Seattle Washington Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Suing A Payment Bond Surety in Different Venue Than Set Forth in The Subcontract

August 10, 2021 — David Adelstein - Florida Construction Legal Updates
The venue to file a lawsuit can be an important issue for a variety of reasons, whether for convenience or the prospect of a more favorable outcome. Oftentimes, there is a venue provision in a contract that provides where the exclusive venue for any dispute arising out of the contract must be brought. In a recent case, Southeastern Concrete Constructors, LLC v. Western Surety Company, 2021 WL 2557297 (Fla. 2d DCA 2021), dealing with a Florida Department of Transportation (FDOT) project, a subcontractor filed suit against the general contractor’s FDOT payment bond issued under Florida Statute s. 337.18. The subcontractor did not file suit against the general contractor. The subcontractor filed suit in Hillsborough County, Florida. However, the subcontract contained a venue provision requiring disputes under the subcontract to be brought in Levy County, Florida. Based on this venue provision in the subcontract, the trial court granted a motion to transfer the venue of the dispute to Levy County. This, however, was reversed on appeal. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Super Lawyers Selects Haight’s Melvin Marcia for Its 2023 Northern California Rising Stars List

July 16, 2023 — Melvin F. Marcia - Haight Brown & Bonesteel LLP
Congratulations to Melvin Marcia who was selected to the 2023 Northern California Rising Stars list. Each year, no more than 2.5 percent of the lawyers in the state are selected by the research team at Super Lawyers to receive this honor. Super Lawyers, part of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. The result is a credible, comprehensive and diverse listing of exceptional attorneys. The Super Lawyers lists are published nationwide in Super Lawyers magazines and in leading city and regional magazines and newspapers across the country. Super Lawyers magazines also feature editorial profiles of attorneys who embody excellence in the practice of law. Read the court decision
Read the full story...
Reprinted courtesy of Melvin F. Marcia, Haight Brown & Bonesteel LLP
Mr. Marcia may be contacted at mmarcia@hbblaw.com

ETF Bulls Bet Spring Will Thaw the U.S. Housing Market

April 08, 2014 — Corinne Gretler – Bloomberg
Build it and they will come, if it’s not too chilly. Traders have turned bullish on a security that tracks home construction companies, appliance makers and furniture retailers as spring finally ends the harsh winter. As the SPDR S&P Homebuilders ETF (XHB) heads for its first weekly gain since February, investors are buying options betting that the rebound will keep going. The cost of bullish contracts has risen to the highest versus bearish ones in 2 ½ years. The ETF has gained 2.2 percent this week. The exchange-traded fund of companies such as Ryland Group Inc., Whirlpool Corp. and Home Depot Inc. has rebounded 8 percent after reaching its lowest level this year on Feb. 3 as investors attribute weakness in the housing market to winter weather. Between December and February, snow covered 1.42 million square miles of the continental U.S., the 10th-largest snow cover in records going back to 1966, according to the National Climatic Data Center. Read the court decision
Read the full story...
Reprinted courtesy of Corinne Gretler, Bloomberg
Ms. Gretler may be contacted at cgretler1@bloomberg.net

TxDOT, Flatiron/Dragados Mostly Resolve Bridge Design Dispute

March 13, 2023 — James Leggate - Engineering News-Record
The Texas Dept. of Transportation and contractor Flatiron/Dragados LLC have “completely satisfied” four of the five main design safety concerns the state agency raised over the under-construction new Harbor Bridge in Corpus Christi, officials say. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The EEOC Is Actively Targeting the Construction Industry

February 27, 2023 — Cameron S. Hill Sr. & Maia Fleischman, Construction Executive
Risks and potential liabilities in the construction industry are not new. Construction participants know the typical hot spots: Projects are delayed. Supply chain issues raise materials costs. Owners and general contractors dispute the effects of changes in the scope of work. Employees can become injured. Be aware that workplace conduct and practices are increasingly a priority and focus for governmental intervention, resulting in increased risk management attention on the construction industry. The Equal Employment Opportunity Commission (EEOC) is watching, and if you are not prepared, you could be liable for hundreds of thousands of dollars related to how your employees interact with each other. We recommend you immediately review your employment policies and procedures in addition to considering an update of your training practices. Reprinted courtesy of Cameron S. Hill Sr. and Maia Fleischman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Hill may be contacted at chill@bakerdonelson.com Ms. Fleischman may be contacted at mfleischman@bakerdonelson.com Read the court decision
Read the full story...
Reprinted courtesy of

Location, Location, Location—Even in Construction Liens

October 28, 2015 — Craig Martin – Construction Contractor Advisor
We all know the importance of filing a construction lien within 120 days of your last work. Nebraska Construction Lien Act, § 52-137. But, equally, if not more important is filing the construction lien on the correct property. Often times on a construction project, the exact address of the project may not be known. And, if there are a few buildings going up on the same general site, it is difficult to determine which property or building address you are working on. Sometimes you can look at the contract. For example, the AIA family of documents lists the address on the first page. But, what if the wrong address is listed? What if the wrong owner is listed? Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Balfour in Talks With Carillion About $5 Billion Merger

July 30, 2014 — Simon Thiel and Alex Webb – Bloomberg
Balfour Beatty Plc (BBY), the U.K. construction company whose chief quit in May after predicting a profit drop, is in merger talks with rival Carillion Plc (CLLN) to form the country’s biggest builder with a market valuation of about 3 billion pounds ($5 billion). A deal would create a market-leading service and construction business able to serve more clients and cut costs, the builders said in a statement yesterday, adding that they’re trying to develop a strategy and business plan. Balfour and Carillion surged as much as 13 percent and 14 percent respectively in London trading today. Balfour, based in London, has struggled since the global recession, with a lack of building work in the U.K. and the cancellation of projects across Australia, where the company cut hundreds of jobs last year. A merged company would benefit from Carillion’s booming services business as the Wolverhampton, England-based builder expands its maintenance offerings for the rail, oil and telecommunication industries. Mr. Thiel may be contacted at sthiel1@bloomberg.net; Mr. Webb may be contacted at awebb25@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Simon Thiel and Alex Webb, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES