Fairfield Connecticut Building Expert Directory

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Judge Sentences Roofing Contractor Owner in Florida PPP Fraud Case

July 25, 2021 — Richard Korman - Engineering News-Record
A federal judge in Fort Myers, Fla., sentenced Casey David Crowther, 35, the owner of a successful Florida roofing contracting company, to 37 months in prison for using fictitious employee lists to obtain a $2.7-million federal pandemic-aid loan and then purchasing a $689,000 boat with the funds. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

As Single-Family Homes Get Larger, Lots Get Smaller

September 03, 2014 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ (NAHB) Eye on Housing demonstrated that though the “single-family homes have been generally getting larger,” the average lot size has decreased over the years. For instance, from 1992-1995, “[t]he median lot size of a new single-family detached home sold was an even 10,000 square feet.” However, by 2004, lot size had decreased to 8,833 square feet. It bounced up to 9,000 and then came down again. In 2013, median lot size was 8,720 square feet. Read the court decision
Read the full story...
Reprinted courtesy of

Resulting Loss Provision Does Not Salvage Coverage

April 06, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The court confirmed that there was no coverage for damage to the policyholder's building caused by a large volume of water. Praetorian Ins. Co. v. Arabia Shrine Ctr. Houston, 2016 U.S. Dist. LEXIS 20186 (S.D. Texas Feb. 19, 2016). The damage occurred when water began seeping through the baseboards of the Shrine. Employees saw a large amount of water entering the building. Eventually, the city shut off a water main valve. It was later determined that an 8 inch diameter fire suppression metal pipe failed at the elbow, causing over one million gallons of water to be released into the building. Damages were estimated at nearly $1.7 million. Clean up and repair costs amounted to $237,156. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Court Dismisses Cross Claims Against Utility Based on Construction Anti-Indemnity Statute

August 14, 2018 — David R. Cook - Autry, Hall & Cook, LLP
When a plane crashed and several passengers and crew died or were injured, their representatives sued several defendants, including a nearby plant owner, Milliken & Company (“Plant Owner”), based on claims that transmission lines on Plant Owner’s property were too close to the runways, were too high, and encroached on the airport easements. Plant Owner cross claimed against utility owner, Georgia Power Company (“Utility”). Plant Owner’s claim was based on an easement it granted to Utility, which required Utility to indemnify it for any claims arising out of Utility’s construction or maintenance of the transmission lines. In defense, Utility argued that the easement’s indemnity provision violated Georgia’s construction anti-indemnity statute. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

No Retrofit without Repurposing in Los Angeles

October 21, 2013 — CDJ STAFF
The Los Angeles Times has continued its series on the seismic safety of buildings in downtown Los Angeles. According to the article, Los Angeles only requires seismic retrofits of buildings if their purpose is being changed. One investor, Izak Shomof, bought a residential hotel and kept it as one to avoid retrofitting the building. He converted an office building to upscale residences and so the building was strengthened. His son, Eric Shomof, keeps an office in the unreinforced building. He said if more retrofitting were required, “you’d see a lot more vacant buildings down here,” describing the process as “not cheap.” Depending on whether or when a building has changed its use, the concrete buildings of downtown Los Angeles may or may not be protected against failure in an earthquake. Read the court decision
Read the full story...
Reprinted courtesy of

Australians Back U.S. Renewables While Opportunities at Home Ebb

March 16, 2020 — Natalia Kniazhevich & Matthew Burgess - Bloomberg
Some of Australia’s biggest funds are pouring money into U.S. clean-energy projects as they butt up against a shortage of green opportunities at home. AustralianSuper, the country’s largest pension fund, recently joined Queensland Investment Corporation in a $1 billion funding round for Generate, a San Francisco-based green-finance company. And Construction and Building Unions Superannuation, another pension giant, made its first U.S. clean-power investments last year. The investments come as the wildfires that charred an area about the size of New York State have put increasing pressure on funds to do more to fight global warming. The problem, investors say, is the Australian government isn’t promoting clean-energy development, leaving the nation without enough sizable projects to back. “At this point the platforms of scale don’t exist in Australia,” said Nik Kemp, head of infrastructure at AustralianSuper. “The size of the U.S. market makes for a much larger market and much better long-term growth opportunities.” Read the court decision
Read the full story...
Reprinted courtesy of Natalia Kniazhevich & Matthew Burgess, Bloomberg

Three Recent Cases Strike Down Liquidated Damages Clauses In Settlement Agreements…A Trend Or An Aberration?

November 01, 2021 — Adam M. Tuckman - ConsensusDocs
Beginning more than one century ago, owners and contractors generally have adopted the convention of including liquidated damages in their contracts to fix potential liability for delay (and other losses) at the inception of the project. The proliferation of liquidated damages clauses in modern contracts can be attributed to economic and legal factors. From the owner’s standpoint, it may be exceedingly difficult to prove the actual cost impact of a delayed completion of the project. A properly calculated liquidated damages rate would save the owner the significant expense of quantifying its delay damages. On the contractor’s side, a reasonable amount of liquidated damages may be preferable to uncapped or unknown liability, allowing the contractor to more accurately price its bid and efficiently allocate risk. Coinciding with, or perhaps a leading cause of, the industry’s embrace of liquidated damages provisions, was the shift in courts throughout the country from disfavoring such clauses to accepting them (within limits) as an appropriate exercise of contract rights. While some variation exists among the states, courts have generally recognized that liquidated damages clauses are a viable alternative to proof of actual loss so long as (i) actual losses were difficult to quantify, and (ii) the stipulated sum bears a reasonable relationship to the anticipated loss at the time of contracting. See, e.g., Restatement (Second) of Contracts § 356. Conversely, a clause that penalizes the breaching party rather than serving as an estimate of probable loss is likely to be found unenforceable. Read the court decision
Read the full story...
Reprinted courtesy of Adam M. Tuckman, Watt, Tieder, Hoffar, & Fitzgerald, LLP
Mr. Tuckman may be contacted at atuckman@watttieder.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES