BlogIn a victory for additional insureds, a California appeals court held, in Pulte Home Corp. v. American Safety Indemnity Co., Cal.Ct.App. (4th Dist.), Docket No. D070478 (filed 8/30/17), that an insurer’s denial of coverage for completed operations based on the inclusion of the phrase “ongoing operations” in an additional insured endorsement, was improper. Additionally, an insurer wishing to limit coverage under an additional insured endorsement to ongoing operations must do so via clear and explicit language.
Read the court decisionRead the full story...Reprinted courtesy of
Gary Barrera, Wendel Rosen Black & Dean LLPMr. Barrera may be contacted at
gbarrera@wendel.com
Ohio Court of Appeals: Absolution Pollution Exclusion Bars Coverage for Workplace Coal-Tar Pitch Exposure Claims
January 10, 2018 —
Complex Insurance Coverage ReporterOn December 28, 2017, the Ohio Court of Appeals (Eighth District) held in GrafTech International, Ltd., et al. v. Pacific Employers Ins. Co., et al., No. 105258 that coverage for alleged injurious exposures to coal tar pitch was barred by a liability insurance policy’s absolute pollution exclusion. Applying Ohio law, the court concluded that Pacific Employers had no duty to defend GrafTech or pay defense costs in connection with claims by dozens of workers at Alcoa smelting plants that they were exposed to hazardous substances in GrafTech products supplied to Alcoa as early as 1942.
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams LLP
New York’s Comprehensive Insurance Disclosure Act Imposes Increased Disclosure Requirements On Defendants at the Beginning of Lawsuits
February 07, 2022 —
Craig Rokuson & Lisa M. Rolle - Traub Lieberman Insurance Law BlogOn December 31, 2021, New York Governor Kathy Hochul signed into law the Comprehensive Insurance Disclosure Act, which amends Section 3101(f) of the Civil Practice Law & Rules (CPLR) to require the automatic disclosure of insurance-related items within sixty days of the filing of an answer in a civil suit. For lawsuits pending as of the effective date of the Act, the disclosures required by Section 3101(f) must be provided by March 1, 2022.
Pursuant to amended Section 3101(f), defendants (including third-party defendants, cross-claim defendants, and counterclaim defendants) must provide the following information to plaintiffs within sixty days of answering the affirmative pleading, accompanied with a certification from both the defendant and his/her/their/its defense counsel that the disclosures are accurate and complete:
- Copies of all insurance policies that may be liable to satisfy a judgment in the lawsuit, including the insurance application.
- The contact information of any individuals responsible for adjusting the claim on each policy, including his/her/their phone number and email address. If a TPA is involved, his/her/their contact information must also be disclosed.
Reprinted courtesy of
Craig Rokuson, Traub Lieberman and
Lisa M. Rolle, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com
Ms. Rolle may be contacted at lrolle@tlsslaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Chinese Billionaire Developer Convicted in UN Bribery Case
August 02, 2017 —
Bob Van Voris - BloombergA Chinese developer was convicted of charges he paid bribes to win backing for a United Nations conference center that he hoped to build in Macau.
A jury in Manhattan on Thursday found the developer, billionaire Ng Lap Seng, guilty of all six charges he faced, including conspiracy, bribery and money laundering, in the biggest UN corruption scandal since the oil-for-food program in the early 2000s. Prosecutors claimed Ng funneled hundreds of thousands of dollars to former UN General Assembly President John Ashe and other officials.
Read the court decisionRead the full story...Reprinted courtesy of
Bob Van Voris, Bloomberg
Keeping Detailed Records: The Best Defense to Constructive Eviction
October 24, 2023 —
Ben T. Welch & Ken Brown - Snell & WilmerInevitably, commercial property owners and managers will be faced with a claim by a tenant of constructive eviction. This article is intended to describe what constructive eviction is and to suggest what owners and managers can do to prepare for, and ward off, such claims.
Constructive eviction occurs where a tenant’s “right of possession and enjoyment” of the leasehold is disrupted by the landlord in a manner that renders the premises “unsuitable for the purposes intended.”i Put another way, it is interference that is so “substantial nature and so injurious as to deprive the tenant of the beneficial enjoyment of a part or the whole of the demised premises.”ii Although easy to describe in theory, constructive eviction can be devilishly difficult to determine in the real world. In litigation, determining when interference crosses over the line to constructive eviction is intensely fact-sensitive and resists sweeping generalizations.iii
For instance, Utah courts have held that tenants have been constructively evicted when they have been subjected to continual harassment or insults by the landlord or the landlord’s agent,iv prevented or impaired in their access to the leased premises during operating hours,v or when a landlord fails to provide an operable elevator (or other essential commercial amenities) necessary for a tenant’s business operations.vi By contrast, claims of “discomfort” or “inconvenience” have been rejected as a basis for constructive eviction.vii The same goes for claims that a landlord wrongfully served a three-day notice to pay or quit.viii
Generally, constructive eviction is an affirmative defense made in response to a landlord’s lawsuit for nonpayment of rent.ix It is not, as is commonly supposed, a basis for a tenant’s premature abandonment of the premises. In other words, the defense is raised after the tenant has vacated as a result of being effectively “evicted.”x Further, the defense requires the tenant to actually abandon the premises and do so within a “reasonable time” after the alleged interference.xi A tenant cannot stay in possession and simply refuse to pay rent on the basis of constructive eviction.xii
The key consideration in preparing for, and responding to, a claim of constructive eviction is keeping good records. A tenant claiming constructive evicting likely must prove that the issue was raised in a timely manner and, despite multiple entreaties, was never resolved.xiii As such, it is critical that landlords acknowledge tenant complaints as well as document in writing their efforts to ameliorate those complaints. While a landlord does not carry the burden of proof for constructive eviction, detailed documentation can thwart a tenant’s claim that a landlord has been inattentive or unwilling to address the tenant’s concerns.
Detailed records are also useful in disputes where a tenant claims substantial interference. “The whole point of constructive eviction is that the landlord basically drove the tenant out through the landlord’s action or inaction.”xiv As such, a landlord that is unable to document the steps taken in response to complaints will be grossly disadvantaged whereas the tenant, which had control and knowledge of the premises, will have a much easier time describing how the alleged interference deprived them of enjoying the premises.
Even with meticulous records, however, owners and managers may still face claims of construction eviction. In such instances, counsel should be retained to properly advise on compiling, preserving, and employing the evidence necessary to refute the tenant’s claims.
i Gray v. Oxford Worldwide Grp., Inc., 139 P.3d 267, 269 (Utah Ct. App. 2006).
ii Gray, 139 P.3d at 270 (citing Neslen, 254 P.2d at 850) (internal formatting omitted).
iii See Gray, 139 P.3d at 269–70 (citing Thirteenth & Washington Sts. Corp. v. Neslen, 254 P.2d 847, 850 (Utah 1953)); Brugger v. Fonoti, 645 P.2d 647, 648 (Utah 1982).
iv See Gray, 139 P.3d at 270–71.
v Thirteenth & Washington Sts. Corp. v. Neslen, 254 P.2d 847 (Utah 1953).
vi See Richard Barton Enterprises, Inc. v. Tsern, 928 P.2d 368, 375, 378 (Utah 1996) (citing Union City Union Suit Co. v. Miller, 162 A.D.2d 101, 556 N.Y.S.2d 864 (1990)).
vii See Myrah v. Campbell, 163 P.3d 679, 682–84 (Utah Ct. App. 2007).
viii Barton v. MTB Enterprises, 889 P.2d 476, 477 (Utah Ct. App. 1995); see also Brugger, 645 P.2d at 648 (stating that the tenant’s complaints revolved around standard problems commonly associated with building maintenance and did not rise to the level of substantial interference); viv Reid v. Mutual of Omaha Ins. Co., 776 P.2d 896, 898–900 (Utah 1989) (upholding trial court’s findings of fact concerning insufficiency of disruption so as to justify claim for constructive eviction).
ix See Kenyon v. Regan, 826 P.2d 140, 142 (Utah Ct. App. 1992).
x See Kenyon, 826 P.2d at 142.
xi See Kenyon, 826 P.2d at 142; see also Barton v. MTB Enterprises, Inc., 889 P.2d 476, 477 (Utah Ct. App. 1995); Brugger, 645 P.2d at 648.
xii See Kenyon, 826 P.2d at 142 (citing Fernandez v. Purdue, 518 P.2d 684, 686 (Utah 1974)).
xiii See Brugger, 645 P.2d at 648 (noting that while the tenant had raised legitimate issues concerning state of the premises, the landorld had taken steps to remedy the problems within a reasonable time) (citing 49 Am.Jur.2d, Landlord and Tenant, § 617).
xiv Barton, 889 P.2d at 477.
Reprinted courtesy of
Ben T. Welch, Snell & Wilmer and
Ken Brown, Snell & Wilmer
Mr. Welch may be contacted at bwelch@swlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Lightstone Committing $2 Billion to Hotel Projects
February 26, 2015 —
Nadja Brandt – Bloomberg(Bloomberg) -- David Lichtenstein, whose real estate company owned Extended Stay Hotels when the chain went bankrupt, is committing $2 billion to developing and investing in lodging properties.
Lightstone Group is choosing “top-branded” select-service properties, those with limited amenities, in proven U.S. markets for its projects, Lichtenstein said in an interview. As part of the strategy, Lightstone has teamed up with Marriott International Inc. to build five Moxy hotels in New York -- four in Manhattan and one in Brooklyn. The “micro” lodgings, with high-tech features and smaller-than-average rooms, are geared toward younger travelers.
Read the court decisionRead the full story...Reprinted courtesy of
Nadja Brandt, BloombergMs. Brandt may be contacted at
nbrandt@bloomberg.net
