Fairfield Connecticut Building Expert Directory

Request for Stay Denied in Dispute Over Coverage for Volcano Damage

August 10, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Although there were concurrent state and federal proceedings regarding the insureds' claims for damage caused by Kilauea Volcano, the federal district court refused to dismiss or stay the federal action. Aqulina v Certain Underwriters at Lloyd's Syndicate #2003, 2020 U.S. District Ct. LEXIS 101832 (D. Haw. June 10, 2020). Plaintiffs held homeowner's policies from Lloyd's that were brokered and underwritten by various defendants. Coverage from the May 2018 eruption of Kilauea Volcano was denied based upon an exclusion precluding coverage for lava-related damage. Plaintiffs sued Lloyds and various brokers in federal court, alleging that defendants had engaged in a deceptive scheme to defraud plaintiffs and deprive them of meaningful coverage. Lawsuits were also filed in state court, with plaintiffs arguing their losses were covered by their policies and that defendants wrongfully relied solely on the lava exclusion to deny claims. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Beverly Hills Voters Reject Plan for Enclave's Tallest Building

November 10, 2016 — James Nash – Bloomberg
A costly battle over development in Beverly Hills, California, ended with voters rejecting a hotel owner’s proposal to combine two planned condominium towers into a single building that would have loomed over the wealthy Southern California enclave. With 44 percent in support and 56 percent against, Beverly Hills voters turned down plans by Beny Alagem, who owns the Beverly Hilton and is building an adjacent 170-room Waldorf Astoria, to develop a single 26-story tower next to the hotels, instead of eight- and 18-story buildings that were approved by the city council and a voter referendum in 2008. Alagem’s plan sets aside the remaining 1.7 acres (0.7 hectares) for a public park and gardens. Read the court decision
Read the full story...
Reprinted courtesy of James Nash, Bloomberg

Georgia Amends Anti-Indemnity Statute

June 02, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
In its most recent session, the Georgia General Assembly passed HB 943, which amends Georgia’s Anti-Indemnity Statute. The amendment expands the Anti-Indemnity Statute beyond construction contracts to include contracts for engineering, architectural, and land surveying services (“A/E Contracts”). In a prior post, we discussed Georgia’s Anti-Indemnity Statute, which generally prohibits indemnity clauses in construction contracts that require one party (the “Indemnitor”) to indemnify another party (the “Indemnitee”) if property damage or bodily injury results from the Indemnitee’s sole negligence. The prior post, discussed the Supreme Court of Georgia’s broad interpretation of the Anti-Indemnity Statute. HB 943 adds subpart (c), which states:

A covenant, promise, agreement, or understanding in or in connection with or collateral to a contract or agreement for engineering, architectural, or land surveying services purporting to require that one party to such contract or agreement shall indemnify, hold harmless, insure, or defend the other party to the contract or other named indemnitee, including its, his, or her officers, agents, or employees, against liability or claims for damages, losses, or expenses, including attorney fees, is against public policy and void and unenforceable, except for indemnification for damages, losses, or expenses to the extent caused by or resulting from the negligence, recklessness, or intentionally wrongful conduct of the indemnitor or other persons employed or utilized by the indemnitor in the performance of the contract. This subsection shall not affect any obligation under workers’ compensation or coverage or insurance specifically relating to workers’ compensation, nor shall this subsection apply to any requirement that one party to the contract purchase a project specific insurance policy or project specific policy endorsement.

(Emphasis added.) Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Home insurance perks for green-friendly design (guest post)

February 04, 2014 — Melissa Dewey Brumback – Construction Law in North Carolina
Wondering how to get your residential clients to pony up more money for green design? Check out today’s guest post by Carrie Van Brunt-Wiley and Katherine Wood. They are writers for the Homeowners’ Insurance Blog, which serves as a resource center for insurance consumers and homebuyers across the country. The U.S. Green Building Council’s new LEEDv4 standards present challenges for contractors, engineers, and architects – the restrictions in many cases are more stringent. There is, however an added bonus to remaining on the sustainable-building track: it’s more marketable than you think. That’s because green homes don’t just appeal to buyers with environmental concerns any more. Now smart budgeters seek them out as well. Why? While it’s true that sustainable construction can cost about 2% more than conventional methods, McGraw-Hill’s Smart Market Report says it typically increases a building’s overall value by an average of 7.5% and improves the return on investment by 6.6%. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback can be contacted at mbrumback@rl-law.com

That’s What I have Insurance For, Right?

December 31, 2014 — Craig Martin – Construction Contractor Advisor
Ah, the age old question, What does my insurance really cover? A federal court in Georgia recently weighed in on this issue in Standard Contractors, Inc. v. National Trust Insurance Company, and ruled that a contractor’s commercial general liability insurer did not have to pay for damage caused by a subcontractor. Standard Contractors was hired to renovate the pool on an army base. Standard hired a subcontractor to for design and installation work. The subcontractor’s work was subpar in that the subcontractor omitted a number of parts, installed the wrong parts, and caused more than $400,000 in damage to the pool. Standard submitted a claim to its insurer seeking coverage for the loss under its commercial general liability policy. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

U.S. Housing Starts Top Forecast on Single-Family Homes

December 17, 2015 — Victoria Stilwell – Bloomberg
New-home construction in the U.S. rebounded in November, led by gains in single-family dwellings that signal the residential real estate industry will continue to support growth in the world’s largest economy. Housing starts climbed 10.5 percent to a 1.17 million annualized rate from a 1.06 million pace in October, figures from the Commerce Department showed Wednesday in Washington. The median estimate of 81 economists surveyed by Bloomberg was for a 1.13 million rate. Work began on the most stand-alone houses since January 2008, and permits for similar projects reached an eight-year high. Read the court decision
Read the full story...
Reprinted courtesy of Victoria Stilwell, Bloomberg

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New Proposed Regulations Expand CFIUS Jurisdiction Regarding Real Estate

January 20, 2020 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
On September 17, 2019, the U.S. Department of Treasury issued two new proposed rules for the Committee on Foreign Investment in the United States (CFIUS) implementing the Foreign Investment Risk Review Modernization Act (FIRRMA). Of particular interest to readers of this blog was the second of the proposed rules, which addressed FIRRMA’s real estate-related expansion of CFIUS jurisdiction. Pillsbury's Construction & Real Estate Law Team Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES