Insurer’s Broad Duty to Defend in Oregon, and the Recent Ruling in State of Oregon v. Pacific Indemnity Company
January 02, 2024 —
Keith Sparks - Ahlers Cressman & Sleight PLLCOregon law mandates a broad duty to defend, requiring insurers to provide legal representation to their policyholders whenever there is a potential for coverage under the policy. The significance of this broad interpretation means that an insurer has a duty to defend an insured even in situations where the alleged facts only imply a covered claim, and even in situations where the underlying claim is ultimately not covered by the policy. The insurer’s duty to defend is triggered if the allegations of the complaint, reasonably interpreted, could result in the insured being held liable for damages covered by the policy. This is referred to as the “four-corners” rule; it is also sometimes referred to as the eight-corners rule (for the four corners of the complaint plus the four corners of the policy). Oregon’s adoption of a broad interpretation of the duty to defend affirmatively places the onus on insurers to err on the side of coverage.
This broad duty to defend is based on the principle that an insured should not have to bear the expense of defending a lawsuit that the insurer may ultimately have to pay for. The duty to defend is also important because it helps ensure that insureds have access to legal representation when faced with a lawsuit.
Read the court decisionRead the full story...Reprinted courtesy of
Keith Sparks, Ahlers Cressman & Sleight PLLCMr. Sparks may be contacted at
keith.sparks@acslawyers.com
Maryland Contractor Documents its Illegal Deal and Pays $2.15 Million to Settle Fraud Claims
January 07, 2015 —
Craig Martin- Construction Contractor Advisor BlogWhy would a contractor create a contract for illegal work? I really don’t know.
Late last year, the FBI announced that a Maryland contractor, Forrester Construction Company, agreed to pay $2.15 million dollars to resolve a criminal investigation into alleged fraud in connection with the use of disadvantaged business enterprises involving more than $145 million of District of Columbia government contracts.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense
October 01, 2024 —
David Adelstein - Florida Construction Legal UpdatesA federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!!
In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:
The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.
Jackson Construction Co., supra, at 90.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Unbilled Costs Remain in Tutor Perini's Finances
October 23, 2018 —
Scott Van Voorhis – Engineering News-RecordTutor Perini is struggling to shake off long-running concerns over the hundreds of millions in unbilled costs that have been on the contractor’s balance sheet for years. The Sylmar, Calif.-based construction giant reported more than $1 billion in unbilled costs or receivables at the end of the second quarter, up by more than $100 million from the start of the year, according to the company’s federal filings. That was $100 million higher than at the end of 2016, when the amount was $832 million.
Read the court decisionRead the full story...Reprinted courtesy of
Scott Van Voorhis, ENRENR may be contacted at
ENR.com@bnpmedia.com
Florida “Property Damage” caused by an “Occurrence” and “Your Work” Exclusion
July 23, 2014 —
Scott Patterson - CD CoverageIn J.B.D. Construction, Inc. v. Mid-Continent Casualty Co., * Fed.Appx. *, 2014 WL 3377690 (11th Cir. 2014), claimant property owner Sun City contracted with insured general contractor J.B.D. for the construction of a fitness center. The fitness center was to be physically connected to an existing Sun City building. J.B.D. utilized subcontractors for some of the work. Shortly after completion, leaks developed in the fitness center’s roof, windows and doors which J.B.D. attempted to fix. After Sun City refused to make the final contract payment, J.B.D. sued Sun City for contract amounts owed. Sun City counterclaimed for the construction defects, alleged damage to the fitness center and other property. J.B.D. tendered defense of the counterclaim to its CGL insurer Mid-Continent. After Mid-Continent failed to agree to defend, J.B.D. settled with Sun City, paying Sun City $182K. Following several demands from J.B.D. for reimbursement of defense costs and the settlement amount, Mid-Continent tendered the defense costs minus a deductible. J.B.D. then sued Mid-Continent for breach of duties to defend and indemnify. On cross motions for summary judgment, the federal district trial court entered judgment for Mid-Continent, finding no duties to defend or indemnify. On appeal, the Eleventh Circuit reversed on the duty to defend while affirming on the duty to indemnify. Applying Florida law, the court first held that the defective work, including the defective installation of the fitness center’s windows, doors, and roof, did not constitute “property damage.” Thus, the costs to repair or replace the defective work did not constitute damages because of “property damage.” The court next held that, while damage to other portions of the fitness center would constitute “property damage” caused by an “occurrence,” all such “property damage” fell within the “your work” exclusion.
Read the court decisionRead the full story...Reprinted courtesy of
Scott Patterson, CD Coverage
Harsh New Time Limits on Construction Defect Claims
April 26, 2011 —
Scott F. Sullan, Esq., Mari K. Perczak, Esq., and Leslie A. Tuft, Esq.A recent Colorado Supreme Court decision, Smith v. Executive Custom Homes, Inc., 230 P.3d 1186 (Colo. 2010), considerably shortens the time limit for bringing many construction defect lawsuits. Homeowners and homeowner associations risk losing the right to seek reimbursement from builders, developers and other construction professionals unless they carefully and quickly act upon discovery of evidence of any potential construction defect.
The Statute of Limitations for Construction Defect Claims
Colorado’s construction defect statute of limitations limits the time for homeowners and homeowners associations to bring lawsuits for construction defects against “construction professionals,” including developers, general contractors, builders, engineers, architects, other design professionals, inspectors and subcontractors. The statute requires homeowners and associations to file suit within two years “after the claim for relief arises.” A claim for relief “arises” when a homeowner or association discovers or reasonably should have discovered the physical manifestation of a construction defect.
The two-year time limitation applies to each construction defect separately, and will begin to run upon the appearance of a “manifestation” of a construction defect (which may include, for example, a condition as simple as a roof leak or drywall cracks), even if the homeowner or association does not know the cause of the apparent problem.
The Smith Opinion and its Effect on the Statute of Limitations
In Smith v. Executive Custom Homes, Inc., the plaintiff homeowner, Mrs. Smith, slipped on ice that had accumulated on her sidewalk because of a leaking gutter and suffered injury. When she first noticed the leak, she reported it to her property manager, who reported it to the builder. The builder attempted to repair the gutter, unbeknownst to Mrs. Smith, and she did not notice further problems until approximately one year after she first observed the leak, when she fell and suffered serious injury. She sued the builder within two years of her injury, but nearly three years after she first learned of the leak.
The Colorado Supreme Court dismissed Mrs. Smith’s claims as untimely and held that under the construction defect statute of limitations, the two-year period for suing for injuries due to construction defects begins when the homeowner first observes the physical manifestation of the defect, even if the resulting injury has not yet occurred. The court acknowledged that this ruling could result in “unfair results,” especially if a serious and unforeseeable injury occurs more than two years after the first time the homeowner noticed the problem, and as a result the victim is unable to seek redress from those responsible for the defect.
Read the full story…
Reprinted courtesy of Scott F. Sullan, Esq., Mari K. Perczak, Esq., and Leslie A. Tuft, Esq. of Sullan2, Sandgrund, Smith & Perczak, P.C., and they can be contacted through their web site.
Read the court decisionRead the full story...Reprinted courtesy of
Mediating Contract Claims and Disputes at the ASBCA
December 20, 2021 —
Brian Waagner - Construction ExecutiveThe Contract Disputes Act establishes the formal process for resolving nearly all claims and disputes that arise under federal government contracts. It is the source of the requirement that contractors certify claims in excess of $100,000, the contracting officer’s final decision and the deadlines for bringing a dispute to the court of federal claims or an agency board of contract appeals.
It is also the source of the federal government’s authority to use mediation and other forms of alternative dispute resolution. Here are six key factors contractors should know about mediating contract claims and disputes at the Armed Services Board of Contract Appeals (ASBCA).
1. The Parties Control the Parameters of ADR Proceedings
Many commercial contracts and court rules require mediation of every dispute. There is no settlement meeting, mediation or any other type of mandatory ADR proceedings in cases brought to the ASBCA. The parties control the process, and they may adopt any approach to ADR that they believe will be effective. Mediation is nevertheless voluntary. Without the agreement of both parties, it won’t happen.
Reprinted courtesy of
Brian Waagner, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
No Coverage for Breach of Contract Claims Against Contractor
March 19, 2014 —
Tred R. Eyerly – Insurance Law HawaiiThe U. S. District Court found there was no coverage for breach of contract claims against the contractor who walked off the job before completing the project. Pa. Nat'l Mut. Cas. Ins. Co. v. Snider, 2014 U.S. Dist. LEXIS 16920 (M.D. Ala. Feb. 11, 2014).
The homeowners hired Jeff Beale to build their home for an approximate cost of $650,000. Beale said the job would take six to eight months and construction would be completed in early 2005. Construction did not begin, however, until April 2005. By 2005, the homeowners were becoming increasing displeased with Beale's progress. By March 2006, construction costs were approaching $800,000 and the home was not completed. The homeowners made progress payments on a monthly basis. Beale did not return to the home after April 2006 and another contractor was hired to complete the job.
When the homeowners moved in, they discovered several construction defects, including a cracked retaining wall and water intrusion in many areas of the home. They paid over $150,000 to repair the defects, to complete work Beale left unfinished, and remove mold.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
