FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Businesspeople to Nevada: Revoke the Construction Defect Laws

March 01, 2012 — CDJ STAFF

The Nevada chapter of the National Federation of Independent Businesses has said that Nevada’s construction defect and minimum wage laws are hampering job growth. The organization conducted a survey, and although only about two percent of the members responded, they passed the opinions of the group on to Governor Brian Sandoval. Sandoval has said, according to the report by Fox News Reno, that he wants the state to be more business friendly. He supports reforms to Nevada’s construction defect laws, saying that he’d “like to see some reform” on the issue of mandatory attorney’s fees.



Randi Thompson, the spokesperson for the Nevada chapter of the National Federation of Independent Businesses, said that members of her organization would like to see current Nevada construction defect law revoked. She described current law as “driven towards lawyers and not toward protecting consumers.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

The CA Supreme Court Grants Petition for Review of McMillin Albany LLC v. Super Ct. 2015 F069370 (Cal.App.5 Dist.) As to Whether the Right to Repair Act (SB800) is the Exclusive Remedy for All Defect Claims Arising Out of New Residential Construction

December 02, 2015 — Richard H. Glucksman, Esq., Glenn T. Barger, Esq., Jon A. Turigliatto, Esq., & David A. Napper, Esq. – Chapman Glucksman Dean Roeb & Barger Bulletin
As anticipated in a prior CGDRB 2015 Bulletin that discussed the Fifth Appellate District Court’s noteworthy opinion in McMillin Albany LLC v. Super Ct. 2015 F069370 (Cal.App.5 Dist), the California Supreme Court has granted the petition for review of the McMillin Albany decision. The Supreme Court will attempt to resolve the conflict of authority presented by the Fourth Appellate District Court’s opinion in Liberty Mut. Ins. Co. v. Brookfield Crystal Cove LLC (2013) 219 Cal.App.4th 98 and the Fifth Appellate District Court’s rejection of the Liberty Mutual holding in McMillin Albany. In Liberty Mutual, the Fourth District Court of Appeal held that compliance with SB800’s pre-litigation procedures prior to initiating litigation is only required for defect claims [violations of SB 800’s building standards] that have not yet resulted in actual property damage. Where damage has occurred, a homeowner may initiate litigation under common law causes of action without first complying with the pre-litigation procedures set forth in SB 800. Two years later, the Fifth District Court of Appeal, in McMillin Albany, held that the California Legislature intended that all construction defect claims arising out new residential construction are subject to the standards and requirements of the Right to Repair Act [SB800], including specifically, the requirement that the claimant provide the builder with notice and an opportunity to repair prior to filing a lawsuit. According to the Court, SB 800 is the exclusive remedy for all defect claims arising out of new residential construction sold on or after January 1, 2003. The holdings in Liberty Mutual and McMillin Albany present a conflict of authority that the California Supreme Court has appropriately deemed worthy of review. The parties will now be permitted to file briefs on the merits and amicus briefs will certainly be submitted by the defense and plaintiff bars. Our firm will be closely monitoring this case, the outcome of which will significantly impact pre-litigation construction defect claims going forward. We will provide updates as to further activities and the Supreme Court’s decision. Reprinted courtesy of Chapman Glucksman Dean Roeb & Barger attorneys Richard H. Glucksman, Glenn T. Barger, Jon A. Turigliatto and David A. Napper Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com Mr. Barger may be contacted at gbarger@cgdrblaw.com Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com Mr. Napper may be contacted at dnapper@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

New York Appeals Court Rekindles the Spark

March 16, 2017 — Lian Skaf - White and Williams LLP
In John Trimble, et al. v. City of Albany, et al., 2016, 144 A.D.3d 1484; 42 N.Y.S. 3d 432 (N.Y. App. Div.), the Supreme Court of New York, Appellate Division, addressed the issue of governmental immunity for municipal fire companies. The court held that the plaintiff, John Trimble (Trimble), had sufficient evidence related to the four-pronged test for establishing a “special relationship” between a municipality and a citizen for liability to attach. In addition, the court held that the defendants were not entitled to summary judgment on the issue of governmental immunity. Specifically, regarding the latter holding, the court stated that, when there is no actual choice made on the part of the government, the government’s actions cannot be considered discretionary and immunity will not apply. In the case at hand, a fire occurred at Trimble’s home on the evening of February 2, 2013. Trimble called 911 and the Department of Fire and Emergency Services for the City of Albany (the Department) responded. After extinguishing the fire, the Department conducted an investigation and cleared the home. The Department’s investigators then told Trimble that the fire was extinguished and it was safe to enter the home. Trimble did so, removing some items so that he could stay with relatives that night. Several hours later, there was a rekindle and the rekindled fire destroyed the home. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

---

Manhattan Homebuyers Pay Up as Sales Top Listing Price

October 01, 2014 — Oshrat Carmiel – Bloomberg
Manhattan apartment prices rose 4.2 percent in the third quarter, bolstered by buyers who increasingly agreed to pay what sellers were asking or more. The median sale price of condominiums and co-ops was $908,242, up from $872,000 a year earlier, according to a report today from appraiser Miller Samuel Inc. and brokerage Douglas Elliman Real Estate. The average price per square foot increased 12 percent to $1,270, the third-highest in records dating to 1989, the firms said. Prices in Manhattan have climbed for four consecutive quarters, encouraging more owners to list properties after an inventory shortage last year. With the number of apartments on the market up 28 percent from the third quarter of 2013, buyers focused on those that were not-too-ambitiously priced, said Jonathan Miller, president of New York-based Miller Samuel. Read the court decision
Read the full story...
Reprinted courtesy of Oshrat Carmiel, Bloomberg
Mr. Carmiel may be contacted at ocarmiel1@bloomberg.net

---

Massachusetts Federal Court Rejects Adria Towers, Finds Construction Defects Not an “Occurrence”

July 03, 2022 — Eric B. Hermanson & Austin D. Moody - White and Williams
In an important ruling for insurers, U.S. District Court Judge Patti Saris found that Massachusetts does not follow the position taken in Cypress Point Condo Association v. Adria Towers, LLC, 226 N.J. 403, 418 (2016), i.e., it does not hold that "faulty workmanship claims [should be recognized] as ... an 'occurrence,' thus triggering coverage, 'so long as the allegedly defective work [was] performed by a subcontractor rather than the policyholder itself."[1] Instead, Judge Saris reaffirmed earlier Massachusetts authority holding faulty work is not an "occurrence" for coverage purposes,[2] and found this authority applied whether or not the work in question was subcontracted. In the alternative, Judge Saris found, even if a contractor's faulty work could be deemed an an "occurrence," such work did not constitute covered "property damage," because none of the alleged damage was "outside the scope of the work that Tocci was contractually required to fulfill as general contractor."[3] Reprinted courtesy of Eric B. Hermanson, White and Williams and Austin D. Moody, White and Williams Mr. Hermanson may be contacted at hermansone@whiteandwilliams.com Mr. Moody may be contacted at moodya@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Is the Construction Industry Actually a Technology Hotbed?

August 19, 2024 — Andrew Silver - Construction Executive
Technology has always been a driving force behind progress, and the construction industry is no exception. Over the years, technological advancements have revolutionized the way companies design, plan and build structures, leading to increased efficiency, safety and sustainability. From virtual-reality simulations to drones and 3D printing, technology has transformed every aspect of the construction process. However, the construction trades still lag behind other sectors in adoption of digital technologies. With a lack of skilled labor continuing to be an impediment to growth and profitability in the construction industry, technological developments could have significant implications for successful adopters. Already, the industry is seeing a huge difference in valuation between traditional engineering and construction firms and construction software companies. As labor shortages continue to hinder growth in the industry, consolidation is likely, as is the probability that companies with the greatest tech capabilities will be the most highly valued. There are several areas of technology that are of the greatest interest in the current marketplace. BIM Building information modeling with computer-aided design software now allows architects and engineers to create detailed and accurate 3D models of buildings and infrastructure projects, integrating data about every aspect of the building, from materials and costs to energy efficiency and maintenance schedules. These models not only help in visualizing the final product; they also enable better communication and collaboration among project stakeholders. Reprinted courtesy of Andrew Silver, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Higgins, Hopkins, McLain & Roswell Recognized in 2024 Best Law Firm® Rankings

November 16, 2023 — David M. McLain – Colorado Construction Litigation Blog
We are thrilled to announce that Higgins, Hopkins, McLain & Roswell, LLC (“HHMR”) has been recognized in the 2024 Best Law Firm® rankings. Our firm has been placed in Metro Tier 2 in Colorado for Construction Law, a testament to our unwavering commitment to providing top-tier legal services. At HHMR, we pride ourselves on our expertise in construction law and the litigation of construction-related claims. Our team of dedicated attorneys is well-versed and experienced in tort, contract, property, and general casualty litigation. This recognition by Best Lawyers affirms our dedication to serving our clients selflessly and to the best of our ability. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---