Candis Jones Named to Atlanta Magazine’s 2024 “Atlanta 500” List
February 26, 2024 —
Candis Jones - Lewis Brisbois NewsroomAtlanta, Ga. (February 9, 2024) – Atlanta Partner Candis R. Jones has been named to Atlanta Magazine’s 2024 “Atlanta 500” list of the most powerful law professionals in Atlanta. This is the fourth year in a row she has received this recognition.
To compile this list, the publication reviewed nominations from the public and consulted experts across various sectors. The magazine’s editors and writers considered not only the status of the nominees within their respective organizations, but also whether the nominees were visionaries who led programs for their communities and created opportunities for employees. According to Atlanta Magazine, this list is “an anthology of the power that resides in Atlanta.”
Read the court decisionRead the full story...Reprinted courtesy of
Candis Jones, Lewis BrisboisMs. Jones may be contacted at
Candis.Jones@lewisbrisbois.com
Reminder: Just Being Incorporated Isn’t Enough
June 29, 2020 —
Christopher G. Hill - Construction Law MusingsI have discussed why contractors need to incorporate previously here at Construction Law Musings. Among the many reasons to incorporate are possible tax benefits and the protection of personal assets (like your house and your dog) from judgement and collection actions. This latter reason is key in the construction world in which Murphy can look like an optimist and projects have so many moving parts that something is likely to go wrong.
The reason incorporation works as at least a partial shield is that the company and the owners are separate “people” or entities from a legal perspective and a contract with one “person” cannot be enforced against another. This same logic applies in the context of corporate versus individual actions, i. e. the actions of one person cannot be legally attributed to another person. By extension the assets of an individual cannot be collected to satisfy a purely corporate debt or judgment.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Real Estate & Construction News Roundup (1/10/24) – New Type of Nuclear Reactor, Big Money Surrounding Sports Stadiums, and Positivity from Fannie Mae’s Monthly Consumer Survey
February 05, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, the commercial real estate market poses a risk to financial stability, New York City moves towards net-zero building emissions, workers at several Los Angeles area hotels tentatively agree to a new contract, and more!
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Understanding Entitlement to Delays and Proper Support
December 10, 2024 —
Andrew G. Vicknair - The Dispute ResolverIn a previous
post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method.
Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay.
If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
What to Expect From the New Self-Retracting Devices Standard
November 29, 2021 —
Andre Pelland - Construction ExecutiveOne of the latest and most anticipated changes to occur this year relevant to fall protection is the publishing of the ANSI/ASSP Z359.14 2021 revision. Although the effective date isn’t until August 2022, this change is prompting the need for end user to prepare for using and understanding the new terminology performance requirements that will ultimately alter equipment selection criteria.
The reason for its relevance is mostly due to its industry dependence and the increasing popularity of these types of devices. This voluntary consensus standard accounts for a vast portion of the fall protection market equipment and has been adopted as the industry standard, even though it is not the legal requirement. To assure a smooth transition, the immediate priority should be to understand the changes and what it means from a usability standpoint. A clear understanding of what changes devices need to comply will allow users to proceed with a comprehensive transition plan.
What Are the Most Relevant Changes for the User?
Classes
The most significant changes are for Class A and B devices used to designate arrest distances and forces and the introduction of the Class 1 and 2 devices. These classes were known as designators for arresting falls at 24 inches and under with higher forces (Class A), and 54 inches and under with lower forces (Class B). Class 1 devices allow anchoring on overhead anchorages only and limitg freefall to no more than two feet.
Reprinted courtesy of
Andre Pelland, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Pelland may be contacted at
andre.pelland@puresafetygroup.com
No Interlocutory Appeals of "Garden-Variety" Contract Disputes
March 12, 2015 —
Jesse Howard Witt – Acerbic WittColorado’s new procedure for interlocutory appeals has its limits. In the recent decision of Rich v. Ball Ranch Partnership, ___ P.3d ___, 2014 COA 6 (2015), the Colorado Court of Appeals held that Appellate Rule 4.2 does not permit interlocutory review of questions of law in “garden-variety” or “run-of-the-mill” contract disputes. This resolves a subtle question that has been lingering since Colorado first created the interlocutory appeal process four years ago.
Prior to 2011, Colorado did not permit civil litigants to seek appellate review prior to final judgment, except in a small handful of situations. As I discussed in an article at the time, this changed with the passage of C.R.S. § 13-4-102.1 and the adoption of Rule 4.2, which granted the court of appeals discretion to permit the immediate appeal of certain district court orders. These provisions allowed parties to seek interlocutory review of orders before the conclusion of a case if a district court could certify that (1) immediate review might promote a more orderly disposition or establish a final disposition of the litigation, and (2) the order involved a controlling and unresolved question of law. The rule was patterned after 28 U.S.C. § 1292(b), which provides similar relief in the federal courts.
Read the court decisionRead the full story...Reprinted courtesy of
Jesse Howard Witt, The Witt Law FirmMr. Witt welcomes comments at www.acerbicwitt.com
Apartments pushed up US homebuilding in September
October 22, 2014 —
Josh Boak – Bloomberg BusinessweekWASHINGTON (AP) — Construction firms broke ground on more apartment complexes in September, pushing up the pace of U.S. homebuilding.
Housing starts rose 6.3 percent to a seasonally adjusted annual rate of 1.017 million homes, the Commerce Department said Friday. Almost all of the gains came from apartment construction — a volatile category — which increased 18.5 percent after plunging in August.
The sluggish recovery and meager wage growth has left more Americans renting instead of owning homes. Apartment construction has surged 30.3 percent over the past 12 months.
Read the court decisionRead the full story...Reprinted courtesy of
Josh Boak, Bloomberg Businessweek
Treasure Island Sues Beach Trail Designer over Concrete Defects
September 10, 2014 —
Beverley BevenFlorez-CDJ STAFFThe city of Treasure Island, Florida “has filed a lawsuit against Graham Landscape Design of St. Petersburg and Coastal Technology Corp. of Vero Beach for failing to properly design the 1-mile trail along the city's beachfront, which has hundreds of cracks in its concrete surface,” reported the Tampa Bay Times.
"The city has been unable to resolve the construction defects of the Central Beach Trail outside of the litigation process," City Attorney Maura Kiefer said to the Tampa Bay Times.
Cracks allegedly began appearing on the $1.2 million dollar trail soon after the project was concluded (March 2013). Treasure Island “submitted a performance bond claim and notified insurance companies representing Graham Landscape of the problem.”
Consultants hired by Phil Graham IV, the owner of the design company, determined that the cracking was caused by “a combination of problems in the design, construction and composition of materials.”
Read the court decisionRead the full story...Reprinted courtesy of